MICHEL, Circuit Judge.
The Sharman Company (“Sharman” or “the contractor”) appeals from the judgment of the United States Claims Court,1 awarding the government $1,391,240 under the Contract Disputes Act of 1978 (CDA), 41 U.S.C. § 601 et seq., following the contractor’s repudiation of this contract to make steel water tanks for the Marine Corps. The Sharman Company v. United States, No. 90-108C (Cl. Ct. June 12, 1992). The Claims Court held that the government was entitled to return of $1,391,240 in unliquidated progress payments because prior steel price increases, not the government’s delays, caused the contractor’s decision not to perform.
Sharman filed suit on February 2, 1990, placing the progress payments claim in litigation. Per CDA section 605, a final decision of a contracting officer on a claim is a jurisdictional prerequisite to litigation. Because the contracting officer had not issued a final decision as to either the government counterclaim, or the contractor’s mirror image claim regarding the progress payments, both derivative of the original contractor costs claim, before Sharman filed suit, the Claims Court lacked jurisdiction over both claims and should have dismissed them.
The Claims Court, however, dismissed the contractor’s claim for its costs asserted in the original complaint of February 2, 1990 as arising from a termination for the convenience of the government, because that claim had not been presented to the contracting officer. Therefore, the jurisdictional prerequisite was held not met as to this claim.2
Additionally, the Claims Court dismissed Sharman’s challenge in its original complaint to the default termination as a declaratory judgment complaint beyond its jurisdiction. Since the 1992 amendments to the CDA grant the Claims Court jurisdiction over contractor challenges to default terminations in all non-final cases, the Claims Court now has subject matter jurisdiction over this matter.
Accordingly, we: (1) reverse the money judgment in favor of the government, for lack of jurisdiction; and (2) remand with instructions to address the contractor’s independent challenge to the default termination, which is no longer beyond the Claims Court’s jurisdiction and in light of our holding requires decision.
I. BACKGROUND
Sharman contracted with the United States Marine Corps (“the government”) for the manufacture of steel water tanks. Due to escalation in steel prices during the term of contract performance, Sharman repudiated the contract. Because Sharman did not complete production of the tanks as required, the government terminated the entire contract 3 for default through a notice and final decision of termination issued by the contracting officer on August 7, 1989.
On September 12, 1989, the government sent a letter to the contractor seeking repay[1567]*1567ment of progress payments in the' amount of $2,066,696.36. The letter was characterized as a “notice of demand for payment of contract debt,” and also notified Sharman that if it disputed the amount sought, it could submit a proposal for deferment of collection.
Sharman, however, did not dispute the amount to the contracting officer but instead filed suit in the Claims Court on February 2, 1990. In its complaint, “Sharman sought invalidation of the default termination, conversion of the termination to one for Government convenience and recovery of all uncompensated costs incurred in the contract’s performance.” Sharman Co. v. United States, 24 Cl.Ct. 763, 765 (1991) (as characterized by Claims Court in its ruling on the government’s motion to dismiss). The complaint also included a count in quantum meruit asserting entitlement to all the government’s progress payments, which Sharman characterized as “payment for the work performed” on the contract, plus additional monies.4
The government filed its answer to Shar-man’s complaint on May 3, 1990, denying Sharman’s entitlement to relief as well as its characterization of the government’s progress payments as earned.
On June 12, 1990, the government moved to dismiss the complaint for lack of subject matter jurisdiction on the grounds that the complaint did not present a “claim,” i. e., an assertion of entitlement to a sum certain presently due and owing, but rather, was essentially a request for declaratory relief concerning the lawfulness of the default termination. Alternatively, the government argued that even if Sharman’s complaint were read as including a demand for relief from the debt first noticed in the contracting officer’s letter of September 12, 1989, the court lacked jurisdiction because on its face that letter plainly was not a final decision, which did not issue until after suit was initiated.
On October 18, 1990, before the Claims Court ruled on the government’s motion to dismiss, the contracting officer sent the contractor another letter regarding return of the progress payments. This letter stated that it was a “notice of the Contracting Officer’s final decision,” and identified the amount owed in unliquidated progress payments as $1,391,240.29. It was the first statement by the government of a “claim,” i.e., the assertion as a matter of right to a sum certain as presently due and owing, on which there was a final decision by the contracting officer.
On December 20, 1991, the Claims Court granted in part and denied in part the government’s motion to dismiss. The court dismissed Sharman’s claim for convenience termination costs on the grounds that the claim had not been quantified and had never been submitted to the contracting officer. Sharman, 24 Cl.Ct. at 766. The court also stated that, in view of Overall Roofing & Construction, Inc. v. United States, 929 F.2d 687, 689 (Fed.Cir.1991), the contracting officer’s decision on the default termination was, of itself, insufficient to confer jurisdiction with respect to Sharman’s challenge. However, the court held that it nevertheless had jurisdiction to entertain Sharman’s challenge to the default termination decision as an issue relating to the money claim but not as an independent claim, i.e., a separate cause of action. It viewed the contracting officer’s letter of September 12, 1989, concerning return of excess progress payments as a “timely assertion of a repayment demand,” 24 Cl.Ct. at 767, which had the effect of quantifying the government’s claim inherent in the earlier default termination decision. Accordingly, the Claims Court viewed Sharman’s challenge to the termination for default as being properly before it “as a contractor’s suit on a quantified Government claim.” Id. at 768. The court did not explain how this September 1989 notice and demand constituted a “claim” under the CDA and its implementing regulation. Nor did it explain how the September letter met the requirement for a final decision.
In response to the court’s partial dismissal, Sharman amended its complaint on January 6, 1992 to include a specific challenge to the [1568]*1568government’s right to payment of the amount representing unliquidated progress payments. The government counterclaimed for the unliquidated progress payments in the amount of $1,391,240.
Free access — add to your briefcase to read the full text and ask questions with AI
MICHEL, Circuit Judge.
The Sharman Company (“Sharman” or “the contractor”) appeals from the judgment of the United States Claims Court,1 awarding the government $1,391,240 under the Contract Disputes Act of 1978 (CDA), 41 U.S.C. § 601 et seq., following the contractor’s repudiation of this contract to make steel water tanks for the Marine Corps. The Sharman Company v. United States, No. 90-108C (Cl. Ct. June 12, 1992). The Claims Court held that the government was entitled to return of $1,391,240 in unliquidated progress payments because prior steel price increases, not the government’s delays, caused the contractor’s decision not to perform.
Sharman filed suit on February 2, 1990, placing the progress payments claim in litigation. Per CDA section 605, a final decision of a contracting officer on a claim is a jurisdictional prerequisite to litigation. Because the contracting officer had not issued a final decision as to either the government counterclaim, or the contractor’s mirror image claim regarding the progress payments, both derivative of the original contractor costs claim, before Sharman filed suit, the Claims Court lacked jurisdiction over both claims and should have dismissed them.
The Claims Court, however, dismissed the contractor’s claim for its costs asserted in the original complaint of February 2, 1990 as arising from a termination for the convenience of the government, because that claim had not been presented to the contracting officer. Therefore, the jurisdictional prerequisite was held not met as to this claim.2
Additionally, the Claims Court dismissed Sharman’s challenge in its original complaint to the default termination as a declaratory judgment complaint beyond its jurisdiction. Since the 1992 amendments to the CDA grant the Claims Court jurisdiction over contractor challenges to default terminations in all non-final cases, the Claims Court now has subject matter jurisdiction over this matter.
Accordingly, we: (1) reverse the money judgment in favor of the government, for lack of jurisdiction; and (2) remand with instructions to address the contractor’s independent challenge to the default termination, which is no longer beyond the Claims Court’s jurisdiction and in light of our holding requires decision.
I. BACKGROUND
Sharman contracted with the United States Marine Corps (“the government”) for the manufacture of steel water tanks. Due to escalation in steel prices during the term of contract performance, Sharman repudiated the contract. Because Sharman did not complete production of the tanks as required, the government terminated the entire contract 3 for default through a notice and final decision of termination issued by the contracting officer on August 7, 1989.
On September 12, 1989, the government sent a letter to the contractor seeking repay[1567]*1567ment of progress payments in the' amount of $2,066,696.36. The letter was characterized as a “notice of demand for payment of contract debt,” and also notified Sharman that if it disputed the amount sought, it could submit a proposal for deferment of collection.
Sharman, however, did not dispute the amount to the contracting officer but instead filed suit in the Claims Court on February 2, 1990. In its complaint, “Sharman sought invalidation of the default termination, conversion of the termination to one for Government convenience and recovery of all uncompensated costs incurred in the contract’s performance.” Sharman Co. v. United States, 24 Cl.Ct. 763, 765 (1991) (as characterized by Claims Court in its ruling on the government’s motion to dismiss). The complaint also included a count in quantum meruit asserting entitlement to all the government’s progress payments, which Sharman characterized as “payment for the work performed” on the contract, plus additional monies.4
The government filed its answer to Shar-man’s complaint on May 3, 1990, denying Sharman’s entitlement to relief as well as its characterization of the government’s progress payments as earned.
On June 12, 1990, the government moved to dismiss the complaint for lack of subject matter jurisdiction on the grounds that the complaint did not present a “claim,” i. e., an assertion of entitlement to a sum certain presently due and owing, but rather, was essentially a request for declaratory relief concerning the lawfulness of the default termination. Alternatively, the government argued that even if Sharman’s complaint were read as including a demand for relief from the debt first noticed in the contracting officer’s letter of September 12, 1989, the court lacked jurisdiction because on its face that letter plainly was not a final decision, which did not issue until after suit was initiated.
On October 18, 1990, before the Claims Court ruled on the government’s motion to dismiss, the contracting officer sent the contractor another letter regarding return of the progress payments. This letter stated that it was a “notice of the Contracting Officer’s final decision,” and identified the amount owed in unliquidated progress payments as $1,391,240.29. It was the first statement by the government of a “claim,” i.e., the assertion as a matter of right to a sum certain as presently due and owing, on which there was a final decision by the contracting officer.
On December 20, 1991, the Claims Court granted in part and denied in part the government’s motion to dismiss. The court dismissed Sharman’s claim for convenience termination costs on the grounds that the claim had not been quantified and had never been submitted to the contracting officer. Sharman, 24 Cl.Ct. at 766. The court also stated that, in view of Overall Roofing & Construction, Inc. v. United States, 929 F.2d 687, 689 (Fed.Cir.1991), the contracting officer’s decision on the default termination was, of itself, insufficient to confer jurisdiction with respect to Sharman’s challenge. However, the court held that it nevertheless had jurisdiction to entertain Sharman’s challenge to the default termination decision as an issue relating to the money claim but not as an independent claim, i.e., a separate cause of action. It viewed the contracting officer’s letter of September 12, 1989, concerning return of excess progress payments as a “timely assertion of a repayment demand,” 24 Cl.Ct. at 767, which had the effect of quantifying the government’s claim inherent in the earlier default termination decision. Accordingly, the Claims Court viewed Sharman’s challenge to the termination for default as being properly before it “as a contractor’s suit on a quantified Government claim.” Id. at 768. The court did not explain how this September 1989 notice and demand constituted a “claim” under the CDA and its implementing regulation. Nor did it explain how the September letter met the requirement for a final decision.
In response to the court’s partial dismissal, Sharman amended its complaint on January 6, 1992 to include a specific challenge to the [1568]*1568government’s right to payment of the amount representing unliquidated progress payments. The government counterclaimed for the unliquidated progress payments in the amount of $1,391,240. The government also requested that the Claims Court certify the jurisdictional issue for an interlocutory appeal pursuant to 28 U.S.C. § 1292(b) (1988), but the request was denied.
On June 11, 1992, the Claims Court ruled from the bench on the merits of the government claim. The Claims Court found that “[ijnasmuch as the escalation in steel prices had begun well before [the date from which the government was responsible for the delay], the Government’s delay cannot be considered the source of the contractor’s injuries.” Accordingly, the Claims Court entered judgment in the amount of $1,391,240 on the government’s counterclaim and in light of its ruling in December 1991, dismissed the remainder of the contractor’s complaint, inter alia, challenging the default termination. Sharman appealed to this court. We have jurisdiction pursuant to 28 U.S.C. § 1295(a)(3) (1988).
II. STANDARD OF REVIEW
In an appeal of a CDA case, we review de novo for errors of law. See Cooper v. United States, 827 F.2d 762, 763 (Fed.Cir.1987) (citing Milmark Servs., Inc. v. United States, 731 F.2d 855, 857 (Fed.Cir.1984)). A determination of whether the Claims Court had jurisdiction in such a case is a question of law. Transamerica Ins. Corp. v. United States, 973 F.2d 1572, 1576 (Fed.Cir.1992). Therefore, no deference is due to the Claims Court decision on the dispositive issue here.
III. ANALYSIS
On appeal, both parties argue that the Claims Court lacked jurisdiction over the contractor’s claim and the government counterclaim for return of progress payments. Therefore, before we may review the merits we must first address whether the Claims Court had jurisdiction over any of the claims in suit.
A. The Government’s Counterclaim for Progress Payments
On appeal, the government argues, as it did in its motion to dismiss, that “because the Government’s claim for the return of unliqui-dated progress payments was not the subject of a final contracting officer’s decision prior to the commencement of this suit, the Claims Court lacked jurisdiction to entertain the suit.” The government is correct.
Under the CDA, a final decision by the contracting officer on a claim, whether asserted by the contractor or the government, is a “jurisdictional prerequisite”5 to further legal action thereon.6 41 U.S.C. [1569]*1569§ 605(a) (“All claims by a contractor against the government relating to a contract shall be in writing and shall be submitted to the contracting officer for a decision. All claims by the government against a contractor relating to a contract shall be the subject of a decision by the contracting officer.”); 41 U.S.C. § 605(b) (“The contracting officer’s decision on the claim shall be final and conclusive and not subject to review by any forum, tribunal, or Government agency, unless an appeal or suit is timely commenced as authorized by this chapter.”); Joseph Morton Co. v. United States, 757 F.2d 1273, 1279-80 (Fed.Cir.1985) (holding both contractor claims and government counterclaims require contracting officer’s final decision); Paragon Energy Corp. v. United States, 645 F.2d 966, 971, 227 Ct.Cl. 176 (1981), aff'd, 230 Ct.Cl. 884, 1982 WL 25259 (1982); Burgett Inv., Inc., AGBCA No. 81-108-1, 81-1 BCA ¶ 14,-913 (1981) (dismissing newly asserted government counterclaim because under the CDA issuance and receipt of contracting officer’s final decision on the claim is a jurisdictional prerequisite). In this context, “claim” refers to “each claim under the CDA for money that is one part of a divisible case.” Joseph Morton Co., 757 F.2d at 1281. Moreover, although the recent amendments to the CDA allow post-filing curing of technical defects in certification, they do not dispense with the “jurisdictional prerequisite” of a pre-filing final decision by the contracting officer. See 138 Cong.Rec. S17799 (daily ed. October 8, 1992) (statement of Sen. Heflin) (stating that “[a] contracting officer’s final decision under the Contract Disputes Act will remain a jurisdictional prerequisite to review by the Court of Federal Claims” even after the amendments made by Public Law No. 102-572) (emphasis added).
As the Claims Court itself noted, jurisdiction must be determined “under the actual circumstances existing at the time a complaint is filed,” 24 Cl.Ct. at 769; accord Newman-Green, Inc. v. Alfonzo-Larrain, 490 U.S. 826, 830, 109 S.Ct. 2218, 2221-22, 104 L.Ed.2d 893, reh’g denied, 492 U.S. 932, 110 S.Ct. 12, 106 L.Ed.2d 627 (1989) (stating that “[t]he existence of federal jurisdiction ordinarily depends on the facts as they exist when the complaint is filed.”). Here, the jurisdictional prerequisite as to both the contractor’s claim and the government’s counterclaim for progress payments was not met because there was no final decision of the contracting officer at the time that Sharman filed its initial complaint, alleging, in part, entitlement to the government’s progress payments. Neither the August 7, 1989 default termination decision, the September 12, 1989 demand letter, nor the October 18, 1990 “final decision” letter, alone or in combination, qualifies as a valid and timely final decision of the contracting officer on the government’s counterclaim or the contractor’s mirror image claim.
Furthermore, although Sharman amended its complaint on January 6, 1992 to include an explicit challenge to the government’s right to return of the unliquidated progress payments, this amendment merely restated, inter alia, Sharman’s earlier assertion of entitlement to those same payments for the same partial performance in the quantum meruit count of its original complaint. [1570]*1570Therefore, it is actually the same claim. Similarly, the added government counterclaim involves the same unliquidated progress payments and the same partial performance, and is therefore effectively the same claim, but made by the other party. Therefore, because the progress payment claim was part of the litigation from the outset, Sharman’s later amendment to its complaint, and the corresponding government counterclaim which followed, do not affect our determination. Whether the jurisdictional prerequisite was met must be judged from the time that the progress payment claim became part of the lawsuit — ie., when the lawsuit was first filed. Here there was no final decision on any such claim at that time.
1. The August 7, 1989 Default Termination Decision
Although the contracting officer had issued a final decision on the default termination, he had not issued as a final decision the government’s demand for the return of unliquidated progress payments when the original suit was filed. The contracting officer’s default termination letter of August 7, 1989 could not provide a jurisdictional basis for the government’s counterclaim for progress payments because these two claims are not the same. Crippen & Graen Corp. v. United States, 18 Cl.Ct. 237, 241 (1989) (“[T]he default claim and the demand for return of the unliquidated progress payments are separate and distinct ... for jurisdictional purposes.”). Therefore, the contracting officer’s final decision solely on the default termination does not satisfy the jurisdictional prerequisite of a contracting officer’s final decision as to the unliquidated progress payments claim. Id. at 240-41 (distinguishing Nuclear Research Corp. v. United States, 814 F.2d 647 (Fed.Cir.1987) on the ground that the contracting officer in that case made a final decision on both the default termination and the progress payment claim).
Furthermore, the government’s claim for return of progress payments is a claim for money damages. Such a claim requires a “written demand or written assertion by one of the contracting parties seeking, as a matter of right, the payment of money in a sum certain.” FAR § 33.201 (1992). At the time of the August letter, no such written demand or assertion of present entitlement to a sum certain had been submitted to or issued by the contracting officer. Additionally, the August letter contains no reference to any money entitlement being asserted by the government, let alone to the progress payments. Therefore, the August letter could not possibly constitute a final decision for purposes of the government’s money damages claim or the contractor’s mirror image claim.
2. The September 12, 1989 Demand Letter
The September 12, 1989 letter seeking repayment of the progress payments is also not a final decision for jurisdictional purposes on the government’s counterclaim. On its face, this letter simply states that it is a “notice and demand for payment”; it does not contain the customary designation “final decision.” The text of the September letter also makes clear that it is not a final decision because it specifically invites Sharman to submit a proposal for deferment of collection “if immediate payment is not practicable or if the amount is disputed.” 24 Cl.Ct. at 766. As the Claims Court itself acknowledged, such notices are “tentative determinations issued to invite contractor comment rather than as final decisions.” Id. at 768 (citing Crippen & Graen, 18 Cl.Ct. at 240). The September letter, therefore, is not a final decision, either viewed alone, or, as urged by the Claims Court, in the context of the earlier August letter.
The Claims Court’s theory that the September letter “quantified” a government claim, implicit in the August default termination letter and therefore the two letters taken together constitute a valid final decision on a “claim” for jurisdictional purposes is incorrect.7 There is no authority that [1571]*1571supports the combining of two separate letters from the contracting officer, one constituting a final decision on a default termination—the August letter—and the other demanding a specific amount—the September letter—to create a final decision on a monetary claim. They are two entirely separate communications related to two separate and distinct matters.8 Even assuming that combining such letters were ever permissible, the facts in this case do not support such a combination. The August letter made no reference to any money entitlement; therefore there was no “claim” in the August letter for the September letter to quantify, as theorized by the Claims Court. Moreover, the amount specified in the September letter was not yet in dispute at the time of the August or September letters; it had been proposed by the contracting officer and not rejected by the contractor. Therefore, these letters do not assert a claim. Dawco Constr., Inc. v. United States, 930 F.2d 872, 878 (Fed.Cir.1991) (“[A] claim must seek payment of a sum certain as to which a dispute exists at the time of submission.”). Indeed, the amount was later cut nearly in half by the government, unilaterally.9 Consequently, the September letter, taken alone or in combination with the August letter, provides no final decision for jurisdictional purposes on the government’s monetary claim.
3. The October 18, 1990 Letter
On October 18, 1990, the contracting officer issued a letter, calling itself a “final decision,” on the government claim for unliq-uidated progress payments. As noted by the Claims Court, however, this letter did not issue until “more than six months after this suit was filed.” 24 Cl.Ct. at 766. Sharman’s original complaint was filed on February 2, 1990, alleging entitlement to the government’s progress payments under a quantum meruit theory as part of its “reimburse[ment] ... for the value of the work performed.” As noted earlier, this asserted entitlement to the progress payments in Sharman’s original complaint is the same “claim” as stated by Sharman’s amended complaint and the government’s counterclaim, because in each case the “claim” alleges entitlement to the same money based on the same partial performance, only under a different legal label. Therefore, the progress payment “claim” was in litigation between the parties as of the date that Sharman’s original complaint was filed.10
Once a claim is in litigation, the Department of Justice gains exclusive authority to act in the pending litigation. 28 U.S.C. §§ 516-20 (1988); Hughes Aircraft Co. v. United States, 534 F.2d 889, 901, 209 Ct.Cl. 446 (1976). That exclusive authority divests the contracting officer of his authority to issue a final decision on the claim. Durable [1572]*1572Metal Prods., Inc. v. United States, 21 Cl.Ct. 41, 46 (1990) (filing suit in Claims Court divests contracting officer of authority over plaintiffs claim). Because the progress payment claim was the subject of litigation at the outset, the contracting officer had no authority to issue a final decision on the claim after the complaint was filed. Therefore, the October 1990 final decision letter was issued without authority and consequently is a nullity. It also came too late to affect jurisdiction which must be assessed as of February 1990. As a result, it provides no jurisdictional basis for the government’s counterclaim for the progress payments.
B. The Default Termination Challenge
The Claims Court dismissed the portion of Sharman’s original complaint seeking declaratory judgment that the government’s termination for default was unlawful, because it was unaccompanied by a monetary claim.11 This ruling was correct at the time it was made because Overall Roofing required such a result. 929 F.2d at 689. Section 907(b)(1) of Public Law No. 102-672, enacted on October 29, 1992, however, effectively overrules Overall Roofing and grants the Claims Court jurisdiction to determine whether a termination for default is proper. Federal Courts Administration Act of 1992, Pub.L. No. 102-572, § 907(b), 106 Stat. 4506, 4519.12 This new jurisdiction applies retroactively to actions that were still awaiting final judgment upon enactment, as this one was.13
Therefore, the Claims Court now has jurisdiction to address the contractor’s independent challenge to the default termination.14 In light of our decision reversing the money judgment in favor of the government, the contractor’s challenge to the government’s termination for default is not moot and there[1573]*1573fore must be remanded for decision.15
IV. CONCLUSION
A final decision from the contracting officer on the government’s monetary claim, the basis of the trial court’s judgment, was a prerequisite to jurisdiction over this claim in the Claims Court. Because this claim was effectively put in litigation by Sharman’s original complaint and because the contracting officer had not issued a final decision as to either the government claim or the contractor’s mirror image claim before the original suit was filed, the Claims Court did not have jurisdiction over either claim. In addition, because there had been no final decision by the contracting officer on the contractor’s claim for convenience termination costs, the Claims Court correctly dismissed it for lack of jurisdiction. Accordingly, we: (1) reverse the money judgment in favor of the government; and (2) remand with instructions: under the 1992 amendments to the CDA the Claims Court now has subject matter jurisdiction over the default termination challenge in the contractor’s original complaint, and in light of our holdings it now requires decision.
REVERSED AND REMANDED.
COSTS
Each party to bear its own costs.