Opinion
KENNARD, J.
In recent years, general contractors in California have begun to insert “pay if paid” provisions into their agreements with subcontractors. A pay if paid provision makes payment by the owner to the general contractor a condition precedent1 to the general contractor’s obligation to pay the subcontractor for work the subcontractor has performed.
In other jurisdictions, the majority view is that, if reasonably possible, clauses in construction subcontracts stating that the subcontractor will be paid when the general contractor is paid will not be construed as establishing true conditions precedent, but rather as merely fixing the usual time for payment to the subcontractor, with the implied understanding that the subcontractor in any event has an unconditional right to payment within a reasonable time. (See, e.g., Koch v. Construction Technology, Inc. (Tenn. 1996) 924 S.W.2d 68; Power & Pollution Svcs. v. Suburban Piping (1991) 74 Ohio App.3d 89 [598 N.E.2d 69]; OBS Co., Inc. v. Pace Const. Corp. (Fla. 1990) 558 So.2d 404; Southern St. Masonry v. J.A. Jones Const. (La. 1987) 507 So.2d 198; Thos. J. Dyer Co. v. Bishop International Engineering Co. (6th Cir. 1962) 303 F.2d 655.) This approach has been followed in California. (Yamanishi v. Bleily & Collishaw, Inc. (1972) 29 Cal.App.3d 457, 462-463 [105 Cal.Rptr. 580]; see also Rubin v. Fuchs (1969) 1 Cal.3d 50, 53 [81 Cal.Rptr. 373, 459 P.2d 925] [stating that “provisions of a contract will not be construed as conditions precedent in the absence of language plainly requiring such construction”].) A contract clause that has been construed in this fashion is sometimes referred to as a “pay when paid” rather than a “pay [886]*886if paid” provision. (See Kirksey, “Minimum Decencies”—A Proposed Resolution of the “Pay-When-Paid”/ “Pay-If-Paid” Dichotomy (Jan. 1992) Construction Law. 1.)
If it is not reasonably possible to construe the contractual provision as other than a condition precedent, then courts must decide whether public policy permits enforcement of a contractual provision that may result in the subcontractor’s forfeiting all right to payment for work performed. The high court of New York has concluded that a true pay if paid provision in a subcontract for construction work is void as against public policy. (West-Fair Elec. v. Aetna Cas. & Sur. Co. (1995) 87 N.Y.2d 148, 157 [638 N.Y.S.2d 394, 398, 661 N.E.2d 967, 971].) In Illinois, North Carolina, and Wisconsin, pay if paid provisions have been declared void and unenforceable by statute.2 (770 Ill. Comp. Stat. Ann. 60/21; N.C. Gen. Stat. § 22C-2 (1991); Wis. Stat. § 779.135.) The validity of a true pay if paid provision presents a question of first impression in this court.
We granted review in this case to determine whether a subcontractor may collect on a general contractor’s payment bond for work it has performed under a contract containing a pay if paid provision when the owner has not paid the general contractor. We conclude that pay if paid provisions like the one at issue here are contrary to the public policy of this state and therefore unenforceable because they effect an impermissible indirect waiver or forfeiture of the subcontractors’ constitutionally protected mechanic’s lien rights in the event of nonpayment by the owner. Because they are unenforceable, pay if paid provisions in construction subcontracts do not insulate either general contractors or their payment bond sureties from their contractual obligations to pay subcontractors for work performed.
I. Facts
In 1990, the owner of a commercial building in Los Angeles entered into a contract with Keller Construction Co., Ltd. (Keller), as general contractor, for rehabilitation work on the building. Keller in turn entered into subcontracts for this project with, among others, Wm. R. Clarke Corporation, Barsotti’s, Inc., Garvin Fire Protection Systems, Inc., and Church and Larsen, Inc. (collectively, the subcontractors). Each subcontract contained a pay if paid provision and three of the four subcontracts also included an [887]*887addendum reiterating the pay if paid limitation yet also purporting to preserve the subcontractors’ mechanic’s lien rights and to make those rights the subcontractors’ “sole remedy” in the event the owner failed to pay Keller.3
At the owner’s insistence, and pursuant to the terms of the general contract, Keller obtained a labor and material payment bond from defendant Safeco Insurance Company of America (Safeco) to protect the owner from mechanic’s lien claims by subcontractors and material suppliers. The bond recited that it was a payment bond as defined in Civil Code section 30964 and that it had been executed to comply with title 15 (Works of Improvement) of the Civil Code.5 The bond stated that Keller, as principal, and Safeco, as surety, “are held and firmly bound unto any and all persons who perform labor upon or bestow skill or other necessary services on, or furnish materials or lease equipment to be used or consumed in, or furnish appliances, teams, or power contributing to the work described in [the general contract between the owner and Keller], a copy of which contract is or may be attached hereto, and is hereby referred to, in the sum of’ $16.5 million. The bond further stated: “Now, Therefore, the Condition of This Obligation Is Such, That if the Principal shall pay, or cause to be paid in full, the claims of all persons performing labor upon or bestowing skill or other necessary services on, or furnishing materials or leasing equipment to be used or consumed in or furnishing appliances, teams or power contributing to such work, then this obligation shall be void; otherwise to remain in [888]*888full force and effect.” In the final provision relevant here, the bond stated: “No suit, action or proceeding may be maintained on this bond unless the person claiming hereunder shall previously have either, recorded a mechanic’s lien claim pursuant to Title 15, Works of Improvement, of the Civil Code of the State of California or given notice to the Surety on this bond before the expiration of the time prescribed in said statute for recording a lien.” The bond was duly executed by the authorized agents of Keller and Safeco, and it was duly recorded.
After substantial work had been completed on the project, the owner stopped making payments to Keller, apparently as a result of the owner’s insolvency. Keller then declined to pay the subcontractors, which recorded mechanic’s liens and filed separate actions against Safeco seeking recovery under the payment bond. The actions were deemed related and were assigned to the same judge for all purposes. Three of the actions were resolved by summary judgment, the fourth by trial to the court. In each action, the trial court granted judgment for the subcontractors and against Safeco. Safeco appealed from each judgment. After consolidating the appeals, the Court of Appeal affirmed each judgment against Safeco.6
II. Analysis and Resolution
Safeco argues here, as it did in the trial court and in the Court of Appeal, that its obligation under the payment bond never matured because the liability of a surety on a private works payment bond is no greater than that of its principal, and Keller, the principal on the payment bond issued by Safeco, never incurred any obligation to pay the subcontractors for their work because a condition precedent to Keller’s contractual obligation to pay the subcontractors—that Keller receive payment from the owner for the subcontractors’ work—was never satisfied. Safeco’s argument thus assumes the validity of the pay if paid provisions in the subcontracts, under which payment from the owner to Keller was a condition precedent to Keller’s obligation to pay the subcontractors. As will appear, we conclude that the assumption is false.
Our state Constitution provides: “Mechanics, persons furnishing materials, artisans, and laborers of every class, shall have a lien upon the property upon which they have bestowed labor or furnished material for the [889]*889value of such labor done and material furnished; and the Legislature shall provide, by law, for the speedy and efficient enforcement of such liens.” (Cal. Const., art. XIV, § 3.) As this court has said, “The mechanic’s lien is the only creditors’ remedy stemming from constitutional command and our courts ‘have uniformly classified the mechanics’ lien laws as remedial legislation, to be liberally construed for the protection of laborers and materialmen.’ [Citation.]” (Hutnick v. United States Fidelity & Guaranty Co. (1988) 47 Cal.3d 456, 462 [253 Cal.Rptr. 236, 763 P.2d 1326].) “[S]tate policy strongly supports the preservation of laws which give the laborer and materialman security for their claims.” (Connolly Development, Inc. v. Superior Court (1976) 17 Cal.3d 803, 827 [132 Cal.Rptr. 477, 553 P.2d 637].)
By law, a subcontractor may not waive its mechanic’s lien rights except under certain specified circumstances. Subdivision (a) of Civil Code section 3262 provides: “Neither the owner nor original contractor by any term of their contract, or otherwise, shall waive, affect, or impair the claims and liens of other persons whether with or without notice except by their written consent, and any term of the contract to that effect shall be null and void. Any written consent given by any claimant pursuant to this subdivision shall be null, void, and unenforceable unless and until the claimant executes and delivers a waiver and release. Such a waiver and release shall be binding and effective to release the owner, construction lender, and surety on a payment bond from claims and liens only if the waiver and release follows substantially one of the forms set forth in this section and is signed by the claimant or his or her authorized agent, and, in the case of a conditional release, there is evidence of payment to the claimant. Evidence of payment may be by the claimant’s endorsement on a single or joint payee check which has been paid by the bank upon which it was drawn or by written acknowledgment of payment given by the claimant.”
Subdivision (d) of Civil Code section 3262 provides that a waiver and release of mechanic’s lien rights “shall be null, void and unenforceable unless it follows substantially the following forms in the following circumstances: . . . .” The subdivision then lists the text of four lien waivers: (1) a conditional waiver and release upon progress payment; (2) an unconditional waiver and release upon progress payment; (3) a conditional waiver and release upon final payment; and (4) an unconditional waiver and release upon final payment. Thus, under our mechanic’s lien law, waiver and release of mechanic’s lien rights is permitted only in conjunction with payment, or a promise of payment, and a conditional release is effective only if the claimant is actually paid. (See Cal. Mechanics’ Liens and Other Remedies (Cont.Ed.Bar 1988) § 4.21, p. 200.)
Safeco argues that a pay if paid provision in a construction subcontract does not violate Civil Code section 3262’s anti-waiver provisions [890]*890because, under Civil Code section 3140 (limiting a subcontractor’s recovery on a mechanic’s lien claim to “such amount as may be due him according to the terms of his contract”), mechanic’s lien remedies are available only to subcontractors whose payment rights have vested under the terms of their contracts. Absent a contractual right to payment, a subcontractor has no mechanic’s lien remedy to enforce. In Safeco’s view, a mechanic’s lien is merely one remedy that is granted to subcontractors to enforce a contractual right to payment. Absent such a contractual right, there can be no remedy. Thus, according to Safeco, the subcontractors have not waived their mechanic’s lien remedy. Rather, they never acquired the contractual payment right that is a necessary precondition to the enforcement of any mechanic’s lien remedy.
Strictly speaking, Safeco is correct. A pay if paid provision in a construction agreement does not take the form of a waiver of mechanic’s lien rights. Yet “[t]he law respects form less than substance” (Civ. Code, § 3528), and a pay if paid provision is in substance a waiver of mechanic’s lien rights because it has the same practical effect as an express waiver of those rights.
The New York high court put it this way: “As the owner here has become insolvent, the owner may never make another contract payment to the general contractor. Because the lack of future payments by the owner is virtually certain, [the plaintiff subcontractor’s] right to receive payment has been indefinitely postponed, and plaintiff has effectively waived its right to enforce its mechanics’ liens. The waiver has occurred by operation of the pay-when-paid provision because mechanics’ liens may not be enforced until a debt becomes due and payable.” (West-Fair Elec. v. Aetna Cas. & Sur. Co., supra, 87 N.Y.2d at p. 158 [638 N.Y.S.2d at p. 398, 661 N.E.2d at p. 971].)
We may agree with Safeco that a pay if paid provision is not precisely a waiver of mechanic’s lien rights and yet conclude that a pay if paid provision is void because it violates the public policy that underlies the anti-waiver provisions of the mechanic’s lien laws. The Legislature’s carefully articulated anti-waiver scheme would amount to little if parties to construction contracts could circumvent it by means of pay if paid provisions having effects indistinguishable from waivers prohibited under Civil Code section 3262.
Safeco advances several arguments against the conclusion that pay if paid provisions in construction subcontracts are void as against public policy. We consider these arguments in turn.
Safeco argues that it is established law in this state that pay if paid provisions in construction subcontracts are valid and enforceable. The authority Safeco cites for this proposition is Michel & Pfeffer v. Oceanside Properties, Inc. (1976) 61 Cal.App.3d 433 [132 Cal.Rptr. 179], which we find to [891]*891be distinguishable. There, under a modification of the subcontractor’s agreement with the general contractor, the subcontractor agreed to accept as payment for the final 15 percent of the contract price a pro rata interest in funds the general contractor would receive from either a secured promissory note or the proceeds of an intended sale of the project property. The Court of Appeal concluded that under this agreement the subcontractor had no right to the final payment until the general contractor received funds from one of the two designated sources. (Id. at p. 441.) The Court of Appeal further reasoned that because the general contractor had not received funds from either source, the general contractor was not in default on its agreement, and the subcontractor therefore could not yet recover its final payment either by proceeding against the surety on a payment bond or by foreclosing a mechanic’s lien on the project property. (Ibid.)
Although the agreement provision at issue in Michel & Pfeffer v. Oceanside Properties, Inc., supra, 61 Cal.App.3d 433, raises some of the same concerns as a pay if paid provision, it was not such a provision. Nothing in the Court of Appeal’s opinion suggests that the final payment to the subcontractor could be delayed indefinitely, nor did the Court of Appeal consider whether, if so, the provision there at issue violated the public policy underlying the anti-waiver provisions of Civil Code section 3262. Accordingly, we do not find the Court of Appeal’s decision in that case relevant or helpful in deciding the issue presented here, and Safeco’s reliance upon it is misplaced.
In defense of pay if paid provisions, Safeco argues strenuously that the public policy against waivers of mechanic’s lien rights is not the only public policy at issue, and that this court should consider also the fundamental public policy served by freedom of contract. Safeco argues that pay if paid provisions should be held valid because they permit general contractors and subcontractors to allocate the risk of owner insolvency in a mutually agreeable manner.
Safeco’s argument assumes that the sole purpose and effect of a pay if paid provision in a subcontract is to allocate the risk of owner insolvency. But the provisions at issue here were not so limited. As noted above, the pay if paid provision in each subcontract made the owner’s payment to Keller a condition precedent of Keller’s obligation to pay the subcontractor “regardless of the reason for Owner’s nonpayment, whether attributable to the fault of the Owner, Contractor, Subcontractor or due to any other cause.”
In any event, we find Safeco’s “freedom of contract” argument unpersuasive in this context. By closely and carefully circumscribing subcontractors’ [892]*892freedom to waive mechanic’s lien rights, and by forbidding waivers not accompanied by payment, or a promise of payment, the Legislature has already determined that there are policy considerations here that override the value of freedom of contract. We merely recognize and enforce that legislative policy determination.
Moreover, it is doubtful that enforcement of the pay if paid provisions at issue in this case would be fully consistent with the intent of the contracting parties. All but one of the subcontracts at issue here contained an addendum purporting to reserve mechanic’s lien rights and remedies. This addendum is evidence of a contractual intent to allow the subcontractors, in the event of the owner’s default in its payment obligations to the general contractor, to obtain payment for work performed by foreclosing mechanic’s liens on the project property. Yet the pay if paid provision makes this impossible, because the amount due and unpaid under the subcontract is the measure of the subcontractors’ mechanic’s liens. Had the subcontractors understood that this reservation of rights was illusory (because under Civil Code section 3140 their recovery on their mechanic’s lien claims would be limited to amounts due under their subcontracts), they might never have entered into the subcontracts. In short, the allocation of risks and remedies contemplated by the subcontracts appears to be a statutory impossibility, and this lawsuit must necessarily determine which contracting party will have its expectations frustrated.
In this court, in its consolidated reply brief on the merits, Safeco for the first time has taken the position that “it is not necessary for any party improving real property to establish the validity of a contract claim in order to have a mechanic’s lien” and that “[t]he reference in the mechanic’s lien laws to the contract price merely is used to set a limit on the amount of a mechanic’s lien, rather than to create a condition precedent to the validity of the lien.” Safeco appears to argue, in other words, that pay if paid provisions do not preclude the assertion of mechanic’s lien claims, and therefore are not against public policy. Safeco cites no authority for this assertion, which is inconsistent with the position Safeco took initially in this court in its brief on the merits. We reject this new position as being contrary to the language of Civil Code section 3140, which provides that a subcontractor’s mechanic’s lien claim is for “only such amount as may be due him according to the terms of his contract” (italics added). This statutory language does not merely refer to the contract price; rather, it refers to and incorporates all of “the terms of [the] contract” to determine the amount that is “due” under the subcontract, making this contractually due amount the measure of the subcontractor’s mechanic’s lien claim.
Safeco’s argument fails in another respect as well. Were we to adopt Safeco’s proposed construction of Civil Code section 3140, and thereby to [893]*893conclude that the pay if paid provision merely bars the subcontractors’ contract claims against Keller, while fully preserving their mechanic’s lien claims (and thus not violating the public policy underlying the anti-waiver provisions of the mechanic’s lien laws), this conclusion would not assist either Safeco or Keller because both are obligated by the payment bond to pay all valid mechanic’s lien claims. If the subcontractors have valid mechanic’s lien claims, as posited by Safeco’s argument, then those claims are necessarily enforceable against the payment bond.
Seeking to escape from this inexorable logic, Safeco argues that it incurred no liability on the bond because a surety’s obligation on a payment bond is only to answer for the default of its principal. As Safeco observes, the very definition of a surety is “one who promises to answer for the debt, default, or miscarriage of another, or hypothecates property as security therefor.” (Civ. Code, § 2787.) Absent a default by the principal, the surety incurs no liability. In this connection, Safeco relies also on Civil Code section 2809, which states that a surety’s obligation “must be neither larger in amount nor in other respects more burdensome than that of the principal.” Safeco argues that its obligation under the payment bond is simply to answer for any default by Keller in the performance of its contractual payment obligations to the subcontractors. Because payment by the owner was a condition precedent to Keller’s contractual payment obligations to the subcontractors, and because that condition was not met, Keller was not in default of any contractual payment obligation to the subcontractors. Therefore, reasons Safeco, as a surety it incurred no liability on the payment bond.
The fallacy of this reasoning (apart from its erroneous assumption that the pay if paid provisions are valid and enforceable and its reliance on a strained construction of Civil Code section 3140) is that it considers only Keller’s contractual liability under the subcontracts, while ignoring Keller’s separate and independent liability as principal and co-obligor on the payment bond. Keller’s contract with the owner required it to obtain a payment bond, the purpose of which is “to create an additional fund or security for the satisfaction of lien claimants [citations], and also to limit the owner’s liability to the contract price [citation] . . . .” (Sudden Lumber Co. v. Singer (1930) 103 Cal.App. 386, 390 [284 P. 477]; accord, Simpson v. Bergmann (1932) 125 Cal.App. 1, 12 [13 P.2d 531].) The payment bond at issue here refers to Keller’s contract with the owner, but makes no mention of the subcontracts. The operative language of the bond states that “[Keller], as Principal, and [Safeco], as Surety, are held and firmly bound unto any and all persons who perform labor upon ... the work described in” the general contract.
Keller’s obligation under the bond is measured by the terms of the bond and the statutes referenced in the bond. (Southern Heaters Corp. v. N. Y. Cas. [894]*894Co. (1953) 120 Cal.App.2d 377, 379 [260 P.2d 1048].) Under the bond, Keller assumed an obligation to pay the lien claims of any and all persons, including subcontractors, that performed work on the project identified in the general contract. Liability on the bond thus extends not only to those with whom Keller has entered into subcontracts, but to “everyone who has a right to claim a lien” (Myers v. Alta Construction Co. (1951) 37 Cal.2d 739, 743 [235 P.2d 1]; see also Hammond Lumber Co. v. Willis (1915) 171 Cal. 565, 568-569 [153 P. 947]; Union Asphalt, Inc. v. Planet Ins. Co. (1994) 21 Cal.App.4th 1762 [27 Cal.Rptr.2d 371]). And the liability on the bond to pay mechanic’s lien claims fell equally on Keller as principal and Safeco as surety. (See, e.g., Code Civ. Proc., § 996.410, subd. (a) [stating that “[t]he beneficiary may enforce the liability on a bond against both the principal and sureties”].) Thus, the default for which Safeco promised to answer was Keller’s default under the bond and not Keller’s default under the subcontracts.
We find nothing to the contrary in Flickinger v. Swedlow Engineering Co. (1955) 45 Cal.2d 388 [289 P.2d 214] (Flickinger) or in Lewis & Queen v. N. M. Ball Sons (1957) 48 Cal.2d 141 [308 P.2d 713] (Lewis).
Flickinger, supra, 45 Cal.2d 388, concerned a subcontract for work on a state highway project. The subcontractor was a licensed contractor who later assigned the benefits of the contract to a partnership composed of himself and another licensed contractor. After the work was completed, the general contractor sued both the partnership and the individual partners, who responded with a cross-complaint against the general contractor. The trial court entered judgment that neither party take anything on their opposing claims, and this judgment became final. The original subcontractor then sued the general contractor and its payment bond sureties, arguing a legal theory of recovery different from the one he had unsuccessfully urged by cross-complaint in the earlier action. The trial court granted judgment for the subcontractor, and the general contractor appealed. This court reversed, holding that the subcontractor could and should have asserted any claim arising from the subcontract in the earlier action, and that the claim was therefore barred.
Rejecting the subcontractor’s argument that this bar was not good against the payment bond surety, who was not a party to the earlier action, this court stated: “[A]ny right which plaintiff might have had to recover upon the bond was necessarily dependent upon plaintiff’s right to recover upon his contract with [the general contractor]. While he had the option to file a cross-complaint on the bond and thereby bring in the surety as a party in the prior action [citation], he was clearly compelled to assert by way of counterclaim, [895]*895in said prior action, any right which he had against [the general contractor] under the contract which was the basis of [the general contractor]’s prior action. [Citation.] Having omitted to assert directly in that action his alleged rights under the contract, but having elected to assert his alleged rights upon an alleged acount stated with the resulting adverse final judgment on the merits, plaintiff is now barred from relitigating his alleged rights under the contract as the basis for an action against [the general contractor] as the principal on the bond. And as such defense to this action is available to [the general contractor] as the principal, it is likewise available to . . . the surety on the bond.” (Flickinger, supra, 45 Cal.2d 388, 394.)
In Lewis, supra, 48 Cal.2d 141, a state road construction contract prohibited the general contractor from subcontracting more than 50 percent of the work. Attempting to circumvent this requirement, the general contractor purported to enter into separate equipment rental and subcontract agreements with a partnership that did not have a contractor’s license. Later, the partnership sued the general contractor and its payment bond sureties for money due under the rental agreements. The trial court denied recovery. On the partnership’s appeal, this court affirmed, relying on Business and Professions Code section 7031, which bars unlicensed contractors from bringing any action for compensation for work requiring a license. After concluding that the partnership could not recover from the general contractor because the rental agreement was a sham and the partnership was actually seeking recovery for work requiring a license, this court considered the partnership’s claim against the payment bond sureties. This court noted that Business and Professions Code section 7031 bars not only an unlicensed contractor’s action for breach of contract, but also its action to foreclose a mechanic’s lien. This court then stated: “The obligation of the sureties on defendant’s bonds was not to pay for labor merely by virtue of the fact that it had been expended on [the public work]. It was an obligation to pay only if plaintiff established, without reference to the bond, a legal and valid claim for compensation.” (Lewis, supra, 48 Cal.2d 141, 155, citing, inter alia, Flickinger, supra, 45 Cal.2d 388, 393-394.)
Flickinger, supra, 45 Cal.2d 388, and Lewis, supra, 48 Cal.2d 141, both stand for the proposition that a claimant on a labor and material payment bond must “establish[], without reference to the bond, a legal and valid claim for compensation” (id. at p. 155). That proposition is in no way inconsistent with our conclusion here that the payment bond obligates Keller to pay the subcontractors’ valid mechanic’s lien claims, because a mechanic’s lien claim is “a legal and valid claim for compensation.” Where the bond is conditioned, as is the Safeco bond at issue here, on the payment of mechanic’s lien claims on a particular private work, Flickinger and Lewis [896]*896require only that a claimant on the bond establish, without reference to the terms of the bond, a legal and valid mechanic’s lien claim for that project. Neither Flickinger nor Lewis, nor any other case that has come to our attention, has addressed Safeco’s hypothesized situation, in which a subcontractor is able to establish, without reference to the terms of a payment bond, a legal and valid mechanic’s lien claim but not a legal and valid claim for breach of contract.
One more appellate decision requires our attention. In Kalfountzos v. Hartford Fire Ins. Co. (1995) 37 Cal.App.4th 1655 [44 Cal.Rptr.2d 714] (Kalfountzos), the Court of Appeal applied the rule of law established in Flickinger, supra, 45 Cal.2d 388, and Lewis, supra, 48 Cal.2d 141. In Kalfountzos, the issue presented was whether a surety on a public works payment bond could assert the defenses and setoffs of a principal whose corporate powers had been suspended for nonpayment of franchise fees. Concluding that the surety could assert the defenses of its principal, the Court of Appeal stated: “The surety must pay on the bond only if the claimant establishes, without reference to the bond, a legal obligation on the part of the principal to pay." (Kalfountzos, supra, 37 Cal.App.4th 1655, 1659, italics added.) The italicized language goes beyond the rule of law declared in Flickinger, supra, 45 Cal.2d 388, and Lewis, supra, 48 Cal.2d 141, on which the Court of Appeal purported to rely, because it requires the claimant on the bond to establish, without reference to the bond, a claim for compensation that is not only legal and valid, but also one that the bond principal would otherwise be obligated to pay. To the extent that Kalfountzos implies that the principal on a payment bond incurs no liability on the bond unless it has a separate payment obligation, contractual or otherwise, the statement is incorrect and is hereby disapproved. When a general contractor executes a statutory labor and material payment bond as principal, the obligation on the bond is not limited to the subcontractors and material suppliers with which the general contractor has executed valid contracts, but extends also to lower tier subcontractors and material suppliers with which the general contractor has no privity of contract, and to which the general contractor owes no payment obligation apart from the bond, provided only that they have valid lien claims for that project. (Myers v. Alta Construction Co., supra, 37 Cal.2d 739, 743; Hammond Lumber Co. v. Willis, supra, 171 Cal. 565, 568-569; Union Asphalt, Inc. v. Planet Ins. Co., supra, 21 Cal.App.4th 1762.)
III. Conclusion
Having concluded that a general contractor’s liability to a subcontractor for work performed may not be made contingent on the owner’s payment to [897]*897the general contractor, we conclude that Keller was liable to the subcontractors under their subcontracts for the work they performed and that Safeco, as Keller’s surety, was likewise liable on the payment bond.
The judgment of the Court of Appeal is affirmed, and the matter is remanded for further proceedings consistent with this opinion.
George, C. J., Werdegar, J., and Brown, J., concurred.