Pete Vicari, General Contractor, Inc. v. United States

53 Fed. Cl. 357, 2002 U.S. Claims LEXIS 216, 2002 WL 1969644
CourtUnited States Court of Federal Claims
DecidedAugust 26, 2002
DocketNo. 99-988C
StatusPublished
Cited by2 cases

This text of 53 Fed. Cl. 357 (Pete Vicari, General Contractor, Inc. v. United States) is published on Counsel Stack Legal Research, covering United States Court of Federal Claims primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook
Pete Vicari, General Contractor, Inc. v. United States, 53 Fed. Cl. 357, 2002 U.S. Claims LEXIS 216, 2002 WL 1969644 (uscfc 2002).

Opinion

OPINION

MILLER, Judge.

Having changed attorneys, this is defendant’s second effort to dispatch this case on summary judgment. See Pete Vicari, Gen. Contractor, Inc. v. United States, 47 Fed.Cl. 353 (2000). After the court granted summary judgment on three of the five counts in plaintiffs original complaint brought under the Contract Disputes Act of 1978, 41 U.S.C. §§ 601-613 (2000), plaintiff filed an amended complaint adding additional claims for delays, extended indirect costs, certain direct costs, and the return of liquidated damages withheld by the Government. At issue is whether plaintiff is entitled to (1) an extension of the contract for alleged delays caused by the Government; (2) recovery of its extended indirect costs caused by the delays and other modifications to the contract; (3) compensation for work that the Government claims to have performed itself; and (4) return of liquidated damages withheld by the Government. Argument is deemed unnecessary.

FACTS

The facts recited with respect to each claim are undisputed, unless otherwise noted. On March 13, 1997, Pete Vicari, General Contractor, Inc. (“plaintiff’), and the United States Coast Guard (the “USCG”) entered into Contract No. DTCG47-97-C-3EFK 01 (the “contract”) for road resurfacing and the construction of New Family Housing, Unaccompanied Personnel Housing (“UPH”), and a fire lane at the USCG station at Grand Isle, Louisiana. The contract was a firm fixed-price contract. Under the contract the USCG agreed to pay plaintiff $3,850,335.00 [360]*360for the work, which plaintiff agreed to finish by April 8, 1998. A Notice To Proceed was issued on April 9, 1997.

1. Glued-laminated beam submittals

The contract specifications required plaintiff to submit shop drawings for “glued-laminated” beams to be used in the project.1 The specifications defined the drawings as

[djesign analysis and calculations of structural laminated members, showing design criteria used to accomplish the applicable analysis. Drawings of structural laminated members indicating materials, shop fabrication, and field erection details; including methods of fastening.

The specifications charged that the USCG generally would review and return routine submittals within two weeks.

On September 9, 1997, plaintiff submitted preliminary drawings for the glued-laminated beams, Submittal No. 41, to Graves and Carlos Architects, P.C. (“G & C”), the USCG’s architect/engineer for the project. The drawings were created by plaintiffs supplier, Structural Woods Systems (“Structural Woods”), which plaintiff hired to fabricate the glued-laminated beams. G & C received Submittal No. 41 two days later, on September 11,1997.

G & C returned Submittal No. 41 to plaintiff on October 3, 1997, stamped “Rejected-Revise and Resubmit.” The stated basis for the rejection was that Submittal No. 41 was incomplete. Submittal No. 41 was marked “FOR INFORMATION ONLY; NOT FOR FABRICATION.” Failing to bear the seal or stamp of a professional engineer, Submittal No. 41 instead was marked “FINAL ENGINEERING NOT COMPLETE AT THIS TIME. LOUISIANA [Professional Engineer] SEAL WILL BE ON ‘FINAL’ PRINTS.”

Plaintiff resubmitted the glued-laminated beam drawings to G & C on October 16, 1997, as Submittal No. 54. As with Submittal No. 41, Submittal No. 54 contained the legend “FOR INFORMATION ONLY; NOT FOR FABRICATION,” and “FINAL ENGINEERING NOT COMPLETE AT THIS TIME. LOUISIANA [Professional Engineer] SEAL WILL BE ON ‘FINAL’ PRINTS.” G & C reviewed and approved Submittal No. 54 and returned it on October 23, 1997, to plaintiff with corrections as noted.

On October 24, 1997, Structural Woods verbally contacted G & C to seek additional information about the approved submittal. On November 10, 1997, Structural Woods requested a deviation to one of the connections on the submittal. Plaintiff had no knowledge of these communications between Structural Woods and G & C until sometime after November 10, when Structural Woods notified plaintiff that it had requested information from G & C. On December 3, 1997, plaintiff submitted a formal request to G & C seeking the same information requested by Structural Woods. G & C responded to plaintiffs request on December 11,1997.

On May 11, 1998, plaintiff requested additional compensation and an equitable adjustment for 82 days of delay, which represents the time period from September 21,1997, the date on which plaintiff alleges that G & C should have approved Submittal No. 41, to December 11, 1997, when fabrication of the glued-laminated beams actually began.2 In addition to the Government’s failure to approve Submittal No. 41, plaintiffs letter charged that “there were numerous questions left unanswered” in G & C’s October 23, 1997 approval that contributed to the delay. Plaintiff also maintained that G & C’s and Structural Woods’ corresponding without plaintiffs knowledge also delayed the start of fabrication.

On August 11,1998, the contracting officer unilaterally issued Modification No. 0007 extending the contract completion date by 17 days to compensate plaintiff for G & C’s late [361]*361return of Submittal No. 41. On September 11, 1998, plaintiff submitted a claim to the contracting officer demanding the full 82-day extension and compensation in the amount of $116,729.01 for the delay. The contracting officer denied this claim on December 11, 1998.

2. UPH design deficiencies

During the course of performance, plaintiff claimed reimbursement from the USCG for delays and additional work resulting from alleged deficiencies in structural framing designs issued by G & C with respect to the UPH barracks (the “UPH design deficiencies”). See generally Pete Vicari, 47 Fed.Cl. at 356. Plaintiff requested modifications to the contract to increase the contract price for the cost of these delays and additional work. The USCG, plaintiff, and G & C negotiated and executed an Agreement of Compromise, Settlement and Release (the “Settlement Agreement”), dated January 5, 1999, limited to “structural modifications and associated work on the UPH Barracks.” The Settlement Agreement compensated plaintiff in the amount of $111,410.74 and granted an extension of time, from January 18,1999, to March 31, 1999, to complete the project. The Settlement Agreement recited that it was in full satisfaction of plaintiffs claims against G & C and the USCG for both delays and design deficiencies. In consideration for plaintiffs release of its claims regarding the design deficiencies, the USCG gave up its right to assess liquidated damages for delay in completion of the project.

3. Drywall installation

By letter dated June 14, 1999, plaintiff requested an extension of 36 days due to a shortage of drywall. In a prior letter dated May 11, 1999, plaintiff had explained that, absent the UPH design deficiencies, it could have ordered the drywall earlier, thereby presumably avoiding the shortage. On April 3, 2000, the USCG unilaterally issued Modification No. 0016 to the contract, effective June 22, 1999, extending the contract completion date 19 days due to the shortage.

Free access — add to your briefcase to read the full text and ask questions with AI

Related

Cite This Page — Counsel Stack

Bluebook (online)
53 Fed. Cl. 357, 2002 U.S. Claims LEXIS 216, 2002 WL 1969644, Counsel Stack Legal Research, https://law.counselstack.com/opinion/pete-vicari-general-contractor-inc-v-united-states-uscfc-2002.