Southern New England Contracting Co. v. State

345 A.2d 550, 165 Conn. 644, 1974 Conn. LEXIS 1058
CourtSupreme Court of Connecticut
DecidedJanuary 2, 1974
StatusPublished
Cited by64 cases

This text of 345 A.2d 550 (Southern New England Contracting Co. v. State) is published on Counsel Stack Legal Research, covering Supreme Court of Connecticut primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook
Southern New England Contracting Co. v. State, 345 A.2d 550, 165 Conn. 644, 1974 Conn. LEXIS 1058 (Colo. 1974).

Opinion

MacDonald, J.

The plaintiff, The Southern New England Contracting Company, by virtue of a contract dated June 26,1964, with the state of Connecticut, acting therein by and through its commissioner of public works, was engaged as the general contractor for the construction of a new state health department laboratory building on Clinton Street in Hartford. The plaintiff brought an action for damages it claimed to have sustained as a result of certain alleged breaches of that contract by the state and the state, in turn, counterclaimed for liquidated damages for delay in completion of the building. After a trial to the court, the issues were found for the plaintiff, in part, and for the defendant, in part. The defendant has appealed from the judgment rendered and the plaintiff has cross appealed claiming error in the court’s failure to include interest on certain damages awarded to the plaintiff.

The defendant, in its appeal, has assigned as error the refusal of the trial court to find the facts set forth in forty paragraphs of its draft finding, the inclusion in the finding of ten paragraphs alleged either to be contrary to the evidence or in language *646 of doubtful meaning, or both, and of twenty-five “conclusions” claimed to be unsupported by subordinate facts and tbe law. It also assigned error in the overruling of twenty-seven claims of law. The plaintiff has responded by assigning as error in the defendant’s appeal the inclusion of thirty-one paragraphs of the finding alleged to have been found without evidence or in language of doubtful meaning, the trial court’s failure to find facts set forth in two paragraphs of the plaintiff’s draft counter-finding, and the reaching of one conclusion claimed to be unsupported by subordinate facts. We hardly need to point out how strongly this eourt disfavors such an unwieldy method of presenting an appeal. Pawlinski v. Allstate Ins. Co., 165 Conn. 1, 3, 327 A.2d 583. Furthermore, although certain additions and corrections to the finding are technically warranted, 1 as is likely to be the case in any *647 litigation as factually complex as the one at bar, their effect is largely cumulative and is not dispositive of the issues on this appeal.

The defendant, to some extent, has simplified and clarified the basis of its appeal by abandoning a number of its claims and by focusing its appeal primarily upon the following three issues: (1) the responsibility for two separate periods of delay in the completion of the building, (2) the computation of damages for the delay, and (3) the question of whether the installation of certain temperature control wiring was extra work for which the plaintiff was entitled to additional compensation. For purposes of clarity, the salient facts, as determined by the finding as corrected, will be considered in relation to these issues. A review of the general facts, however, must precede any discussion of these specific issues.

The construction project began on July 8, 1964, and the contract called for it to be completed 360 *648 working days later on January 12,1966. Subsequent extensions of time granted to the plaintiff by the state increased the allotted construction time by ninety-seven working days, but completion of the project nonetheless required 171 working days more than were allowed. The plaintiff subsequently sued to recover: (1) the unpaid balance on the contract, (2) excessive deductions from the contract price for the state’s deletion of certain equipment, (3) the cost of labor and materials for the installation of certain electrical temperature control wiring .allegedly not included in the contract, and (4) damages for the delay in completion of the contract. The judgment rendered on the last two claims has generated the issues on this appeal.

In letting this project in 1964, the state employed the “pre-filed” bid system in that bids of the electrical, plumbing and heating subcontractors were received, opened and accepted prior to the submission of bids by interested general contractors. Each general contractor bidding was advised of the identity and contract price of the major subcontractors already accepted by the state and was obligated to incorporate the subcontractors’ price into his own bid. The bidding procedure took place within the span of one month. The plans and specifications were made available on May 14,1964, the bids of the major subcontractors opened on June 3, and the proposals of the general contractors opened on June 10. The plaintiff was selected .as the general contractor and entered into the required subcontracts with the selected subcontractors.

The contract provided that certain laboratory equipment would be procured and installed by the state and was not a part of the contract work. The *649 plaintiff was required, however, to install electrical and plumbing lines in the concrete floors, to which this not-in-eontract (hereinafter NIC) equipment would be connected by the state at a later date, and which would service such items as the electric current, hot and cold water, distilled water, compressed air, gas, and sanitary waste. The terms of the contract specifically advised the general contractor that the state would provide the shop drawings showing the intended location of this equipment so that the plaintiff could locate the required plumbing and wiring “sleeves” before pouring the concrete floors. The drawings, however, were not in existence at the time the contract was signed in June, 1964, were not available on February 3, 1965, at which time the trial court found the plaintiff was ready to pour the concrete floors, and were not actually prepared and submitted to the plaintiff until April 30, 1965, although the plaintiff had made a number of requests for the drawings, beginning as early as September 10, 1964. The trial court rejected the state’s claim that the plaintiff would not have been ready to pour the concrete floors even if the NIC drawings had been available and concluded that the state’s failure to provide the drawings caused a delay of three and one-half months.

The so-called temperature control wiring in this building provided the interconnection between fans, switches, and other devices and was essential to the synchronized operation of the building’s heating ,and air conditioning system. A dispute as to the responsibility for the line voltage (120 volts or higher) portion of this wiring arose after construction began. Both the heating subcontractor and the electrical subcontractor had read their respective divi *650 sions of the state’s specifications (divisions 29 and 30 respectively) to exclude the line voltage temperature control wiring from the work which they were required to do. Installation of the disputed control wiring was necessary for the proper operation of the temperature control system and the plaintiff attempted to resolve the dispute by seeking a change order from the state authorizing the electrical subcontractor to do the wiring at a fair rate of compensation. The state at first agreed to such a change order, but later refused and issued a series of orders to the plaintiff to install the wiring at its own expense.

Free access — add to your briefcase to read the full text and ask questions with AI

Related

Suntech of Connecticut, Inc. v. Lawrence Brunoli, Inc.
72 A.3d 1113 (Connecticut Appellate Court, 2013)
O'Connor v. Larocque
31 A.3d 1 (Supreme Court of Connecticut, 2011)
Bridgeport Harbour Place I, LLC v. Ganim
30 A.3d 703 (Connecticut Appellate Court, 2011)
Shoreline Care v. Jansen Rogan, No. X06-Cv-94-0155982 S (Nov. 15, 2002)
2002 Conn. Super. Ct. 14653 (Connecticut Superior Court, 2002)
M.J. Daly & Sons, Inc. v. City of West Haven
783 A.2d 1138 (Connecticut Appellate Court, 2001)
M.J. Daly Sons v. City of West Haven, No. Cv96-0053211s (Sep. 24, 1999)
1999 Conn. Super. Ct. 12917 (Connecticut Superior Court, 1999)
Greene v. Perry, No. Cv 97 0057091s (Jun. 9, 1999)
1999 Conn. Super. Ct. 6679 (Connecticut Superior Court, 1999)
Fairfax County Redevelopment & Housing Authority v. Worcester Bros.
514 S.E.2d 147 (Supreme Court of Virginia, 1999)
City, Hartford v. Int'l Assoc., Fire., No. Cv-960558850 (Jun. 12, 1997)
1997 Conn. Super. Ct. 6988 (Connecticut Superior Court, 1997)
Rafalowski v. Old County Road, Inc., No. Cv95 0555432s (Mar. 26, 1997)
1997 Conn. Super. Ct. 3057 (Connecticut Superior Court, 1997)
Rafalowski v. Old County Road, Inc.
719 A.2d 84 (Connecticut Superior Court, 1997)
Gilbane Building Co. v. Stamford Towers, No. Cv91 0118788 S (Nov. 18, 1996)
1996 Conn. Super. Ct. 9029 (Connecticut Superior Court, 1996)
Matlack, Inc. v. White Oak Corporation, No. Cv93 052 95 39 (Jan. 25, 1996)
1996 Conn. Super. Ct. 544 (Connecticut Superior Court, 1996)
Weischet v. A. Prete Son Construction Co., Inc., No. 69621 (Oct. 19, 1995)
1995 Conn. Super. Ct. 12038 (Connecticut Superior Court, 1995)
Aircraft Gear Corp. v. Kaman Aerospace Corp.
875 F. Supp. 485 (N.D. Illinois, 1995)
Mohawk Mt. Ski Area v. American Home Assce., No. Cv 056905 (Jan. 30, 1995)
1995 Conn. Super. Ct. 573 (Connecticut Superior Court, 1995)
Standard Sprinkler Corp. v. State, No. Cv 91 0510150 (Jun. 20, 1994)
1994 Conn. Super. Ct. 6771 (Connecticut Superior Court, 1994)
Daum v. Williams, No. Cv87 0293773 S (Feb. 28, 1994)
1994 Conn. Super. Ct. 2040 (Connecticut Superior Court, 1994)
Hansen v. the City of New Haven, No. Cv93 0342979 (Feb. 22, 1994)
1994 Conn. Super. Ct. 1756 (Connecticut Superior Court, 1994)

Cite This Page — Counsel Stack

Bluebook (online)
345 A.2d 550, 165 Conn. 644, 1974 Conn. LEXIS 1058, Counsel Stack Legal Research, https://law.counselstack.com/opinion/southern-new-england-contracting-co-v-state-conn-1974.