Williams, J.
— This appeal involves the financing and construction arrangements for a building which was never built. The Superior Court, in its judgment against the financing company, Continental, Inc., awarded money damages to the owner, a partnership of Robert L. Hyskell and others d/b/a Lynnwood Pacific Industrial Center, for breach of contract and to the contractor, Lincor Contractors, Ltd. for tortious interference with the construction contract. Continental appeals and Lynnwood Pacific cross-appeals. We reverse and remand on the issue of Lynnwood Pacific's damages.
The facts are that Lynnwood Pacific purchased on contract a building site in Lynnwood upon which to construct an office complex. It contracted with Lincor, a general contractor, to design and build the project.
As Lynnwood Pacific had limited assets, Lincor assisted it in obtaining 100 percent financing for the project by contacting Continental, a commercial mortgage lender, for both a construction loan and permanent financing. Based upon Continental's assurance that the construction loan would be made, Lynnwood Pacific borrowed $100,000 from Rainier National Bank to make a balloon payment on the real estate contract. Continental then negotiated, and Lynn-wood Pacific accepted, a commitment for permanent financing of $1.8 million from Union Mutual Life Insurance Company. After reviewing several loan applications from Lynnwood Pacific, the construction budget and contract, and a project appraisal, Continental agreed to provide the construction loan. Lynnwood Pacific then authorized Lincor to begin construction.
Shortly thereafter, Continental told Lynnwood Pacific [320]*320that no funds would be disbursed until Lincor was removed as the general contractor. Lynnwood Pacific discharged Lincor but was unable to find another builder. Continental did not provide the construction money, the Union Mutual commitment expired, and the project dissolved. Litigation which developed among the parties was consolidated for trial.
The principal issue on appeal concerns the method employed by the trial court in assessing the damages sustained by Lynnwood Pacific because of Continental's withholding of the construction loan proceeds, thus effectively terminating the project.
The trial court found that the project could have been completed by April 1979 as contemplated in the construction contract at a cost of $1,996,622, but that to construct the complex after judgment would cost an additional $397,342.70 for increased interest and an additional $282,920.74 for increased construction expenses. The trial court also found that Lynnwood Pacific was entitled to $254,987.79 for lost rent caused by the delay, $40,753.97 for interest paid to Rainier National Bank, $51,722.45 for interest paid to Mr. Petropoulous, the beneficiary of a deed of trust on the property, and $59,750 for loan fees paid to Continental.
These findings were carried into the judgment against Continental on the theory that after judgment Lynnwood Pacific would complete the project. To fix the damages upon what the cost would be to build after judgment with the attendant assessment of the additional interest cost, lost rent and inflation loss is a fundamentally erroneous method of computation leading only to conjecture and surmise. Rather, the following applies:
The purpose of awarding damages for breach of contract is neither to penalize the defendant nor merely to return to the plaintiff that which he has expended in reliance on the contract. It is, rather, to place the plaintiff, as nearly as possible, in the position he would be in had the contract been performed. He is entitled to the [321]*321benefit of his bargain, i.e., whatever net gain he would have made under the contract. Munson v. McGregor, 49 Wash. 276, 94 Pac. 1085 (1908); Herbert v. Hillman, 50 Wash. 83, 96 Pac. 837 (1908); Herrett v. Wershnig, 170 Wash. 417, 16 P. (2d) 608 (1932); Hardinger v. Till, 1 Wn. (2d) 335, 96 P. (2d) 262 (1939); Williston on Contracts, § 1338; McCormick on Damages, § 137.
The plaintiff is not, however, entitled to more than he would have received had the contract been performed. If the defendant, by his breach, relieves the plaintiff of duties under the contract which would have required him to spend money, an amount equal to such expenditures must be deducted from his recovery. Gould v. McCormick, 75 Wash. 61, 134 Pac. 676 (1913); Robbins v. Seattle Peerless Motor Co., 148 Wash. 197, 268 Pac. 594 (1928); Rathke v. Roberts, 33 Wn. (2d) 858, 207 P. (2d) 716 (1949); Restatement, Contracts, §§ 329, 333, 335; McCormick on Damages, § 143.
Platts v. Arney, 50 Wn.2d 42, 46, 309 P.2d 372 (1957).
In measuring Lynnwood Pacific's damages, three additional rules are applicable:
(1) Damages must be proved with reasonable certainty or supported by competent evidence in the record. Iverson v. Marine Bancorporation, 86 Wn.2d 562, 565, 546 P.2d 454 (1976).
(2) Damages for a lender's breach of a contract to loan money are recoverable if they were reasonably in the contemplation of the parties when the contract was made, are the natural and proximate results flowing from the breach, and were proved with reasonable certainty. Larson v. Union Inv. & Loan Co., 168 Wash. 5, 12, 10 P.2d 557 (1932).
(3) In the case of construction contracts, special problems have been encountered in putting the injured party in the pecuniary position he would have enjoyed had the contract been properly performed by the builder. These special problems have led to the creation of special rules for measuring damages in such cases. Eastlake Constr. Co. v. Hess, 102 Wn.2d 30, 39, 686 P.2d 465 (1984).
[322]*322With these precepts in mind, the consequences of Continental's breach are:
Loss of Contemplated Building
Lynnwood Pacific presented no evidence that it would procure another loan, hire another contractor and construct another building.1 Thus, it did not sustain its burden of proof that any increased interest or construction costs would be incurred. Because these costs were neither proven with reasonable certainty nor supported by competent evidence in the record, the trial court erred in awarding damages for these items. See Iverson, at 565.
But, Lynnwood Pacific has suffered a loss. When the contract was made, the parties contemplated that Lynn-wood Pacific would use the loan from Continental to construct the building. As a natural and proximate result of Continental's breach, Lynnwood Pacific could not construct the building. Lynnwood Pacific's equity in the building can be proven with reasonable certainty. See, e.g., findings of fact 5, 63, 42. Thus, Lynnwood Pacific is entitled to an award of damages, see Larson, at 12, measured by its loss of equity, see St. Paul at Chase Corp. v. Manufacturers Life Ins. Co., 262 Md. 192, 278 A.2d 12, 35-37, cert. denied,
Free access — add to your briefcase to read the full text and ask questions with AI
Williams, J.
— This appeal involves the financing and construction arrangements for a building which was never built. The Superior Court, in its judgment against the financing company, Continental, Inc., awarded money damages to the owner, a partnership of Robert L. Hyskell and others d/b/a Lynnwood Pacific Industrial Center, for breach of contract and to the contractor, Lincor Contractors, Ltd. for tortious interference with the construction contract. Continental appeals and Lynnwood Pacific cross-appeals. We reverse and remand on the issue of Lynnwood Pacific's damages.
The facts are that Lynnwood Pacific purchased on contract a building site in Lynnwood upon which to construct an office complex. It contracted with Lincor, a general contractor, to design and build the project.
As Lynnwood Pacific had limited assets, Lincor assisted it in obtaining 100 percent financing for the project by contacting Continental, a commercial mortgage lender, for both a construction loan and permanent financing. Based upon Continental's assurance that the construction loan would be made, Lynnwood Pacific borrowed $100,000 from Rainier National Bank to make a balloon payment on the real estate contract. Continental then negotiated, and Lynn-wood Pacific accepted, a commitment for permanent financing of $1.8 million from Union Mutual Life Insurance Company. After reviewing several loan applications from Lynnwood Pacific, the construction budget and contract, and a project appraisal, Continental agreed to provide the construction loan. Lynnwood Pacific then authorized Lincor to begin construction.
Shortly thereafter, Continental told Lynnwood Pacific [320]*320that no funds would be disbursed until Lincor was removed as the general contractor. Lynnwood Pacific discharged Lincor but was unable to find another builder. Continental did not provide the construction money, the Union Mutual commitment expired, and the project dissolved. Litigation which developed among the parties was consolidated for trial.
The principal issue on appeal concerns the method employed by the trial court in assessing the damages sustained by Lynnwood Pacific because of Continental's withholding of the construction loan proceeds, thus effectively terminating the project.
The trial court found that the project could have been completed by April 1979 as contemplated in the construction contract at a cost of $1,996,622, but that to construct the complex after judgment would cost an additional $397,342.70 for increased interest and an additional $282,920.74 for increased construction expenses. The trial court also found that Lynnwood Pacific was entitled to $254,987.79 for lost rent caused by the delay, $40,753.97 for interest paid to Rainier National Bank, $51,722.45 for interest paid to Mr. Petropoulous, the beneficiary of a deed of trust on the property, and $59,750 for loan fees paid to Continental.
These findings were carried into the judgment against Continental on the theory that after judgment Lynnwood Pacific would complete the project. To fix the damages upon what the cost would be to build after judgment with the attendant assessment of the additional interest cost, lost rent and inflation loss is a fundamentally erroneous method of computation leading only to conjecture and surmise. Rather, the following applies:
The purpose of awarding damages for breach of contract is neither to penalize the defendant nor merely to return to the plaintiff that which he has expended in reliance on the contract. It is, rather, to place the plaintiff, as nearly as possible, in the position he would be in had the contract been performed. He is entitled to the [321]*321benefit of his bargain, i.e., whatever net gain he would have made under the contract. Munson v. McGregor, 49 Wash. 276, 94 Pac. 1085 (1908); Herbert v. Hillman, 50 Wash. 83, 96 Pac. 837 (1908); Herrett v. Wershnig, 170 Wash. 417, 16 P. (2d) 608 (1932); Hardinger v. Till, 1 Wn. (2d) 335, 96 P. (2d) 262 (1939); Williston on Contracts, § 1338; McCormick on Damages, § 137.
The plaintiff is not, however, entitled to more than he would have received had the contract been performed. If the defendant, by his breach, relieves the plaintiff of duties under the contract which would have required him to spend money, an amount equal to such expenditures must be deducted from his recovery. Gould v. McCormick, 75 Wash. 61, 134 Pac. 676 (1913); Robbins v. Seattle Peerless Motor Co., 148 Wash. 197, 268 Pac. 594 (1928); Rathke v. Roberts, 33 Wn. (2d) 858, 207 P. (2d) 716 (1949); Restatement, Contracts, §§ 329, 333, 335; McCormick on Damages, § 143.
Platts v. Arney, 50 Wn.2d 42, 46, 309 P.2d 372 (1957).
In measuring Lynnwood Pacific's damages, three additional rules are applicable:
(1) Damages must be proved with reasonable certainty or supported by competent evidence in the record. Iverson v. Marine Bancorporation, 86 Wn.2d 562, 565, 546 P.2d 454 (1976).
(2) Damages for a lender's breach of a contract to loan money are recoverable if they were reasonably in the contemplation of the parties when the contract was made, are the natural and proximate results flowing from the breach, and were proved with reasonable certainty. Larson v. Union Inv. & Loan Co., 168 Wash. 5, 12, 10 P.2d 557 (1932).
(3) In the case of construction contracts, special problems have been encountered in putting the injured party in the pecuniary position he would have enjoyed had the contract been properly performed by the builder. These special problems have led to the creation of special rules for measuring damages in such cases. Eastlake Constr. Co. v. Hess, 102 Wn.2d 30, 39, 686 P.2d 465 (1984).
[322]*322With these precepts in mind, the consequences of Continental's breach are:
Loss of Contemplated Building
Lynnwood Pacific presented no evidence that it would procure another loan, hire another contractor and construct another building.1 Thus, it did not sustain its burden of proof that any increased interest or construction costs would be incurred. Because these costs were neither proven with reasonable certainty nor supported by competent evidence in the record, the trial court erred in awarding damages for these items. See Iverson, at 565.
But, Lynnwood Pacific has suffered a loss. When the contract was made, the parties contemplated that Lynn-wood Pacific would use the loan from Continental to construct the building. As a natural and proximate result of Continental's breach, Lynnwood Pacific could not construct the building. Lynnwood Pacific's equity in the building can be proven with reasonable certainty. See, e.g., findings of fact 5, 63, 42. Thus, Lynnwood Pacific is entitled to an award of damages, see Larson, at 12, measured by its loss of equity, see St. Paul at Chase Corp. v. Manufacturers Life Ins. Co., 262 Md. 192, 278 A.2d 12, 35-37, cert. denied, 404 U.S. 857 (1971).
Lost Rent
The trial court awarded Lynnwood Pacific lost rent for a period of 30 months, measured from the scheduled date of completion to the date of anticipated completion if Lynn-wood Pacific constructed another building. This was error because Lynnwood Pacific did not prove that another building would be constructed. See Iverson, at 565.
Lynnwood Pacific is, however, entitled to be compensated for not having the rent-generating building from the date of scheduled completion to the date of judgment, i.e., [323]*323a period of 25 months. See Platts, at 46. This is a special problem calling for the use of special rules. See Eastlake Constr. Co., at 39. The trial court found the net monthly rental value to be $8,606.61. Awarding Lynnwood Pacific lost net monthly rental from the scheduled date of completion to the date of judgment when the amount became liquidated and interest commenced to accrue is appropriate. See Sandler v. Lawn-A-Mat Chem. & Equip. Corp., 141 N.J. Super. 437, 358 A.2d 805, 814 (1976).
Under this equity method of computation, the court can find the net gain by deducting from the fair market value of the building on the date of scheduled completion all costs Lynnwood Pacific reasonably would have incurred in achieving the completed building, including the cost of acquiring the land and borrowing money.
Another issue raised by Continental involves the fixing of liability and award of damages to Lincor for tortious interference with the construction contract. Continental contends that its economic interests were being threatened and so its interference was privileged. See Holman v. Coie, 11 Wn. App. 195, 214, 522 P.2d 515, 72 A.L.R.3d 1209, review denied, 84 Wn.2d 1011 (1974), cert. denied, 420 U.S. 984 (1975). The rule is that interference is justified as a matter of law only when the one interfering is exercising an absolute right, equal or superior to the right which is invaded. Topline Equip., Inc. v. Stan Witty Land, Inc., 31 Wn. App. 86, 93, 639 P.2d 825, review denied, 97 Wn.2d 1015 (1982). Continental had no right under its contract with Lynnwood Pacific to require that Lincor be removed from the project. Nor did Continental acquire such a right because the construction contract was terminable at will, so long as neither of the parties had elected to terminate it. Restatement (Second) of Torts § 766, comment g, at 10-11 (1979); see also Island Air, Inc. v. LaBar, 18 Wn. App. 129, 140, 566 P.2d 972 (1977). Continental's interference was not privileged and the damages were properly awarded.
Continental also contends that Lincor's damages should have been limited to the profit it would have made on the [324]*324project. The trial court awarded Lincor the entire amount of compensation it would have received under its contract with Lynnwood Pacific — 6 percent of the project's budgeted cost. This amount should have been reduced by any expenses Lincor saved as a result of Continental's wrongful acts. C. McCormick, Damages § 40, at 146 (1935); Restatement (Second) of Torts § 774A, comment b, at 55 (1979). There is no evidence that Lincor's expenses were reduced by Continental's tortious interference, thus the trial court's computation of Lincor's damages was correct. See Williams v. Fixdahl, 6 Wn. App. 24, 27-28, 491 P.2d 1309 (1971).
We have examined the other issues in Continental's assignments of error and determined that they are insubstantial.
Lynnwood Pacific's cross appeal concerns attorney's fees, one of the contentions being that because the construction loan application, the proposed construction loan agreement, and an application for a permanent loan from Continental all contained attorney's fees provisions, fees should be allowed under RCW 4.84.330. No action was brought to carry out the terms or for the breach of any of these documents. Hence, they create no right to attorney's fees.
Nor are Lynnwood Pacific's attorney's fees consequential damages. Expenses of litigation are not recoverable unless authorized by contractual obligation, statute or a recognized ground of equity. State ex rel. Macri v. Bremerton, 8 Wn.2d 93, 113-14, 111 P.2d 612 (1941).
Finally, Lynnwood Pacific contends Continental is liable for the attorney's fees it incurred in defending against a lien foreclosure suit Lincor brought for its engineering, architectural and development fees. The partnership was primarily liable to Lincor for these charges and should have paid them. The cost of resisting paying an honest debt cannot be passed on.
In view of all the facts and circumstances, we feel that the fairest disposition we can make of this appeal is to remand the cause to the Superior Court for Snohomish County to reopen for evidence as necessary and to redeter[325]*325mine Lynnwood Pacific's damages. In all other respects, the judgment is affirmed. Neither party will recover costs in this court.
Scholfield, J., concurs.