University Commons-Urbana, Ltd. v. Universal Constructors Inc.

304 F.3d 1331, 2002 WL 31042267
CourtCourt of Appeals for the Eleventh Circuit
DecidedSeptember 13, 2002
DocketNo. 01-11864
StatusPublished
Cited by9 cases

This text of 304 F.3d 1331 (University Commons-Urbana, Ltd. v. Universal Constructors Inc.) is published on Counsel Stack Legal Research, covering Court of Appeals for the Eleventh Circuit primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook
University Commons-Urbana, Ltd. v. Universal Constructors Inc., 304 F.3d 1331, 2002 WL 31042267 (11th Cir. 2002).

Opinion

TJOFLAT, Circuit Judge:

In this appeal, Universal Constructors, Inc. (“Universal”) and Reliance Insurance Company (“Reliance”) challenge a district court order confirming an arbitration award entered in favor of University Commons-Urbana, Ltd. (“University Commons”) and Capstone Development Corporation (“Capstone Development”). One of the grounds of appellants’ challenge is that a member of the arbitration panel was not impartial. The district court rejected this ground on its face, without holding an evidentiary hearing. We conclude that appellants’ allegations of partiality are sufficient to warrant an evidentiary hearing. We therefore vacate the award and remand the case so that an evidentiary hearing may be held and findings of fact and conclusions of law may be made concerning the issue.

I.

University Commons is an Illinois-based limited partnership formed by Capstone Development, a Birmingham-based developer that specializes in student-oriented apartment projects for colleges and universities throughout the United States. Some of Capstone’s projects are developed “on campus” in conjunction with colleges and universities, while others are developed “off campus” through a limited partnership. University Commons was just such a partnership, formed to develop an off-campus apartment project (the “Project”) near the University of Illinois, in Urbana.

In September 1997, University Commons contracted with Universal to build these apartments. Specifically, the contract called for Universal to erect 132 four-bedroom and 108 two-bedroom student apartment units, a club house, a swimming pool, a maintenance building, and a duplex. Reliance acted as Universal’s surety and issued a $13,218,664 performance bond guaranteeing Universal’s performance of the Project.

The Project was scheduled for completion in August 1998. Universal did not meet this deadline, however. On April 1, 1999, with the pool unfinished and landscaping work still to be done, Capstone Development sent Universal a notice terminating their contract on the ground that Universal’s failure to complete the job on time constituted a material breach. Later that month, Capstone Development hired Capstone Building Corporation (“Capstone Building”) to complete the job. Capstone [1334]*1334Building completed the project by July 31, 1999.

On June 14, 1999, University Commons filed a Demand for Arbitration with the American Arbitration Association (“AAA”), alleging breach of contract against Universal. University Commons sought $3,649,669.98 in damages from Reliance under the Performance Bond, including $286,899 for deductive change orders, $555,285.34 for the cost of repairing, replacing, or completing Universal’s work, and $3,307,485.64 for the damage allegedly caused by Universal’s failure to complete the project on schedule. The bulk of this $3,307,485.64 that Universal sought as compensation for the delay was lost rental income, specifically $1,099,464 for the 1998-1999 school year and $1,989,700 for the 1999-2000 school year.

University Commons and Capstone Development presented these same claims and sought these same damages in a law suit they brought in the United States District Court for the Northern District of Alabama on July 30, 1999. The court stayed prosecution of the case on December 7, 1999, after the parties mutually consented to submit the case to arbitration.

In August 1999, the AAA provided the parties with a list of fifteen possible arbitrators and their resumes. Each party had the right to strike five of the arbitrators on a peremptory basis and rank the remaining names on the list in order of preference. The AAA would then fashion a tribunal based on the parties’ preferences. In the arbitration in this case, styled University Commons-Urbana, Ltd. do Capstone Development Corp. and Universal Constructors, Inc., and Reliance Insurance Company, the AAA ultimately named a panel comprised of three arbitrators, including Edward P. Meyerson, an experienced construction attorney.

The arbitration itself ran from April to June 2000 and was conducted in three parts. During the first set of hearings, from April 17 to April 25, 2000, University Commons set forth its case-in-chief. Then, from June 1 until June 8, 2000, the hearings continued into a second session as Universal and Reliance presented their case-in chief. Finally, the hearings resumed for a third time from July 10 to July 12, 2000, for the parties’ rebuttals and closing arguments.

Prior to the arbitration hearings, the parties held several telephone conference calls with the arbitrators to discuss scheduling and the depositions that needed to be taken. During none of these calls, the first of which occurred on November 11, 1999, did Meyerson disclose any involvement with the parties, their witnesses, or their counsel — Bradley Arant Rose & White LLP (“Bradley Arant”), counsel for University Commons, and Smith, Currie & Hancock LLP, counsel for Universal. In fact, Meyerson never made any written disclosure of any kind indicating that he had a financial or personal interest which might affect his partiality.

At the start of the arbitration hearings on April 17, 2000, Meyerson indicated, however, that he knew and had worked with and against the attorneys and law firms who represented both sides in the arbitration. This would not be Meyerson’s last disclosure: During the course of the arbitration hearings, he also would reveal other previous contacts with people who had interests in the arbitration. For instance, at some point during the arbitration process, Meyerson informed the parties that he had met with a representative from Capstone Building to discuss possible [1335]*1335legal representation.1 In addition, at the end of the hearings, when Jeff Schattinger, Capstone Development’s construction manager, appeared to testify, Meyerson acknowledged that he had met Schattinger previously. Despite these disclosures, there is no evidence in the record that Universal or Reliance objected to Meyer-son’s role as an arbitrator during any stage of the arbitration hearings.

On August 17, 2000, the arbitrators rendered their decision, awarding $2,248,648 to University Commons along with 12% interest per annum accruing from August 15, 2000. Universal and Reliance received nothing on their counterclaims. The arbitrators did not otherwise itemize the award of damages, though. Consequently, they gave no indication as to what portions of the $3,649,669.98, which University Commons originally sought in damages, they thought had merit.

Little time passed, however, before the award was challenged. On August 30, 2000, Universal and Reliance filed a petition to vacate the award in the United States District Court for the Northern District of Georgia. University Commons countered and filed a motion to confirm the award in the still pending litigation (which had been stayed) in the Northern District of Alabama. On October 23, 2000, the district court in Georgia issued an order sua sponte transferring its case to the Northern District of Alabama, and the district court there consolidated the two cases the following month.

On December 15, 2000, the parties met in accordance with Rule 26(f) of the Federal Rules of Civil Procedure,2 and the district court ordered them to proceed with limited discovery," to be completed by March 5, 2001.

Free access — add to your briefcase to read the full text and ask questions with AI

Related

Ray v. Longhi
M.D. Florida, 2021
Municipal Workers Compensation Fund, Inc. v. Morgan Keegan & Co.
190 So. 3d 895 (Supreme Court of Alabama, 2015)
Winfrey v. Simmons Foods, Inc.
495 F.3d 549 (Eighth Circuit, 2007)
Kostoff v. Fleet Securities, Inc.
506 F. Supp. 2d 1150 (M.D. Florida, 2007)
Amadeo Bianchi v. Int'l Brotherhood of Teamsters
441 F.3d 1278 (Eleventh Circuit, 2006)
Peebles v. Merrill Lynch, Pierce, Fener & Smith Inc.
431 F.3d 1320 (Eleventh Circuit, 2005)
Waverlee Homes, Inc. v. McMichael
855 So. 2d 493 (Supreme Court of Alabama, 2003)

Cite This Page — Counsel Stack

Bluebook (online)
304 F.3d 1331, 2002 WL 31042267, Counsel Stack Legal Research, https://law.counselstack.com/opinion/university-commons-urbana-ltd-v-universal-constructors-inc-ca11-2002.