Oassoday, O. J.
The plaintiffs claim that the case was improperly taken from the jury. This seems to be based upon the theory that their contract made with the defendant through Findorff was separate from, independent of, and without reference to the plans, specifications, and contract which the defendant had previously made with the owners of the Kappa House in respect to the plastering. If the evidence on the part of the plaintiffs sustains such theory, then the verdict was improperly directed. The evidence is undisputed, and to the effect that March 11, 1901, the defendant entered into a written contract, including plans and specifications, with the owners of the Kappa House, to erect, construct, and complete the same on or before September 1, 1901, according to such plans and specifications, for $11,441; that, prior to that "time, Porter — named therein as local superintendent — notified different contractors in Madison, including the plaintiffs and the defendant, in' writing, that •such plans and specifications were at his 'office, and invited such contractors, respectively, to examine the same and send him sealed bids for the different parts of the work; that the plaintiffs, pursuant to such notice,, carefully examined such plans and specifications, which were identified by them in evidence, and thereafter sent to Porter their bid for the plastering work; that the defendant sent in a separate bid for the mason work, and also a separate bid for the whole work, and the defendant’s bid for the whole work was accepted, and accordingly the defendant made the contract with the owners March 11, 1901, as stated; that subsequently the defendant sent the plans and specifications to the plaintiffs to give him [292]*292a bid on tbe job; that the plaintiffs then, figured up and returned tbe plans and specifications, and about June 10, 1901, one of tbe plaintiffs met tbe defendant at tbe Pair Store block in tbe presence of Porter, and asked him wbo was going to do the plastering on tbe Kappa House and be replied tbat be did not consider tbe figures of tbe plaintiffs as any bid at all, and tbat be was sure tbat they would not get tbe job; tbat about June 15, 1901, one of tbe plaintiffs asked Pindorff (a subcontractor of a part of tbe woodwork at tbe Kappa House) wbo was going to do tbe plastering on tbat bouse; tbat Pindorff replied by asking wby tbe jilaintiffs did not go and see tbe defendant and do tbe plastering; tbat be then told Pindorff tbat tbe plaintiffs would not see tbe defendant because be bad said wbat be did at tbe Pair Store;, tbat tbe plaintiffs wanted Pindorff to belp tbem get tbe contract before receiving tbe plans and specifications from the defendant; tbat Pindorff then told Mm tbat be thought the plaintiffs were a little bit high on tbe work, and asked if tbe plaintiffs would not “dó tbat work for twenty-one and thirty-five a yard;” tbat be replied tbat tbat would depend on wbat was to be done; tbat Pindorff said, “A bard finish;” tbat be replied tbat tbe plaintiffs could not “do it for twenty-one and thirty-five;” tbat Pindorff then asked wbat tbe plaintiffs wanted “for back plastering,” and be replied, “Thirteen;”' and tbat in a couple of days afterwards Pindorff said, “Go-ahead and do tbe work.” Tbe plaintiff wbo bad such conversation with Findorff testified to tbe effect that be told Pin-dorff wbat tbe plaintiffs’ “bid would be for that job/’ tbat tbe plaintiffs bad previously looked it over “to determine wbat” their "bid would be for that job;” tbat they did tbat. after tbe contract was let to tbe defendant; that before putting in their bid, prior to that time, they “looked over the-plans and specifications carefully as to wbat was required in the plastering part of it;” tbat they “knew wbat tbe plans and specifications required as to plastering and lathing;” tbat [293]*293at that time they understood that if their bid should be accepted they would be controlled by such plans and specifications, but that at the time of the agreement with Eindorff they did not understand that they were bound by such plans and specifications; that they did understand that Mr. 'McCarthy had the contract for the entire work; that they knew that they were making the contract through Eindorff with the defendant, as the other party to the contract; that they Knew the plaintiffs were subcontractors; that they did not expect to do the work differently from what the defendant had •contracted to do it, and that they were bound by what they had agreed with Eindorff; that June 25, 1901, being the ■next day after the plaintiffs commenced work on the Kappa House they received notice in writing from Porter, as such superintendent, that their lathers were “not carrying out the requirements of the specifications where they call for all outside lathing to be narrow laths, nailed with six galvanized iron cut nails to each lath;” that he should expect the lath then “on to be renailed in order to be satisfactory;” that he -showed the letter to Eindorff, who said Porter was the superintendent, and that the plaintiffs better do as he had stated; that they understood from that time on that Porter was superintendent, and that the plaintiffs must “do the work under his directions, not to his satisfaction;” that the plaintiffs did not get any certificate from Porter, and never asked for any. ' August’4, 1901, Porter notified the defendant in writing that the plaintiffs were delaying the work on the Kappa House, and that there would certainly be trouble unless something was done. Two days afterwards the defendant notified the plaintiffs in writing that they would be held responsible for all cost or trouble by reason of such delay. As indicated in the statement of facts, the specifications mentioned required all work to be executed “to the satisfaction of the architects and person superintending the work.” The defendant’s contract with the owners required all work to be executed in a [294]*294thorough, complete, and .most workmanlike mánner, and agreeably to snch directions as should be given from time to time by the architects or Porter, as such local superintendent,, and to such superintendent’s full and entire satisfaction,, without reference thereon to any other person; and it required payment to the defendant by the owners only “on the certificate of the superintendent.” It is undisputed that the-plaintiffs did not do the plastering to the satisfaction of' Porter, and that he refused to give the defendant such certificate by reason of the failure of the plaintiffs to do the work according to such plans and specifications and contract.
The contention that the contract between the plaintiffs and the defendant was made without reference to such specifications and contract previously made between the defendant- and the owners of the Kappa House is without foundation. The interviews between Eindorff and one of the plaintiffs, which resulted in the making of the contract, were without significance or meaning, except when considered with reference to the prior contract and specifications. They say they told Eindorff what the plaintiffs’ “bid would be for the job.” What job was thus referred to ? Certainly the job the plaintiffs had previously looked over “to determine what” their “bid would be for that job.” That manifestly occurred about a week before the conversation with Eindorff, and after the defendant had sent the plans and specifications to the plaintiffs for the purpose of having them give him a bid on the job. At that time they saj they figured and returned the plans- and specifications, which figures the defendant rejected at the Fair Store when the defendant informed the plaintiffs-that they would not get the job at such figures.
Free access — add to your briefcase to read the full text and ask questions with AI
Oassoday, O. J.
The plaintiffs claim that the case was improperly taken from the jury. This seems to be based upon the theory that their contract made with the defendant through Findorff was separate from, independent of, and without reference to the plans, specifications, and contract which the defendant had previously made with the owners of the Kappa House in respect to the plastering. If the evidence on the part of the plaintiffs sustains such theory, then the verdict was improperly directed. The evidence is undisputed, and to the effect that March 11, 1901, the defendant entered into a written contract, including plans and specifications, with the owners of the Kappa House, to erect, construct, and complete the same on or before September 1, 1901, according to such plans and specifications, for $11,441; that, prior to that "time, Porter — named therein as local superintendent — notified different contractors in Madison, including the plaintiffs and the defendant, in' writing, that •such plans and specifications were at his 'office, and invited such contractors, respectively, to examine the same and send him sealed bids for the different parts of the work; that the plaintiffs, pursuant to such notice,, carefully examined such plans and specifications, which were identified by them in evidence, and thereafter sent to Porter their bid for the plastering work; that the defendant sent in a separate bid for the mason work, and also a separate bid for the whole work, and the defendant’s bid for the whole work was accepted, and accordingly the defendant made the contract with the owners March 11, 1901, as stated; that subsequently the defendant sent the plans and specifications to the plaintiffs to give him [292]*292a bid on tbe job; that the plaintiffs then, figured up and returned tbe plans and specifications, and about June 10, 1901, one of tbe plaintiffs met tbe defendant at tbe Pair Store block in tbe presence of Porter, and asked him wbo was going to do the plastering on tbe Kappa House and be replied tbat be did not consider tbe figures of tbe plaintiffs as any bid at all, and tbat be was sure tbat they would not get tbe job; tbat about June 15, 1901, one of tbe plaintiffs asked Pindorff (a subcontractor of a part of tbe woodwork at tbe Kappa House) wbo was going to do tbe plastering on tbat bouse; tbat Pindorff replied by asking wby tbe jilaintiffs did not go and see tbe defendant and do tbe plastering; tbat be then told Pindorff tbat tbe plaintiffs would not see tbe defendant because be bad said wbat be did at tbe Pair Store;, tbat tbe plaintiffs wanted Pindorff to belp tbem get tbe contract before receiving tbe plans and specifications from the defendant; tbat Pindorff then told Mm tbat be thought the plaintiffs were a little bit high on tbe work, and asked if tbe plaintiffs would not “dó tbat work for twenty-one and thirty-five a yard;” tbat be replied tbat tbat would depend on wbat was to be done; tbat Pindorff said, “A bard finish;” tbat be replied tbat tbe plaintiffs could not “do it for twenty-one and thirty-five;” tbat Pindorff then asked wbat tbe plaintiffs wanted “for back plastering,” and be replied, “Thirteen;”' and tbat in a couple of days afterwards Pindorff said, “Go-ahead and do tbe work.” Tbe plaintiff wbo bad such conversation with Findorff testified to tbe effect that be told Pin-dorff wbat tbe plaintiffs’ “bid would be for that job/’ tbat tbe plaintiffs bad previously looked it over “to determine wbat” their "bid would be for that job;” tbat they did tbat. after tbe contract was let to tbe defendant; that before putting in their bid, prior to that time, they “looked over the-plans and specifications carefully as to wbat was required in the plastering part of it;” tbat they “knew wbat tbe plans and specifications required as to plastering and lathing;” tbat [293]*293at that time they understood that if their bid should be accepted they would be controlled by such plans and specifications, but that at the time of the agreement with Eindorff they did not understand that they were bound by such plans and specifications; that they did understand that Mr. 'McCarthy had the contract for the entire work; that they knew that they were making the contract through Eindorff with the defendant, as the other party to the contract; that they Knew the plaintiffs were subcontractors; that they did not expect to do the work differently from what the defendant had •contracted to do it, and that they were bound by what they had agreed with Eindorff; that June 25, 1901, being the ■next day after the plaintiffs commenced work on the Kappa House they received notice in writing from Porter, as such superintendent, that their lathers were “not carrying out the requirements of the specifications where they call for all outside lathing to be narrow laths, nailed with six galvanized iron cut nails to each lath;” that he should expect the lath then “on to be renailed in order to be satisfactory;” that he -showed the letter to Eindorff, who said Porter was the superintendent, and that the plaintiffs better do as he had stated; that they understood from that time on that Porter was superintendent, and that the plaintiffs must “do the work under his directions, not to his satisfaction;” that the plaintiffs did not get any certificate from Porter, and never asked for any. ' August’4, 1901, Porter notified the defendant in writing that the plaintiffs were delaying the work on the Kappa House, and that there would certainly be trouble unless something was done. Two days afterwards the defendant notified the plaintiffs in writing that they would be held responsible for all cost or trouble by reason of such delay. As indicated in the statement of facts, the specifications mentioned required all work to be executed “to the satisfaction of the architects and person superintending the work.” The defendant’s contract with the owners required all work to be executed in a [294]*294thorough, complete, and .most workmanlike mánner, and agreeably to snch directions as should be given from time to time by the architects or Porter, as such local superintendent,, and to such superintendent’s full and entire satisfaction,, without reference thereon to any other person; and it required payment to the defendant by the owners only “on the certificate of the superintendent.” It is undisputed that the-plaintiffs did not do the plastering to the satisfaction of' Porter, and that he refused to give the defendant such certificate by reason of the failure of the plaintiffs to do the work according to such plans and specifications and contract.
The contention that the contract between the plaintiffs and the defendant was made without reference to such specifications and contract previously made between the defendant- and the owners of the Kappa House is without foundation. The interviews between Eindorff and one of the plaintiffs, which resulted in the making of the contract, were without significance or meaning, except when considered with reference to the prior contract and specifications. They say they told Eindorff what the plaintiffs’ “bid would be for the job.” What job was thus referred to ? Certainly the job the plaintiffs had previously looked over “to determine what” their “bid would be for that job.” That manifestly occurred about a week before the conversation with Eindorff, and after the defendant had sent the plans and specifications to the plaintiffs for the purpose of having them give him a bid on the job. At that time they saj they figured and returned the plans- and specifications, which figures the defendant rejected at the Fair Store when the defendant informed the plaintiffs-that they would not get the job at such figures. It is manifest that the job thus referred to meant the job of lathing and plastering which the defendant had agreed to perform for the owners of the Kappa House. He was bound to perform, or get some one else to perform, that job in accordance with such plans, specifications, and contract. If the work should [295]*295be clone in any other way it would be of no value to the defendant. This was well known to the plaintiffs for months before the conversation with Findorff. When, at the Fair Store, one of the pMntiffs asked the defendant who was going to do the plastering work on the Kappa House, he manifestly referred to the plastering work described in the plans, specifications, and contract upon which the plaintiffs had figured, and for which they had made an offer to the defendant, which he then rejected. The “job” repeatedly referred to in the conversation with Findorff manifestly referred to the lathing and plastering which such plans, specifications, and contract required to be done by the defendant. Of course it was competent for the defendant to make an entirely different contract with the plaintiffs. But no man of ordinary judgment would be expected to do so under the circumstances stated. The facts admitted by the plaintiffs clearly show that in case they got the job they expected to do the lath and plastering work on the Kappa House according to such plans, specifications, and prior contract, and that the negotiations through Findorff related only to the price to be paid by the defendant for the “job.” All other matters and details were manifestly understood to be as stated in such plans, specifications, and prior contract. It is conceded that, had the plaintiffs attempted to enforce a lien against the Kappa House for such plastering work, they would have been bound to take notice of the terms and conditions of the original contract, and been controlled thereby. Schroeder v. Galland, 134 Pa. St. 277, 19 Atl. 632, 7 L. R. A. 711; Shaw v. First Baptist Church, 44 Minn. 22, 46 N. W. 146; Shaver v. Murdock, 36 Cal. 293; Henley v. Wadsworth, 38 Cal. 356. Here it stands admitted that the plaintiffs had actual notice of such plans, specifications, and prior contract, and agreed to do such plastering work according to the terms and conditions therein contained. Hence they were bound to do the work to the satisfaction of the architects and Porter, as the local super[296]*296intendent, and they were only entitled to payment upon doing so.
The views expressed make it unnecessary to determine whether it was error for the trial court to hold, as a matter of law, that the plaintiffs were hound to know of the existence of a custom in the city thaf subcontractors took their contracts subject to the terms and conditions of the contract between the owners and the principal contractor, notwithstanding the evidence tended to prove that the plaintiffs had no knowledge of the existence of such custom. In addition to cases cited by counsel, see Ohaieaugay 0. & I. Go.v. Blalce, 144 U. S. 476, 12 Sup. Ct. 731. The trial court, however, properly held that, regardless of such custom, the plaintiffs were, as a matter of fact, hound by the terms and conditions of such original contract, and were only entitled to payment upon doing so.
By the Gourt. — The judgment of the circuit court is affirmed.
Siebeckeb, J., took no part.