Briscoe, J.,
delivered the opinion of the: Court-.
This is a suit brought by the plaintiff against the defendant to recover an alleged balance due on. a contract for1 the purchase of one hundred Wooden hand trucks by the defendant of the plaintiff, to be used in its business to carry material from one part of its building to another.
The plaintiff is a corporation, engaged in the business of manufacturing contractors’ equipments and supplies and a. general line of machinery. The main office is in the City of Pittsburg, Pa., but it also has offices located in Baltimore City and other large cities. Tt also acts as broker or sales agent for other factories making; supplies and machinery that it does not manufacture itself.
The defendant is also a corporation and is. engaged in the general enameling business and, at the time of the contract-entered into and sued on in this case, had a. factory at Wood-hall Street, Baltimore City, and a new plant under construction at Mt. Winans, Baltimore County. The- hand tracks
were purchased for use at its new plant and factory and were to be delivered at its Mt. Winans plant. The trucks were to be specially made and to be used for a special purpose in moving material about the plant. They were designated as platform trucks, with end racks at each end and a platform .about nine feet long and three feet wide.
The contract sued on and which was accepted and acted on by the parties appears from the record to be as follows:
“The Baltimore Enamel and Novelty Co.,
“Baltimore, Md.
“Enameled Iron Signs for Advertising Purposes,
“Brewers’ Trays, Railroad Signals in All Colors,
“and General Enamelers, Die Work,
“Reflectors, Spinning Work.
“Baltimore, August 9th, 1917.
“Please fill the following prompt:
“The Standard Scales & Supply Co.,
“Pittsburgh, Pa.
“100 — trucks like sample, except with heavy casters.
Consigned to our siding, Mount Winans, Md.
“$26.00 per truck; for heavy casters, .90, price per truck; $26.90 total per truck.
“Yours truly,
“The Baltimore Enamel & Novelty Co.,
“Per APC — S.
“Order B — No. 4874.
“Put order number on invoice.
“(Fully equipped machine shop for doing all kinds of “Stamping, Spinning and Die Work.)”
At the close of the testimony the Court directed a verdict for the defendant by granting the defendant’s two prayers which instructed the jury: first, that there was no evidence in the case legally sufficient to entitle the plaintiff to recover •and secondly, that the contract between the parties required the plaintiff to ship the trucks promptly and, as it appears from the uncontradicted evidence in the ease that the plain-tiff did not promptly ship them to the defendant, and the
defendant, after waiting a reasonable time, rescinded or countermanded tbe order, their verdict should be for the defendant.
The plaintiff excepted to the granting of these prayers, and the action of the Court in this ruling isi the basis of the third exception. The first and second exceptions relate tendings on evidence.
From a judgment in .favor of the defendant for costs, the plaintiff has prosecuted this appeal.
It is the settled law that when the evidence offered in the case is legally insufficient to fix a liability upon the defendant, it is the duty of the Court, when applied to by an appropriate prayer, to instruct the jury to find their verdict for the defendant.
Tho undisputed evidence in this case shows that the1 contract between the parties was entered into' on the 9th of" August, 1917, for one hundred special trucks, at $26.90/100-each, aggregating $2,690, to be delivered at Mount Winans, Maryland. The contract, which is in the form of a letter-addressed to the plaintiff by the defendant, and accepted by it, nses the expression “Please fill the following prompt.” and it was understood between the parties, at tbe time of the-contract, that the order would be filled within from four to six weeks.
On October 22nd, 1917, the defendant inquired of the plaintiff by letter, to know wben they would make shipment, as they would soon he ready for them. The plaintiff replied to this letter, on October 23rd, 1917, in which it was stated that the factory promised shipment of the trucks on October 15 th, but they had failed to receive shipping papers or anything indicating that shipment had gone forward. The letter-further stated:
“We are writing factory today, urging upon them the necessity of prompt shipment, if same has not already gone forward, and as soon as we are in receipt of information that shipment has gone forward or
advices, as to when it will go forward, we will immediately0 communicate with you.”
On January 7th, 1918, the defendant was advised by the plaintiff that fifty trucks, one-half of the order', had been .shipped on the 2nd of January, 1918, and that the balance •of the order will'go forward at a very early date. It was further stated in this letter:
“We regret the delay in filling this order, but factory was unable to get sufficient lumber to make these trucks and had considerable difficulty in obtaining same.”
The first shipment, one-half of the order, it will be thus -seen, was not made until about five months after the date of the contract, but the defendant received the fifty trucks, under this shipment, and paid' one-half of the contract price, to wit, the sum of $1,345.
The proof further shows that the defendant on the 18th of May, 1918, not having received the balance of the order, by. -a letter of that date countermanded it, “on account of.the •delay in shipping, as we cannot use the trucks at this late ■date, as they were ordered for a special purpose.”
The plaintiff, however, notwithstanding “the countermand” •of the order, shipped the second fifty trucks on August 2nd .and 5th, 1918, twenty-five in each shipment, but the defend•ant declined to accept them, because it- had countermanded .the order, and the plaintiff had failed to comply with the terms of the contract, with respect to “the prompt” delivery •of the trucks.
Upon these facts there was, in our opinion, no error committed by the granting of the defendant’s two prayers.
Free access — add to your briefcase to read the full text and ask questions with AI
Briscoe, J.,
delivered the opinion of the: Court-.
This is a suit brought by the plaintiff against the defendant to recover an alleged balance due on. a contract for1 the purchase of one hundred Wooden hand trucks by the defendant of the plaintiff, to be used in its business to carry material from one part of its building to another.
The plaintiff is a corporation, engaged in the business of manufacturing contractors’ equipments and supplies and a. general line of machinery. The main office is in the City of Pittsburg, Pa., but it also has offices located in Baltimore City and other large cities. Tt also acts as broker or sales agent for other factories making; supplies and machinery that it does not manufacture itself.
The defendant is also a corporation and is. engaged in the general enameling business and, at the time of the contract-entered into and sued on in this case, had a. factory at Wood-hall Street, Baltimore City, and a new plant under construction at Mt. Winans, Baltimore County. The- hand tracks
were purchased for use at its new plant and factory and were to be delivered at its Mt. Winans plant. The trucks were to be specially made and to be used for a special purpose in moving material about the plant. They were designated as platform trucks, with end racks at each end and a platform .about nine feet long and three feet wide.
The contract sued on and which was accepted and acted on by the parties appears from the record to be as follows:
“The Baltimore Enamel and Novelty Co.,
“Baltimore, Md.
“Enameled Iron Signs for Advertising Purposes,
“Brewers’ Trays, Railroad Signals in All Colors,
“and General Enamelers, Die Work,
“Reflectors, Spinning Work.
“Baltimore, August 9th, 1917.
“Please fill the following prompt:
“The Standard Scales & Supply Co.,
“Pittsburgh, Pa.
“100 — trucks like sample, except with heavy casters.
Consigned to our siding, Mount Winans, Md.
“$26.00 per truck; for heavy casters, .90, price per truck; $26.90 total per truck.
“Yours truly,
“The Baltimore Enamel & Novelty Co.,
“Per APC — S.
“Order B — No. 4874.
“Put order number on invoice.
“(Fully equipped machine shop for doing all kinds of “Stamping, Spinning and Die Work.)”
At the close of the testimony the Court directed a verdict for the defendant by granting the defendant’s two prayers which instructed the jury: first, that there was no evidence in the case legally sufficient to entitle the plaintiff to recover •and secondly, that the contract between the parties required the plaintiff to ship the trucks promptly and, as it appears from the uncontradicted evidence in the ease that the plain-tiff did not promptly ship them to the defendant, and the
defendant, after waiting a reasonable time, rescinded or countermanded tbe order, their verdict should be for the defendant.
The plaintiff excepted to the granting of these prayers, and the action of the Court in this ruling isi the basis of the third exception. The first and second exceptions relate tendings on evidence.
From a judgment in .favor of the defendant for costs, the plaintiff has prosecuted this appeal.
It is the settled law that when the evidence offered in the case is legally insufficient to fix a liability upon the defendant, it is the duty of the Court, when applied to by an appropriate prayer, to instruct the jury to find their verdict for the defendant.
Tho undisputed evidence in this case shows that the1 contract between the parties was entered into' on the 9th of" August, 1917, for one hundred special trucks, at $26.90/100-each, aggregating $2,690, to be delivered at Mount Winans, Maryland. The contract, which is in the form of a letter-addressed to the plaintiff by the defendant, and accepted by it, nses the expression “Please fill the following prompt.” and it was understood between the parties, at tbe time of the-contract, that the order would be filled within from four to six weeks.
On October 22nd, 1917, the defendant inquired of the plaintiff by letter, to know wben they would make shipment, as they would soon he ready for them. The plaintiff replied to this letter, on October 23rd, 1917, in which it was stated that the factory promised shipment of the trucks on October 15 th, but they had failed to receive shipping papers or anything indicating that shipment had gone forward. The letter-further stated:
“We are writing factory today, urging upon them the necessity of prompt shipment, if same has not already gone forward, and as soon as we are in receipt of information that shipment has gone forward or
advices, as to when it will go forward, we will immediately0 communicate with you.”
On January 7th, 1918, the defendant was advised by the plaintiff that fifty trucks, one-half of the order', had been .shipped on the 2nd of January, 1918, and that the balance •of the order will'go forward at a very early date. It was further stated in this letter:
“We regret the delay in filling this order, but factory was unable to get sufficient lumber to make these trucks and had considerable difficulty in obtaining same.”
The first shipment, one-half of the order, it will be thus -seen, was not made until about five months after the date of the contract, but the defendant received the fifty trucks, under this shipment, and paid' one-half of the contract price, to wit, the sum of $1,345.
The proof further shows that the defendant on the 18th of May, 1918, not having received the balance of the order, by. -a letter of that date countermanded it, “on account of.the •delay in shipping, as we cannot use the trucks at this late ■date, as they were ordered for a special purpose.”
The plaintiff, however, notwithstanding “the countermand” •of the order, shipped the second fifty trucks on August 2nd .and 5th, 1918, twenty-five in each shipment, but the defend•ant declined to accept them, because it- had countermanded .the order, and the plaintiff had failed to comply with the terms of the contract, with respect to “the prompt” delivery •of the trucks.
Upon these facts there was, in our opinion, no error committed by the granting of the defendant’s two prayers.
The law is well settled, as a general rule, that in mercantile contracts, stipulations as to time are regarded as essential .and a material provision of the contract, and upon the failure or non-performance of which the purchaser is not hound -to accept and pay for the goods, unless they are delivered or •tendered on the day specified in the contract, and may re
scind and repudiate the contract.
Barker
v.
Borzone,
48 Md. 474;
Ady
v.
Jenkins,
133 Md. 38;
Jones
v.
United States,
96 U. S. 24;
Norrington v. Wright,
115 U. S. 188.
In this case, the second lot of fifty trucks was not shipped" by the plaintiff until about three months, after the defendant had countermanded the order, and until nearly one year after the contract was executed. The contract required that the order should be filled “promptly” and as the delivery of the trucks here sued for was not made until nearly one year after the contract, the Court below was right in holding that the-contract had not been complied with, and as the defendant had countermanded the order, on the 18th of May, 1918, in directing a verdict for the defendant.
The facts in this case, as to the delay in filling the order under the contract, being undisputed, the question of what was a reasonable time, was clearly one of law for the Court, and not for a jury.
Wheeler
v.
Harrison,
94 Md. 147;
United Fruit Company
v.
Transportation Co.,
104 Md. 567.
It is clear, we think, that the defense relied upon, that the-performance of the contract, as to the prompt delivery of the trucks in question, was rendered impossible by an embargo - on shipment from Columbus, Ohio, going east, by the Government, cannot be sustained under the facts of this case.
In 35
Cyc.
244, the general rule, as. to impossibility of performance of contracts arising subsequent to the making of a contract is thus stated, as supported by authority, that a seller-who promises unconditionally to deliver takes the risk of" being unable to- perform, although his- inability is caused by inevitable accident or circumstances beyond his control. It is further said at page 245 of the same volume that, in accordance with the general rule, it has usually been held, that the seller is not excused from delivery by the obstruction of routes of transportation, whether due to the freezing of waterways, seizure of a railway by the Government, freshets or other causes, unless such contingencies, are expressly provided for in the contract and especially will the rule prevail
where other routes of transportation were open to the seller. And that a failure to deliver under the terms of the contract is not excused by the inability of the seller to procure cars •or other means of transportation unless there is a stipulation covering such contingency, and even in such case he must .show that he made a reasonable effort to procure transportation.
The same principle and rule of law has been announced by this Court and the Supreme Court of the United States, in a long line of well considered cases.
Benson
v.
Atwood,
13 Md. 20;
Kribs
v.
Jones,
44 Md. 396;
Pennsylvania R. R. Co.
v.
Reichert,
58 Md. 261.
In
Southern Bldg. Assn.
v.
Price,
88 Md. 163, it is said, it is familiar law that if at the time of making the contract the thing promised be possible in itself, it is no excuse for non-performance that its performance became subsequently "impossible from causes beyond the control of the promisor.
Jones
v.
United States,
96 U. S. 24;
United States
v.
Gleason,
175 U. S. 588.
Under the order, which is the contract in this case, the plaintiff promised unconditionally to manufacture and deliver to the defendant the trucks here in question. The contract was not made dependent upon embargoes or other contingencies which might have been provided for and guarded against by the terms of the contract, but failing in this, the -case must be governed by the general rules of law applicable to such contracts.
Tiffany on Sales,
2nd Ed. 308;
Brantly on Contracts,
262-264.
We find nothing in the contract to show that the trucks were to be shipped f. o. b. Columbus, or to justify the argument made by the plaintiff that the duty or obligation rested ■upon the defendant to furnish the cars necessary for the transportation of the trucks. The only reference in the contract to the shipment of the trucks is that they were to1 be “'consigned to our siding — Mt. Winans, Maryland.”
The course of dealing, however, between the parties .•amounted to a construction of the contract as imposing the duty upon the seller (plaintiff) here to> furnish the cars. The plaintiff provided the cars for the first shipment, and at no time, in its correspondence as to the delay, did it assert or claim that it was the duty of the defendant to furnish the •ears or that the delay in the delivery was due to this cause or failure.
Lauder
v.
Mackie,
97 Md. 13;
Williston on Sales,
409;
Vogl
v.
Schienback,
122 Wis. 491;
Hurst
v.
Altamont Mfg. Co.,
73 Kan. 422.
There is no1 reversible error in the ruling of the Court upon •exceptions to testimony as set out in the record.
The first exception was to the refusal of the Court to allow the witness to answer the following question, “Is this paper which you produced in evidence, is this the full contract or Is it merely the acceptance of an offer on the part of the defendant?” The construction of the contract was for the Court and not for the witness, and there was nothing in the •circumstances surrounding the written contract that would .bring it within any of the exceptions to the general rule that would permit the introduction of oral evidence to vary or •contradict the terms of a written contract.
The second exception was to the1 refusal of the Court, to permit the following question to be asked the witness Little, “whether or not the Standard Seale and Supply Company complied with the contract offered in evidence and if they have done what they contracted to do under that contract.”
The Court properly sustained the defendant’s objection to the question, because the question was one calling for the opinion of the witness^ and whether the contract had been complied with by either of the partiesi was a question of law, under the facts of the case, to be determined by the Court.
Eor the reasons we have stated the judgment from which the appeal was taken will be affirmed.
Judgment affirmed, with costs.