BROADDUS, P. J.
This is a suit to enforce the collection of a special tax bill issued to the contractor J. N. Fellows, for grading and macadamizing Anthony street in the city of Columbia, a city of the third class. The petition contains allegations to the effect that on the 15th day of June, 1908, the city council adopted a resolution declaring the necessity for the work; that due publication of the resolution was made; that the council duly passed an ordinance for the grading and macadamizing of the street; that, in pursuance of the [294]*294said ordinance, plaintiff entered into a contract on the 8th of August, 1908', with the city to do the work provided in said resolution and ordinance for the sum of $3254.568; that he duly performed said contract, and made the improvements by grading, paving and curbing said street; that said work was duly accepted by the council, and assessment for the cost of the work was made by an ordinance levying a special assessment for said improvement and authorizing the tax bills therefor; that the* city caused the total cost of the work to be assessed against the lots and tracts of land fronting and abutting on either side of said street in proportion to the front foot, etc., and did cause tax bills to be issued therefor in payment to the plaintiff as such contractor. It is alleged that the tax bill in suit, which was for $603,395; was the proportionate part charged against the property of defendant, and then follows a description of the tax bill, which is filed. The answer was a general denial.
On the 15th day of June, 1908;, the city council passed a resolution declaring it necessary to grade, pave, curb and gutter Anthony street. The grading, curbing and macadamizing were described in detail. The street was to be twenty-two feet from curb to curb. A sublayer of macadam, five inches deep, was to be laid from gutter line to gutter line, prescribing the materials to be used. Upon this was to be laid a four inch course; no stone to be used whose greatest dimensions exceed one and one-half inches. Upon this layer was to be laid a top course of screened gravel containing about fifteen per cent sand, and no stone which shall exceed one inch in its greatest diameter. . . “The last course to be grouted twenty-four inches from each curb to form a gutter. On each side of the stregt shall be constructed „ a concrete curb five inches wide and sixteen inches in depth/ ’
The specifications for the gutter were as follows: “Gutter to be formed by grouting the top course a [295]*295distance of twenty-four from each curb to form a gutter. Grout to be made of one part Portland cement and six parts clean sand. It being understood that the depth of courses of material above described indicates depths before rolling.”
On the 16th day of March, 1909, the contract was let to plaintiff for the performance of the work according to the plans and specifications. On the 4th day of January, 1910, the work was reported completed, and the council then passed the ordinance levying special tax bills for the work, including that of the defendant.
The time for the completion of the work was fixed at ninety days from the date on which the engineer notified the contractor to begin work. It was provided that: “Should the contractor fail to cómplete the work to the satisfaction of the engineer, within the time specified, then there shall be withheld from the money due him on his final, estimate, a sum of money equal to ten dollars per day for each and every day of such delay.”
The principal controversy was whether the contractor complied with the specifications as to the guttering. It was shown that the contractor made a mix.-ture for the gutter and spread it for the required width on top of the last course, which made a soft mortar crust to form the gutter. The evidence tended to show that this mixture became dust and was blown or washed away. The result was that the gutter washed out in ditches, and some of the curbing fell.
As to the composition of the top course, there was evidence on the part of the defendant that it was not screened, but varied from stones as large as a man’s fist to small particles, and that there was more sand than gravel. And that the work was not done in a good workmanlike manner. On the other hand, plaintiff’s evidence tended to rebut that of the defendant as to that matter, also that the mixture was according to the [296]*296specifications, and showing by standard authority the meaning of the word “sand.” Also, there was evidence tending to show that the cause of the washing of the gutter was that it was overburdened with excessive drainage.
The court, in various instructions, told the jury, substantially, that if the work done by the plaintiff complied with the specifications he was entitled to recover on the taxbill, notwithstanding they might believe the gutters were washed away, or that the street subsequently became in bad condition and out of repair. Other evidence will be referred to hereafter.
By instruction No. 4 the court defined what the word “sand” meant in-the contract. It is as follows: “The court instructs the jury that if you find and believe from the evidence that the term ‘sand’ as used in the contract and specifications for Anthony street means that material that will pass through a number twenty sieve which is a sieve containing twenty meshes to the inch, and if you further find and believe from the evidence that the plaintiff, the contractor, in putting on the top course on said street, used material which contained about fifteen per cent sand, according to the above test, then you must find that as to the-top course that the plaintiff did said work according to the contract and the specifications therefor.”
The defendant asked an instruction placing the burden of proof upon the plaintiff, which the court refused; and one to the effect that if the gutter constructed “was worthless and wholly unserviceable,”' the finding must be for the defendant, which the court also refused. And one also to the effect that “the work contracted for must be reasonably adapted to the purpose,” etc. This was also refused.
Upon the question of the burden of proof the court gave instruction No. 3 at the instance of plaintiff. It is as follows: “The jury are instructed that the- acceptance by the city council of the city of Colum[297]*297"bia of the work done "by the plaintiff on Anthony street and the issuing to him of the tax bills read in evidence, raised the presumption that the improvement on Anthony street was constructed of the material and in the manner prescribed by the contract, plans and specifications read in evidence, and before the defendant ■ can avoid the payment of said tax bills it devolves upon him to show by the greater weight of the evidence that there was a substantial deviation from the plans and specifications in doing said work and the mere fact that gutter or gutters were washed away or that the street subsequently became in had condition and out of repair, will not invalidate the tax hills or authorize the jury to find for the defendant. ’ ’
The plaintiff recovered for the amount of the tax hill with eight per cent interest. The defendant appealed.
It is insisted that the petition does not state a cause of action. It seems that defendant bases his contention upon the theory that all the steps taken by the council and other matters for doing the work by the contractor are not set forth in the petition.
Free access — add to your briefcase to read the full text and ask questions with AI
BROADDUS, P. J.
This is a suit to enforce the collection of a special tax bill issued to the contractor J. N. Fellows, for grading and macadamizing Anthony street in the city of Columbia, a city of the third class. The petition contains allegations to the effect that on the 15th day of June, 1908, the city council adopted a resolution declaring the necessity for the work; that due publication of the resolution was made; that the council duly passed an ordinance for the grading and macadamizing of the street; that, in pursuance of the [294]*294said ordinance, plaintiff entered into a contract on the 8th of August, 1908', with the city to do the work provided in said resolution and ordinance for the sum of $3254.568; that he duly performed said contract, and made the improvements by grading, paving and curbing said street; that said work was duly accepted by the council, and assessment for the cost of the work was made by an ordinance levying a special assessment for said improvement and authorizing the tax bills therefor; that the* city caused the total cost of the work to be assessed against the lots and tracts of land fronting and abutting on either side of said street in proportion to the front foot, etc., and did cause tax bills to be issued therefor in payment to the plaintiff as such contractor. It is alleged that the tax bill in suit, which was for $603,395; was the proportionate part charged against the property of defendant, and then follows a description of the tax bill, which is filed. The answer was a general denial.
On the 15th day of June, 1908;, the city council passed a resolution declaring it necessary to grade, pave, curb and gutter Anthony street. The grading, curbing and macadamizing were described in detail. The street was to be twenty-two feet from curb to curb. A sublayer of macadam, five inches deep, was to be laid from gutter line to gutter line, prescribing the materials to be used. Upon this was to be laid a four inch course; no stone to be used whose greatest dimensions exceed one and one-half inches. Upon this layer was to be laid a top course of screened gravel containing about fifteen per cent sand, and no stone which shall exceed one inch in its greatest diameter. . . “The last course to be grouted twenty-four inches from each curb to form a gutter. On each side of the stregt shall be constructed „ a concrete curb five inches wide and sixteen inches in depth/ ’
The specifications for the gutter were as follows: “Gutter to be formed by grouting the top course a [295]*295distance of twenty-four from each curb to form a gutter. Grout to be made of one part Portland cement and six parts clean sand. It being understood that the depth of courses of material above described indicates depths before rolling.”
On the 16th day of March, 1909, the contract was let to plaintiff for the performance of the work according to the plans and specifications. On the 4th day of January, 1910, the work was reported completed, and the council then passed the ordinance levying special tax bills for the work, including that of the defendant.
The time for the completion of the work was fixed at ninety days from the date on which the engineer notified the contractor to begin work. It was provided that: “Should the contractor fail to cómplete the work to the satisfaction of the engineer, within the time specified, then there shall be withheld from the money due him on his final, estimate, a sum of money equal to ten dollars per day for each and every day of such delay.”
The principal controversy was whether the contractor complied with the specifications as to the guttering. It was shown that the contractor made a mix.-ture for the gutter and spread it for the required width on top of the last course, which made a soft mortar crust to form the gutter. The evidence tended to show that this mixture became dust and was blown or washed away. The result was that the gutter washed out in ditches, and some of the curbing fell.
As to the composition of the top course, there was evidence on the part of the defendant that it was not screened, but varied from stones as large as a man’s fist to small particles, and that there was more sand than gravel. And that the work was not done in a good workmanlike manner. On the other hand, plaintiff’s evidence tended to rebut that of the defendant as to that matter, also that the mixture was according to the [296]*296specifications, and showing by standard authority the meaning of the word “sand.” Also, there was evidence tending to show that the cause of the washing of the gutter was that it was overburdened with excessive drainage.
The court, in various instructions, told the jury, substantially, that if the work done by the plaintiff complied with the specifications he was entitled to recover on the taxbill, notwithstanding they might believe the gutters were washed away, or that the street subsequently became in bad condition and out of repair. Other evidence will be referred to hereafter.
By instruction No. 4 the court defined what the word “sand” meant in-the contract. It is as follows: “The court instructs the jury that if you find and believe from the evidence that the term ‘sand’ as used in the contract and specifications for Anthony street means that material that will pass through a number twenty sieve which is a sieve containing twenty meshes to the inch, and if you further find and believe from the evidence that the plaintiff, the contractor, in putting on the top course on said street, used material which contained about fifteen per cent sand, according to the above test, then you must find that as to the-top course that the plaintiff did said work according to the contract and the specifications therefor.”
The defendant asked an instruction placing the burden of proof upon the plaintiff, which the court refused; and one to the effect that if the gutter constructed “was worthless and wholly unserviceable,”' the finding must be for the defendant, which the court also refused. And one also to the effect that “the work contracted for must be reasonably adapted to the purpose,” etc. This was also refused.
Upon the question of the burden of proof the court gave instruction No. 3 at the instance of plaintiff. It is as follows: “The jury are instructed that the- acceptance by the city council of the city of Colum[297]*297"bia of the work done "by the plaintiff on Anthony street and the issuing to him of the tax bills read in evidence, raised the presumption that the improvement on Anthony street was constructed of the material and in the manner prescribed by the contract, plans and specifications read in evidence, and before the defendant ■ can avoid the payment of said tax bills it devolves upon him to show by the greater weight of the evidence that there was a substantial deviation from the plans and specifications in doing said work and the mere fact that gutter or gutters were washed away or that the street subsequently became in had condition and out of repair, will not invalidate the tax hills or authorize the jury to find for the defendant. ’ ’
The plaintiff recovered for the amount of the tax hill with eight per cent interest. The defendant appealed.
It is insisted that the petition does not state a cause of action. It seems that defendant bases his contention upon the theory that all the steps taken by the council and other matters for doing the work by the contractor are not set forth in the petition.
The city of Columbia being a city of the third class, the pleading in question is to be construed with reference to section 5891, Revised Statutes 1899, now ■section 9296, Revised Statutes 1909. The section provides that: “It shall be sufficient for the plaintiff, in any suit on such special tax bill, to plead the making of the tax bill sued upon, giving the date and contents thereof, and the assignment thereof, if any, and to allege that the party or parties made defendant own, or claim to own, the lands charged, or some estate or interest therein, as the case may be, and to file the tax bill in suit.” And, “Every tax bill shall, in any suit thereon, be prima facie evidence of the validity of the bill, and of the doing of the work and of the furnishing of the material charged for, and of the liability of the land to the charge stated in the bill.”
[298]*298The petition states all the facts required by the statute. We have examined with some care the cases cited by defendant to sustain his theory, and are free to say that we do not think they apply. The question has often been before the courts, and the holding has been uniform that a petition, alleging the facts required by the statute, is sufficient. And we do not see how it could be otherwise, unless the statute should be disregarded. [Cushing v. Powell, 130 Mo. App. 576; Paving Co. v. Bath Co., 136 Mo. App. 555; Bambrick Bros. v. McCormick, 157 Mo. App. 198.]
The validity of the tax bill is challenged on the ground that the preliminary resolution for doing the work failed in specifications.
The rule is stated to be that: “The resolution of the city council providing for street improvement should state directly or by reference the nature and character of the improvements, otherwise the proceedings are without jurisdiction and the tax bills issued would not be valid.” [City of Poplar Bluff v. Bacon, 144 Mo. App. 476; Coulter v. Construction Co., 131 Mo. App. 230.] “The preliminary resolution declaring it necessary that certain streets of a city of the third class should be paved, etc., should substantially inform the public of the kind and character of improvement intended; otherwise the proceedings and tax bills will be invalid.” [City of Kirksville v. Coleman, 103 Mo. App. 215.] In that case the resolution declared that, “it is deemed by said council necessary to improve Brown avenue ... by grading, paving, glittering, curbing and terracing the said avenue,” and there was no mention directly or indirectly of the kind of paving.
The statute does not require any particular description of the work to be done in such cases, it only requires that the city council shall, “by resolution declare such work or improvements necessary to be done.” [Sections 5859 and 5860, it. S. 1899.] How[299]*299ever, it necessarily implies that there should he some description of the nature and character of the work. It does not mean, however, that it should he specifically described. The character of the work and the nature of the material will answer the purpose of the statute. The ease of Muff v. City of Cameron, 134 Mo. App. 607, and authorities cited, we believe, are conclusive on the question. We think -the resolution is sufficiently explicit as to the guttering. It is to be grouted. Grouting consists of the proper proportions of sand, stone and cement. Every property owner to be affected knew what the resolution meant, and such is the only purpose of the statute.
The statute requires that the council shall “cause such resolution to be published in some newspaper printed in the city for two consecutive insertions in a weekly paper, or seven consecutive insertions in a daily paper.” [R. S. 1909, sec. 9255.] The publication was made in a daily paper. There was three gaps in the publication; the first publication was on June the 27th and the last on July the 6th, leaving a gap on June 28th, July 4th and 5th. It is conceded that a paper published six days a week without a Sunday edition is a daily paper within the meaning of the statute, and the continuity would not be broken by the lack of a Sunday edition but, as there were not three Sundays between Jane 27th and July 6th, there was an omission of one work day. In Porter v. Boyd Pav. Co., 214 Mo. 1, it was held, where the publication was to be for ten successive days and the publication was omitted on two Sundays occurring within the time, that the publication was sufficient. The court said: “ ‘ Ten successive days’ means publication on ten successive days when the paper can be published without the publisher running the risk of being indicted for a violation of the Sunday statute of the State.” And such is the holding in Mexico v. Lakenan, 129 Mo. App. 180.
[300]*300It was shown that the paper was not published on Sundays or on the Fourth of 'July. As the Fourth of July was a holiday under the statute, and the publisher could not compel his employees to work on that day, we see no good reason why the same rule should not govern as that applied to Sundays.
As the time when the work should begin was left to the determination of the engineer, defendant asserts that it operated in indefinitely delaying the completion of the work beyond a reasonable time.
A city council cannot delegate to the city engineer the power to extend the time for the completion of a contract for street improvement. [Childers v. Holmes, 95 Mo. App. 154; McQuiddy v. Brannock, 70 Mo. App. 535; Ayers v. Schnohl, 86 Mo. App. 349.] But it is held that such a provision in a contract of this kind was not an attempt to delegate a legislative duty to the city engineer to delay the beginning and completion of the improvement beyond a reasonable time from the approval of the ordinance. [Halsey v. Richardson, 139 Mo. App. 157, and cases cited.]
It is contended that the contract and specifications are not in conformity to the preliminary resolution because it provided for the construction of a worthless and unserviceable gutter. If there was a difference between the resolution and the specifications in the ordinance and contract as to the work and material that went into the construction of the gutter, the ordinance was void, and the tax bill invalid. [City of Poplar Bluff v. Bacon, supra, and cases cited.] But it does not appear that the provision in the ordinance was a departure from the resolution. The latter provided for grouting without further specifications, and it was left to the council to provide the specifications. If the specifications in the ordinance were faulty and not reasonably suitable for the purpose, it was not the fault of the contractor, in the absence of fraud or collusion. He was bound by' his contract to conform to [301]*301the provisions of the ordinance, otherwise the tax hills would be invalid. The discretion was vested in the council to provide the specifications for the construction of the gutter, and it was not for the contractor to dictate to the council the method of doing the work. It is said, substantially, where the ordinance is valid' in its general scope, and does not show on its face fraud or caprice in its enactment, and is suitable to the subject-matter to which it is applied, the fact that it is inapplicable to defendant’s property and imposed a burden on him, without any corresponding benefits to him or his community, cannot for the first time be interposed as a legal defense in a suit on a tax bill for work done under the ordinance. [Herman v. Ring, 85 Mo. App. 235.] “It would be unjust to a contractor who has completed an improvement in full compliance with a contract awarded him by the board of aldermen, which is within the general powers conferred upon it, to refuse payment for the simple reason that the courts may conclude that the means or methods adopted by the hoard were not the best or cheapest.” [Warren v. The Barber Pav. Co., 115 Mo. 572, and cases cited.]
The court, in instruction No. 4 given for plaintiff, undertook to instruct the jury as to the meaning of the word “sand” as used in the contract. The plaintiff was also permitted to introduce evidence as to the technical meaning of “sand.”
A construction of the meaning of the language of a contract, as a general- rule, is a matter for the court. The word “leg” has a well-defined common meaning and should not be controlled by the meaning placed on it by specialists. [Rogers v. Modern Brotherhood of America, 131 Mo. App. 353.] In ordinary parlance, we all understand what is meant by the word “sand,” that is, a composition in which sand predominates. But when it comes to apply the term to ingredients usedfor building purposes, such as plastering or concrete, it should and does have a technical meaning, because [302]*302sand taken from different deposits contains different proportions of other matter such as dirt and stone. [Snoqualmi v. Moynihan Co., 179 Mo. 629.] In such cases, the custom fixing the standard of the quality of a thing’ prevails. [Evans v. Western Bros. Mfg. Co., 118 Mo. 548.] We do not think the instruction was a ; comment on the testimony.
It is urged that the court erred in placing the ultimate burden of proof upon the defendant. The following cases are referred to in support of this contention: Cushing v. Powell, 130 Mo. App. 576; Chillicothe v. Henry, 136 Mo. App. 468; Poplar Bluff v. Bacon, supra; Fruin v. Meredith, 145 Mo. App. 586. In Cushing v. Powell, supra, where the question was one of pleading, it is held that, where the declaration counts on a tax bill, a general denial admits any evidence which may show that the necessary preliminary proceedings never ripened .into a valid tax bill; and the provision of the statute maldng the tax bill itself prima facie evidence of its validity cannot affect the rule.” And such is the holding in Chillicothe v. Henry, supra, and Poplar Bluff v. Bacon, supra. The other cases cited have no application.
On the other hand, it is held that a tax bill is prima facie evidence of the regularity of the proceeding and the liability of the property to be charged, and the burden is upon defendant to overcome the prima facie effect. [Excelsior Springs v. Ettenson, 120 Mo. App. 215; Savings Bank v. Ridge, 183 Mo. l. c. 518; Moberly v. Hogan, 131 Mo. 19; State ex rel. v. Phillips, 137 Mo. 259.] The principle seems to be well settled in this State.
Many other errors are insisted on by the appellant, but the most of them are unimportant, and others have been so often determined by the appellate courts that it is useless to discuss them. The cause was well tried.
[303]*303The judgment provides that it shall hear eight per cent interest. This is error. It only bears six per cent. But, as the matter was not called to the attention of the court in the defendant’s motion for a new trial, the cause should not he reversed, but the judgment modified in that respect. [Boonville v. Stephens, 141 S. W. 1111.] The judgment is modified so that it bears six per cent interest from date of rendition and the cause is affirmed.
All concur.