Colorado § 24-70-218 Attorney general to bring action, when

Colorado Statutes

§ 24-70-218 — Attorney general to bring action, when

Colorado·Title 24 Government·Art. Publication of Legal Notices and Public Printing

If any person making
any bid or proposal under this part 2 fails or refuses to enter into a contract
pursuant to the terms of his or her bid or proposal within the time mentioned in his
or her bond presented with such bid or proposal or fails to fulfill his or her contract
or if there is any unreasonable delay in performing the things required under the
terms of such contract, it is the duty of the executive director of the department of
personnel to notify the attorney general of the state, who shall at once bring suit on
the bond of such contractor against such contractor and his or her sureties and
shall prosecute the same to judgment and final execution.

Free access — add to your briefcase to read the full text and ask questions with AI

If any person making
any bid or proposal under this part 2 fails or refuses to enter into a contract
pursuant to the terms of his or her bid or proposal within the time mentioned in his
or her bond presented with such bid or proposal or fails to fulfill his or her contract
or if there is any unreasonable delay in performing the things required under the
terms of such contract, it is the duty of the executive director of the department of
personnel to notify the attorney general of the state, who shall at once bring suit on
the bond of such contractor against such contractor and his or her sureties and
shall prosecute the same to judgment and final execution.

Colorado § 24-70-218 (Attorney general to bring action, when) — published by Counsel Stack Legal Research, free access to 12M+ legal documents.

Legislative History

Source: L. 37: p. 956, � 21. CSA: C. 130, � 86. CRS 53: � 109-2-20. C.R.S. 1963: � 109-2-18. L. 81: Entire section amended, p. 1295, � 29, effective January 1, 1982. L. 96: Entire section amended, p. 1528, � 81, effective June 1.