MEMORANDUM
DALZELL, District Judge.
On May 30, 2008, Sunlight Electrical Contracting Co., Inc. (“Sunlight”), brought this case in the Court of Common Pleas of Philadelphia County, Pennsylvania. Notice of Removal, Ex. B. Sunlight, a construction subcontractor, sought $1,034,581.80 for alleged non-payment of fees for construction services it provided to the defendants.
The defendants removed to this Court, asserting federal question jurisdiction on the basis of 28 U.S.C. § 1331 because plaintiffs claims included a claim for civil RICO under 18 U.S.C. § 1964(c). Notice of Removal at 1. Sunlight invokes this Court’s supplemental jurisdiction over its state law claims pursuant to 28 U.S.C. § 1367.
In January of 2009 defendants 23S23 and CHC LP filed a third-party complaint against Hunter Roberts Construction Group, Inc. alleging that to the extent 23S23 and CHC LP are liable to Sunlight for nonpayment related to Sunlight’s work on one of the construction projects, located in Philadelphia at 23 South 23rd Street, such liability arose out of the errors of Hunter Roberts, the construction manager for that project. Third Party Comp. ¶¶ 33-39. 23S23 and CHC LP thus sought indemnification from Hunter Roberts on those claims. Id. at ¶¶ 63-64.
[395]*395Discovery in the case closed in September of 2011, and the parties filed a flurry of motions, including Sunlight’s motion to amend its complaint.1 On April 24, 2012, we granted Sunlight’s motion to amend in part. Sunlight promptly filed an amended complaint in which it reduced the scope of the action. While Sunlight, in its original complaint, sought damages based on alleged nonpayment for work it performed at 23 South 23rd Street, 400-414 Walnut Street, 1930-34 Chestnut Street, and 1700 Walnut Street, its amended complaint seeks damages only for nonpayment on the 23 South 23rd Street project.
The'complaint as amended seeks damages from John Turchi, Jr., Turchi, Inc., Carriage House Condominiums, L.P. (“CHC LP”), Carriage House Condominiums, G.P., Inc. (“CHC GP”), and 23S23 Construction, Inc. (“23S23”). Sunlight asserts claims for breach of contract and violations of the Pennsylvania Contractor and Subcontractor Payment Act (“CAS-PA”), 73 Pa. Stat. Ann. §§ 501 et seq. against 23S23 (Count I), Am. Comp. ¶¶ 47-54; a claim for breach of contract/implied contract and CASPA violations against Turchi, Inc., CHC LP, and CHC GP for nonpayment of invoices (Count II), Am. Comp. ¶¶ 55-67; the same claims against CHC LP, CHCH GP, Turchi, Inc., and 23S23 for nonpayment of invoices and nonpayment of costs incurred after the end of the contractual period (Count III), Am. Comp. ¶¶ 68-76; claims of unjust enrichment against Turchi, Inc., CHC LP, and CHC GP for nonpayment of costs incurred when Sunlight customized two units at 23 South 23rd Street (Count IV), Am. Comp. ¶¶ 77-83; and claims against John Turchi, Jr. for violations of the Racketeer Influenced and Corrupt Organizations Act, 18 U.S.C. §§ 1961-1968 (“RICO”) (Count VI), Am. Comp. ¶¶ 116-144. Sunlight also brings a claim of “Piercing the Corporate Veil; Alter Ego; Fraud” against John Turchi, Jr. (Count V), Am. Comp. ¶¶ 84-115, and asserts an alter ego theory against Turchi, Inc. in Counts II and III.
Before us now are two motions for summary judgment. Defendants John Turchi, Jr., Turchi, Inc., CHC LP, and CHC GP2 (“defendants”) move for partial summary judgment on Sunlight’s amended complaint seeking judgment in their favor on the veil piercing claims at Counts II, III, and V, and on Sunlight’s civil RICO claim at Count VI. Third-party defendant Hunter Roberts Construction Group, LLC (“Hunter Roberts”) moves for summary judgment on the third-party complaint. We first consider- the defendants’ motion for summary judgment on the RICO claim because this claim constitutes the sole basis for our original jurisdiction.
I. Defendants’ Motion for Summary Judgment on Sunlight’s RICO Claim
Under Fed.R.Civ.P. 56(a), “[t]he court shall grant summary judgment if the [396]*396movant shows that there is no genuine dispute as to any material fact and the movant is entitled to judgment as a matter of law.” A party opposing a motion for summary judgment “must set forth specific facts showing that there is a genuine issue for trial.” Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 248, 106 S.Ct. 2505, 91 L.Ed.2d 202 (1986) (quoting Fed.R.Civ.P. 56(e)). We will thus begin by reviewing the facts with regard to the RICO claim in Sunlight’s amended complaint.3
A. Factual Background
We rehearse the facts in detail so that we may apply the scrutiny needed to determine whether the facts reveal the requisite deceit to support Sunlight’s civil RICO claim, or, instead, whether they merely suggest a breach of contract.4
Sunlight Electrical Contracting Co., Inc. is an electrical design and construction subcontractor. Am. Comp. ¶ 15. On February 25, 2004, Turchi incorporated 23S23, Inc., CHC LP, and CHC GP in Delaware. Am. Comp. ¶¶ 130-31; Ans. ¶ 86 (admitting that the entities were formed in Delaware on that date). CHC GP is the general partner of CHC LP. Ans. to Am. Comp. ¶ 8.
When Sunlight and the defendants began working together on the 23 South 23rd [397]*397Street project, Sunlight had already worked on four projects for Turchi. In 1999 Sunlight began working on a Turchi development at 1700 Walnut Street. Def. Mem. at 18. In 2000, Sunlight worked on a project at 1600 Sansom Street. Michael DiSandro Dep., Pl. Br. in Opp. Ex. 56 at 51:18-22. In 2001, Sunlight began work on a project at 400 Walnut Street. Pl. Br. in Opp. at 36. In 2002, Sunlight began work on a project at 1930-34 Chestnut Street. Id. All of those projects were in Philadelphia.
For the project at 400 Walnut Street, Sunlight claims that in August of 2001 Turchi put forward “Walnut Construction” as the “owner” and caused Walnut Construction to enter a contract with Sunlight for Sunlight to perform electrical work at 400 Walnut Street. Pl. Br. in Opp. at 34. Sunlight avers that the owner was in fact 400 Walnut Associates, L.P. Am. Comp. ¶¶ 113-114. Walnut Construction did not have any assets of its own.5 Turchi Dep. in In re: 23S23 Construction, Inc., No. 09-12652, Bankr.E.D. Pa., at 103:10-13, Pl. Br. in Opp, Ex. 58. Pursuant to that contract, Sunlight was to receive $827,000, Am. Comp. ¶ 113, and Sunlight claims that it is still owed $203,151.68 from that amount. Pl. Initial Disclosures, Pl. Br. in Opp., Ex. 57.
Sunlight avers that it entered into contracts with Affordable Fire Protection, Inc. and Walnut Construction to perform work on 1930-34 Chestnut Street, Am. Comp. ¶¶ 117, 121, and it claims it is owed $261,585.58 for that work. Dec. 17, 2007 Letter, Pl. Br. in Opp., Ex. 57.
Sunlight also claims that Turchi failed to pay it in full for its work at 1700 Walnut Street, for which Sunlight avers that it is owed $152,333.32. Pl. Br. in Opp., Ex. 57.
Six of the other subcontractors for those projects are currently suing defendants for nonpayment. PI. Br. in Opp. at 33; Subcontractors’ Complaints, Pl. Br. Ex. 6-N-6-S, Ex. 60.
Sunlight received full payment for its work on the 16th Street and Sansom Street projects. See DiSandro Dep., Pl. Br. in Opp. Ex. 56 at 48:18-23.
With regard to Turchi’s statements about payment on the earlier projects, Sunlight claims that Turchi “never told Sunlight ... he did not intend to pay them in full; to the contrary, Turchi always expressed his intention to pay them.” Pl. Br. in Opp. at 35. In support of this proposition, Sunlight points to the deposition of Michael DiSandro, Sunlight’s President. See Affidavit of Michael DiSandro, Pl. Br. in Opp., Ex. 9, ¶ 1. In DiSandro’s deposition he testified that, “[Turchi] kept saying to me, ‘I’m going to get you paid. I’m going to get you paid.’ But, you know, it was never said [sic ] definitely answered.” DiSandro Dep., Pl. Br. in Opp. Ex. 56 at 44:6-9. DiSandro said he spoke with Turchi more than ten times regarding the payment for 1700 Walnut Street, id. at 45:6-8, and DiSandro described Turchi’s statements as follows: “He said, ‘Don’t worry about it. I’m going to pay you.’ But, you know, specifically, he always said — he always blamed somebody else, he didn’t have any money, he was short, overrun on a job, he had to refinance, all different — different aspects.” Id. at [398]*39846:17-23, see also id. at 48:25-49:9 (describing similar representations).
Furthermore, with regard to Turchi’s representations about payment for the 1700 Walnut Street project, DiSandro testified that Turchi told him “that he was trying to refinance on 1700 and he needed money to be able to take care of the old bills. And eventually, he did do that. Later on he send me check [sic], like, two, three years later for that particular job.” Id. at 49:23-50:5.
With regard to 400 Walnut Street, DiSandro testified, “On 4th and Walnut in particular, he said he was going to try to sell the penthouse. As soon as he make the sale on it, he was going to pay me for it. But this stuff never come about.” Id. at 78:20-24. At the end of 2003, Sunlight still believed Turchi owed it money for 400 Walnut and 1700 Walnut, see id. at 80:17-18.
DiSandro testified that he told Turchi that he was hesitant to work on the 23 South 23rd Street project because of Turchi’s failure to make full payment on projects he had worked on in the past. DiSandro Aff., PI. Br. in Opp. Ex. 9, ¶ 2. DiSandro said that after he expressed this concern Turchi paid Sunlight $100,000 toward the balance due on 1700 Walnut Street, id. at ¶ 3.
On October 27, 2004, Sunlight provided a written proposal to Turchi, Inc. offering to work on the electrical design and construction for the renovation of 23 South 23rd Street for $1,782,400. Turchi, Inc. accepted the proposal on November 5, 2004. See November 5, 2004 Letter, PL Br. in Opp. Ex. 59. On February 2, 2005, Sunlight entered into a written contract with 23S23 in which Sunlight agreed to perform electrical services for a guaranteed maximum price of $1,782,400. Design/Build Subcontract Agreement, Am. Comp. Ex. A ¶ 2(d). According to the first paragraph of the agreement, CHC LP, the owner, had engaged 23S23 to be the construction manager for this project. Am. Comp. Ex. A ¶ 1.
At the time the parties entered into the contract, 23S23 had no assets, see, Pl. Br. in Opp. at 15; Aug. 24, 2011 Turchi Dep., Pl. Br. Ex. 10 at 130:20-131:1. From 2004-200723S23 had only “cash” as an asset, and its balance at the start of each year was never more than $100. 23S23 Construction, Inc. Balance Sheets, Pl. Br. in Opp. Ex. 11. Between January 2005 and January 2007, Turchi caused CHC LP, 23S23, Inc., and Turchi, Inc. to wire funds from the construction lender among and between each other and to Turchi himself. Pl. Br. in Opp. at 17-22; Pl. Br. Ex. 6-E-H; 12-15; 17-19, 39, 43.
The instant dispute arises from nonpayment for work on the 23 South 23rd Street project in four categories. The first involves nonpayment of contractual fees, as established in the contract, and, according to Sunlight, through later “change orders.” The second stems from “time and material” work (“T & M Work”), or work which was not included in the contract’s scope, but which Sunlight performed on a “time and material” basis. The third category is costs Sunlight incurred through delayed completion of the project, and the fourth involves costs Sunlight incurred in customizing two units at 23 South 23rd Street.
Turning to the first category, from November of 2004 until October of 2007, Sunlight performed the work described in the contract. Am. Comp. ¶ 19. Sunlight submitted invoices for its work according to the following schedule: from November, 2004 through April, 2005, Sunlight submitted six invoices to Turchi, Inc. From May, 2005 through April, 2006, Sunlight submitted twelve invoices to CHC LP. From May, 2006 through May, 2007 Sunlight [399]*399submitted seven invoices to Turchi, Inc. Am Comp. ¶¶ 20-24.
Sunlight alleges that the total amount due for the twenty-five invoices it submitted from November, 2004 through May, 2007 — -which included the original contractual amount and change orders — comes to $2,054,834. Am. Comp. ¶ 50; Pl. Br. in Opp. at 32 n. 22; Pl. Br.-in Opp., Ex. 57 at 12. Sunlight alleges that it has been paid $1,801,212.85 to date. Am. Comp. ¶ 51; Pl. Br. in Opp. Ex. 57 at 12. Sunlight does not provide evidence in support of this contention other than a statement contained in its own Initial Disclosures. Defendants counter that as of March of 2007 they had paid Sunlight $1,884,388.81. See Def. Br. in Supp. of Mot. at 9 n. 13. In support of their contention, defendants point to Exhibit 3 of their motion for summary judgment, a “Check Register” belonging to CHC,6 see Def. Mem. at 9 n. 13. Based on its contention that it received only $1,801,212.85, Sunlight argues that it is still owed $253,620 under the contract. Even according to defendants’ account, if Sunlight is correct that the total contract amount had been raised to $2,054,834 through change orders, Am. Comp. ¶ 50, defendants would still owe Sunlight $170,445 under the contract.
Sunlight next contends that it is owed money for work it performed on a “time and material basis” in May of 2004 and August of 2007. Am. Comp. ¶ 30. , Sunlight alleges that “[a]ll of the extra and additional work performed and completed by Sunlight on the Project was at the direction and with the knowledge and approval of one or more authorized representatives of 23S23, Inc., or Hunter Roberts, or Turchi, Inc., including Turchi, or CHC LP, or CHC GP.” Am. Comp. ¶ 26. Sunlight submitted a total of twenty-seven invoices for this work: two to John Turchi, Jr., twenty to Turchi, Inc., and five to Hunter Roberts7, including one with a copy to 23S23. Am. Comp. ¶ 33. Sunlight refers to this work as “T & M Work”, and it makes contradictory assertions regarding the payment it received for this aspect of the job. Sunlight first asserts that “[t]o the extent Sunlight received payment on the invoices- for T & M Work, the payments were made by CHC LP,” Am. Comp. ¶ 34, but it later claims that it was never paid anything for the T & M Work, for which it was owed $74,331.08. Am. Comp. ¶¶ 70-72.
The contract provided that Sunlight was to complete the work by November of 2005, but the project was not finished by then, and so on November 7, 2005, CHC LP agreed to extend the completion date to April of 2006 and increase the amount of the contract by $52,468.65 for Sunlight’s additional costs. Am. Comp. ¶¶ 36-38. Ultimately, Sunlight did not complete the project until October of 2007 and it incurred additional labor costs of $41,367 between May 1, 2006 and October 2, 2007. Am. Comp. ¶¶ 40-41. Sunlight has not received any payment for those additional labor costs. Am. Comp. ¶ 42.
Sunlight alleges, and defendants do not dispute, that at the direction of “one or more authorized representatives, of Turchi, Inc., Hunter Roberts, and CHC LP and CHC GP,” Am. Comp. ¶ 78, it provided customization services for two units at 23 South 23rd Street — Units 3C and 4L — for which it has received no payment. Am. [400]*400Comp. ¶¶ 44^16. Sunlight alleges that the total cost of these customizations was $4,387.00. Pl. Initial Disclosures, Pl. Br. in Opp. Ex. 57 at 13.
Sunlight alleges that as of October, 2007, it was owed a total of $418,705.08 for work it had completed on Turehi’s behalf, Am. Comp. ¶ 136, and on December 17, 2007, Turchi signed a letter as president of 23S23 Construction, Inc. stating that “delays and cost over-runs” had affected the completion of the renovation and the unit sales, and asserting that Hunter Roberts was liable to Sunlight. Am. Comp. ¶ 138. Dec. 17, 2007 Letter, Pl. Br. in Opp. Ex. 61. According to Sunlight, when Turchi wrote the letter, he had transferred more than $2,000,000 of construction mortgage loan funds from 23S23, Inc. and CHC LP to Turchi, Inc. and then from Turchi, Inc. to himself and entities he owns and controls. Pl. Br. in Opp. 21-23; Account Statements, Pl. Br. in Opp. Ex. 6-G., 6-I-J, 15,17, and 19-43.
Defendants contend that the claim that Sunlight was owed $418,706 in October of 2007 is inconsistent with the claim Sunlight made in its original complaint that it had been paid $1,866,761. Def. Mem. at 7, 9 n. 13. Sunlight’s admissions in its original complaint do not bind it, and although Sunlight alleges in its amended complaint that CHC LP has paid it $1,801,212.85 toward the contract fees to date, Am. Comp. ¶ 51, that averment does not state when CHC LP paid Sunlight and so it is not necessarily inconsistent with Sunlight’s contention that it was owed a certain amount in October of 2007. But in light of the Check Register defendants introduce, if Sunlight had been paid $1,884,389 in March of 2007 — even accepting its highest estimates for the amounts owed for the T & M Work, the labor costs due to delay, and customization costs — Sunlight would only be owed $290,530.28. Nevertheless, the precise amount Sunlight was owed is not material to its claim that Turchi’s December 17, 2007 statement was misleading in explaining why Sunlight had not been paid.
B. The Civil RICO Standard
Count VI of the Amended Complaint alleges violations of RICO, 18 U.S.C. §§ 1961-1968. Section 1964(c) affords a private right of action for those injured by violations of § 1962. The complaint does not specify which provision of § 1962 Sunlight alleges Turchi violated. In its RICO Case Statement, Sunlight represented that Turchi violated §§ 1962(a), (b), (c), and (d). Case Stmt. ¶ 1. However, in its Brief in Opposition to the defendants’ motion, Sunlight now says that it brings its claim to vindicate a violation of § 1962(c) only. Pl. Br. in Opp. at 44. Sunlight cannot, nor does it attempt to, demonstrate that it suffered an investment injury sufficient to sustain a claim under § 1962(a), see, e.g., Brittingham v. Mobil Corp., 943 F.2d 297, 303 (3d Cir.1991) (a claim under section 1962(a) “requires that a plaintiffs injury be caused by the use or investment of income in [an] enterprise”), nor does it attempt to make a claim under §§ 1962(b) or (d). We will therefore accept the argument Sunlight advances in its opposition to the motion for summary judgment,8 and we will construe Sunlight’s Amended Com[401]*401plaint as making a claim under 18 U.S.C. § 1962(c).
Section 1962(c) proscribes “any person employed by or associated with any enterprise engaged in, or the activities of which affect, interstate or foreign commerce, [from] conducting] or participating], directly or indirectly, in the conduct of such enterprise’s affairs through a pattern of racketeering activity or collection of unlawful debt.” In order to state a claim under § 1962(c), the plaintiff who suffers RICO injury to his business or property must allege “(1) conduct (2) of an enterprise (3) through a pattern (4) of racketeering activity.” Lum v. Bank of America, 361 F.3d 217, 223 (3d Cir.2004) (citing Sedima, S.P.R.L. v. Imrex Co., 473 U.S. 479, 496, 105 S.Ct. 3292, 87 L.Ed.2d 346 (1985)).
a. “Enterprise” Allegations
In order to sustain a claim under § 1962(c), a plaintiff must allege activity by both a person and an enterprise. See, e.g., Jaguar Cars, Inc. v. Royal Oaks Motor Car Co., Inc., 46 F.3d 258, 262 (3d Cir.1995).
Sunlight alleges that the “enterprise” in question is each of the corporate defendants — Turchi, Inc., CHC LP, CHC GP, and 23S23 — individually and collectively. Am. Comp. ¶ 110.
In determining whether a plaintiff has adequately alleged activity by both a person and an enterprise, our Court of Appeals applies a distinctiveness requirement whereby “the ‘person’ subject to liability cannot be the same entity as the ‘enterprise.’ ” Jaguar Cars, 46 F.3d at 262 (quoting Hirsch v. Enright Refining Co., 751 F.2d 628, 633 (3d Cir.1984)).
Our Court of Appeals has interpreted this distinctiveness requirement as meaning that although “a claim simply against one corporation as both ‘person’ and ‘enterprise’ is not sufficient,” a complaint “alleging conduct by officers or employees who operate or manage a corporate enterprise satisfies this requirement.” Id., at 268. Moreover, in Jaguar Cars the Court quoted Judge Posner with approval on this point, particularly his assessment that it “[t]he only important thing is that [the enterprise] be either formally (as when there is incorporation) or practically (as when there are other people besides the proprietor working in the organization) separable from the individual.” Id. at 269 (quoting McCullough v. Suter, 757 F.2d 142, 144 (7th Cir.1985)).
Though Sunlight argues in its opposition to the summary judgment motion that “the enterprise consisted of Turchi, Turchi, Inc., CHC LP, CHC GP, 23S23, Inc., Walnut Construction, 1930-34 Associates, L.P. and 1700 Associates, L.P.,” PL Br. in Opp. at 32, the amended complaint is more precise: “[e]ach of the corporations and partnerships named in this civil action constitutes an ‘enterprise’ within the meaning of 18 U.S.C. § 1962, and the corporations and partnerships, as dominated, controlled and operated by Turchi for his personal benefit, collectively constitute an ‘enterprise’ within the meaning of 18 U.S.C. § 1962.” Am. Comp, at second ¶ 110 on pg. 23.
Defendants do not challenge the sufficiency of Sunlight’s “enterprise” allegations, and we accept Sunlight’s description that the enterprise consists of legally incorporated corporations through which Turchi conducted business. The civil RICO claim does not fail on this ground.
b. Mail And Wire Fraud
The statute defines “racketeering activity” as any act which is indictable under a set of federal and state statutes, including 18 U.S.C. § 1341 (regarding mail fraud) and 18 U.S.C. § 1343 (regarding wire [402]*402fraud). A “pattern of racketeering activity” requires proof that the defendant has committed at least two acts of racketeering within a ten-year period. § 1961(5). See also, e.g., Rotella v. Wood, 528 U.S. 549, 552, 120 S.Ct. 1075, 145 L.Ed.2d 1047 (2000).
Here, Sunlight alleges that John Turchi engaged in a pattern of racketeering activity consisting of mail fraud and wire fraud. Am. Comp. ¶ 141. The elements of an offense under RICO are identical whether the case is civil or criminal, see, e.g., Eisenberg v. Gagnon, 564 F.Supp. 1347, 1353 (E.D.Pa.1983). The elements of mail fraud and wire fraud are: “(1) the existence of a scheme to defraud; (2) the participation by the defendant in the particular scheme with the specific intent to defraud; and (3) the use of the United States mail or of wire communications in furtherance of the fraudulent scheme”, United States v. Syme, 276 F.3d 131, 142 n. 3 (3d Cir.2002) (see also Walter v. Palisades Collection, LLC, 480 F.Supp.2d 797, 803 (E.D.Pa.2007) (applying the Syme standard)).
The offense requires proof of specific intent, United States v. Pearlstein, 576 F.2d 531, 535 (3d Cir.1978), and this “may be found from a material misstatement of fact made with reckless disregard for the truth”, United States v. Hannigan, 27 F.3d 890, 892 n. 1 (3d Cir.1994). The scheme “must involve some sort of fraudulent misrepresentations or omissions reasonably calculated to deceive persons of ordinary prudence and comprehension.” United States v. Pearlstein, 576 F.2d 531, 535 (3d Cir.1978), see also Palisades, 480 F.Supp.2d at 803. As the Supreme Court has explained, “The words ‘to defraud’ in the mail fraud statute have the common understanding of wronging one in his property rights by dishonest methods or schemes, and usually signify the deprivation of something of value by trick, deceit, chicane or overreaching.” Carpenter v. United States, 484 U.S. 19, 27, 108 S.Ct. 316, 98 L.Ed.2d 275 (1987) (internal quotations omitted).
Finally, the use of the mail or wires need not be essential to the scheme, Schmuck v. United States, 489 U.S. 705, 710, 109 S.Ct. 1443, 103 L.Ed.2d 734 (1989). Instead, that use may be merely incident to an essential part of the scheme. Id.
The Supreme Court has held that “RICO is to be read broadly,” Sedima, S.P.R.L. v. Imrex Co., 473 U.S. 479, 497, 105 S.Ct. 3275, 87 L.Ed.2d 346 (1985). But our Court of Appeals has cautioned that because of the “relative ease with which a plaintiff may mold a RICO pattern from allegations that, upon closer scrutiny, do not support it,” Kolar v. Preferred Real Estate Investments, Inc., 361 Fed.Appx. 354, 363 (3d Cir.2010) (internal quotations omitted), we must carefully scrutinize RICO claims. Id.
The essence of Sunlight’s mail and wire fraud allegation is that Turchi engaged in a scheme to defraud subcontractors by inducing them to perform work for which he never intended to pay them in full. PI. Br. in Opp. at 33. Sunlight alleges that Turchi used the United States mail and wires through the “transmittal of checks in partial payment for work performed, the transmittal of written communications requesting payments and denying payments for work performed and completed, and numerous wire transfers of construction mortgage funds from 23S23, Inc. and CHC LP into and out of Turchi, Inc.” in order to further “his fraudulent scheme to obtain goods, labor, material, work and services for construction of the 23rd Street Project without paying therefor”, Am. Comp. ¶ 141.
[403]*403c. The RICO Statute of Limitations
As a threshold matter, Turehi contends that the statute of limitations bars Sunlight’s RICO claim. As noted, civil RICO claims have a four-year limitations period, Agency Holding Corp. v. Malley-Duff & Associates, Inc., 483 U.S. 143, 152-56, 107 S.Ct. 2759, 97 L.Ed.2d 121 (1987). That period begins to run from the date the plaintiff knew or should have known of the injury. Rotella v. Wood, 528 U.S. 549, 558, 120 S.Ct. 1075, 145 L.Ed.2d 1047 (2000) (rejecting the “injury and pattern discovery rule” and holding that the statute of limitations for civil RICO claims accrues at “the point of injury or its reasonable discovery”).
Turehi argues that Sunlight first suffered injury from the alleged scheme to defraud on March 2, 2000 when Sunlight was working with Turehi on an earlier project (1700 Walnut), and the payment on Sunlight’s “final Application for Payment” on that project became overdue. Def. Mem. at 18.
Sunlight responds that it only seeks to recover damages for alleged RICO violations connected with the 23 South 23rd Street project. PI. Br. in Opp. at 50. Sunlight completed its work on that project in October of 2007, and so it contends that its nonpayment injury occurred then — well within the four-year statute of limitations preceding its May 30, 2008 filing in state court. Id. Sunlight also argues that the pattern of racketeering began during earlier projects for which Sunlight provided subcontracting services to Turehi and continued through the 23 South 23rd Street project — including the act of sending the allegedly fraudulent December 17, 2007 letter. Am. Comp. ¶ 142. Sunlight urges us to adopt the “separate accrual” rule according to which “the commission of a separable, new predicate act within a 4-year limitations period permits a plaintiff to recover for the additional damages caused by that act.” Klehr v. AO. Smith Corp., 521 U.S. 179, 190, 117 S.Ct. 1984, 138 L.Ed.2d 373 (1997).9
[404]*404The Supreme Court in Klehr appears to have accepted the validity of the separate accrual rule, and we find no evidence that it barred the use of the rule in Rotella. We will therefore apply the separate accrual rule, under which Sunlight’s RICO claim for the injuries it allegedly suffered relating to the project at 23 South 23rd Street are not time-barred.
C. Civil RICO Compared With Breach of Contract Actions
Courts have distinguished breach of contract claims from civil RICO claims based on mail and wire fraud because unlike breach of contract actions, mail and wire fraud claims require that the defendant has acted in a deceitful manner. Though the scheme to defraud “need not be fraudulent on its face, [it] must involve some sort of fraudulent misrepresentations or omissions reasonably calculated to deceive persons of ordinary prudence and comprehension.” United States v. Pearlstein, 576 F.2d 531, 535 (3d Cir.1978) (internal quotations omitted); see also, e.g., Kehr Packages, Inc. v. Fidelcor, Inc., 926 F.2d 1406, 1415 (3d Cir.1991).
We must therefore determine whether Turchi’s behavior involved “fraudulent misrepresentations or omissions reasonably calculated to deceive persons of ordinary prudence and comprehension” or whether the allegations constitute only a breach of contract action.
Our Court of Appeals has clarified that a scheme to defraud need not include an explicit false representation, see, e.g., United States v. Frankel, 721 F.2d 917, 921 (3d Cir.1983). But while “[t]he scheme need not involve affirmative misrepresentation, [ ] the statutory term ‘defraud’ usually signifies ‘the deprivation of something of value by trick, deceit, chicane or overreaching.’ ” Kehr, 926 F.2d at 1415 (quoting McNally v. United States, 483 U.S. 350, 358, 107 S.Ct. 2875, 97 L.Ed.2d 292 (1987)).
Courts have repeatedly found the element of deceit missing in breach of contract claims. For example, in Kolar as here the plaintiff claimed that defendants had diverted money they owed him to other defendant-controlled entities. Our Court of Appeals affirmed the district court’s dismissal of the RICO claims, finding that “[t]hese allegations set forth disputes sounding in contract. Kolar cannot successfully transmute them into RICO claims by simply appending the terms ‘false’ and ‘fraudulent.’ ” Kolar, 361 Fed. Appx. at 363. Sunlight here makes the cognate allegation against Turchi, ie., that he transferred money to entities he controlled so as to avoid payment.
Indeed, our Court of Appeals has long acknowledged the distinction between breaches of contract and mail and wire fraud that would give rise to a civil RICO action. In Annulli v. Panikkar, 200 F.3d 189, 199-200 (3d Cir.1999), the Court explained that “theft by deception, like a simple breach of contract or intentional interference with contract, is not a predicate act of racketeering activity enumerated in § 1961(1) ... We will not read language into § 1961 to federalize every state tort, contract, and criminal law action.”
Our Court of Appeals in Annulli also explained its reasoning for distinguishing civil RICO claims from common law contract claims:
First, RICO’s list of acts constituting predicate acts of racketeering activity is exhaustive. To read it otherwise would be to usurp the role of Congress in drafting statutes. Second, if garden-variety state law crimes, torts, and contract breaches were to constitute predicate acts of racketeering (along with mail and wire fraud), civil RICO law, which is already a behemoth, would [405]*405swallow state civil and criminal law whole. Virtually every litigant would have the incentive to file their breach of contract and tort claims under the federal civil RICO Act, as treble damages and attorney’s fees would be in sight. We will not read language into § 1961 to federalize every state tort, contract, and criminal law action.
Id., at 200 (internal citations omitted). Other courts have reached similar conclusions. See, e.g., United States v. Kreimer, 609 F.2d 126, 128 (5th Cir.1980) (“the statute does not reject all business practices that do not fulfill expectations, nor does it taint every breach of a business contract”); Gagliardi v. Ward, 967 F.Supp. 67, 68-69 (N.D.N.Y.1997) (nonpayment under a contract does not give rise to a RICO claim); Fuce v. West, No. 12-0874, 2012 WL 3046235, at *3 (E.D.Pa. July 26, 2012) (finding that “[djespite [plaintifffs efforts to transform [defendant’s conduct into criminal offenses, it is clear that he alleges a breach of contract cause of action”, where plaintiff alleged that defendant had paid him less than he had agreed to in an employment contract).
Here, the essence of Sunlight’s allegation is that Turchi repeatedly failed to pay it the money it was owed according to their contracts. As such, Sunlight presents a garden variety breach of contract claim between a developer and contractor. Defendants’ actions do not involve the deceit crucial to be the stuff of a civil RICO claim.
First, Sunlight suggests that it was deceptive of Turchi to enter into contracts with Sunlight and other sub-contractors through no-asset, single-purpose, entities. PI. Br. in Opp. at 47. Sunlight argues that
[B]etween 2001 and 2005, Turchi used entities with no assets to enter into contracts with contractors on the 400 Walnut, 1930-34 Chestnut and 23 South 23rd Street projects, and then prevented those entities from obtaining the construction funds borrowed from the lenders ... He would then use the contracting entities as ‘shields’ that he hid behind claiming they had no money....
Id. But such a practice could only deceive Sunlight if Sunlight believed those entities were, in fact, separate from Turchi — that they were funded and controlled through some other undisclosed source. Instead, as the testimony of Sunlight’s President make pellucid, Sunlight well knew that Turchi was the principal behind all the contracts Sunlight entered into for its projects with him. See, e.g., Michael DiSandro Dep., Pl. Br. in Opp. Ex. 56, at 49:18-25 (explaining that he worked for Turchi on projects at 1700 Walnut Street, 1600 Sansom Street, and 400 Walnut Street); DiSandro Aff., Pl. Br. in Opp. Ex. 9, ¶¶ 2-5 (admitting that Sunlight signed the contract for the 23 South 23rd Street project precisely because Turchi had made a payment toward the 1700 Walnut Street debt).
Moreover, the theory that Turchi deceived Sunlight by making payments on earlier projects to induce Sunlight to work on the 23 South 23rd Street projects only makes sense if Sunlight knew that Turchi was behind 23S23 — the single-purpose entity with which it contracted for that project. If Sunlight believed Turchi was unconnected to 23S23, Turehi’s payment would offer no comfort as to 23S23’s ability to pay.
This second theory of deception — that Turchi promised to pay and made partial payments on earlier projects to induce Sunlight to continue working with him— must also fail.
Defendants argue that “[t]he idea that commercial construction subcontractors unwittingly fell victim to a scheme of serial contract breaches whereby they entered [406]*406into new contracts with their perpetrator, time and time again, over a decade-long period, is inconsistent with reasonable reliance on misrepresentations.” Def. Mem. at 25. We agree. Courts have rejected the argument that behavior such as Turchi’s can give rise to a claim under RICO, reasoning that if a plaintiff-company continues to transact business with someone who has broken contracts in the past, then that plaintiff is not acting as a person of ordinary prudence and comprehension. Such a plaintiff therefore cannot allege the requisite deceit needed to sustain a claim of mail and wire fraud. See, e.g., Ideal Dairy Farms, Inc. v. John Labatt, Ltd, 90 F.3d 737, 747 (3d Cir.1996) (finding no mail or wire fraud where the plaintiff, early in its contractual relationship with the defendant, knew the defendant was charging higher prices than the contract allowed); Lubart v. Riley & Fanelli, P.C., No. 97-6392,1998 WL 398253, at *6 (E.D.Pa. June 22, 1998) (“A person of ordinary prudence and comprehension would not contract with a party who the person believed had fraudulently breached a contract between the parties in the past”).
Sunlight’s claims are thus in the heartland of contract law. No genuine dispute of material fact exists as to whether Turchi deceived Sunlight, as would be necessary to sustain a civil RICO claim. We will therefore grant summary judgment to defendants with regard to Count VI of the Amended Complaint.
II. Remaining State Law Claims and Third-Party Claims
28 U.S.C. § 1367(c)(3) provides that a district court may decline to exercise supplemental jurisdiction over state law claims if it has “dismissed all claims over which it has original jurisdiction”. Our original jurisdiction here is founded solely upon Sunlight’s civil RICO claim against John J. Turchi, Jr., and so we no longer have original jurisdiction over the action. Of the six other suits pending by subcontractors against defendants, four are proceeding in the Philadelphia County Court of Common Pleas, one in the Lehigh County Court of Common Pleas and one in Bankruptcy Court. PI. Br. in Opp. at 33. These cases will likely raise state law questions similar to those at issue in this action. Principles of judicial economy, convenience, and comity thus counsel in favor of dismissal without prejudice of the remaining state law claims.
ORDER
AND NOW, this 18th day of January, 2013, upon consideration of plaintiff Sunlight Electrical Contracting Co., Inc.’s amended complaint (docket entry # 68), defendants’ second motion for partial summary judgment, and their memorandum in support thereof (docket entry # 72), plaintiffs response and brief in opposition thereto (docket entry # 77) defendants’ third party complaint (docket entry # 11), third-party defendant’s motion for summary judgment (docket entry # 73), and defendants’ response in opposition thereto (docket entry # 76), and third-party defendants’ reply thereto (docket entry # 82), and upon the analysis set forth in the accompanying Memorandum, it is hereby ORDERED that:
1. Defendants’ motion for partial summary judgment (docket entry # 72) is GRANTED IN PART;
2. Count VI, the sole federal law claim in the Amended Complaint, is DISMISSED WITH PREJUDICE;
3. The remaining claims are DISMISSED WITHOUT PREJUDICE to their reassertion in the Philadelphia Court [407]*407of Common Pleas;10 and
4. The Clerk shall CLOSE this matter statistically.