(a) For the period from July 1, 2001, to June 30, 2031, or until completion of the UConn 2000 infrastructure improvement program, whichever is later, the university shall have charge and supervision of the design, planning, acquisition, remodeling, alteration, repair, enlargement or demolition of any real asset or any other project on its campuses. (b) (1) The university shall cause to be prepared, proposed construction standards for all projects. The proposed standards shall, subject to applicable law, include, among other things, provisions relating to the quality and type of materials to be used, provisions for safety, fire protection, health and sanitation, provisions for the installation of fixtures, furnishings, equipment, machinery and apparatus, and construction features. (2) Pursuant to such construction standards in effect at such time, the university shall cause to be prepared, within the costs available therefor, the detailed plans and specifications for each project. The university may from time to time modify, or authorize modifications to, such detailed plans and specifications, provided the plans and specifications as so modified shall comply with the construction standards, if any, adopted pursuant to sections 10a-109a to 10a-109y , inclusive, and in effect at the time of the modifications, and the provisions of section 10a-109e are complied with. (3) The university shall identify the scope of work and hire, and contract with persons with the necessary experience and capability to perform such scope of work. (4) The university may contract with a design professional for the design of any project, with a general contractor for the construction of any project; and with one or more prime trade contractors with respect to such construction work if the university determines that to do so will be in the public interest of the state. (c) (1) Any construction contract to which the university is a party may include a provision that the design professional who designed the project, or an architect or professional engineer or construction manager retained or employed specifically for the purpose of supervision, may supervise the work to be performed through to completion and ensure that the materials furnished and the work performed are in accordance with the drawings, plans, specifications and contracts therefor. (2) (A) Except as provided in subparagraph (D) of this subdivision, any total cost basis contract or other contract for the construction of a university project which is estimated to cost more than five hundred thousand dollars, shall be publicly let by the university. The university shall give notice to contractors interested in submitting a project proposal or bid, by posting any such notice on the university web site and on the State Contracting Portal. The notice to contractors shall contain (i) the requirement that contractors be prequalified pursuant to section 4a-100 , or subparagraph (B) of this subdivision, as applicable to such contract, (ii) a statement of the time and place where the responses shall be received, and (iii) such additional information as the university deems appropriate. Upon receipt of such responses, the university shall select any contractor who (I) to the extent required pursuant to the provisions of section 4b-91 , has been prequalified pursuant to section 4a-100 , (II) has shown itself able to post surety bonds required by such contract, (III) has no conflict of interest in the performance of work required by such contract, and (IV) for any such contract that is estimated to cost more than one million dollars, has been prequalified by the university pursuant to subparagraph (B) of this subdivision. (B) For any contract subject to the provisions of subparagraph (A) of this subdivision that is estimated to cost more than one million dollars, the university shall prequalify each contractor by evaluating whether (i) such contractor (I) has demonstrated that it possesses the financial, managerial and technical ability and integrity necessary to faithfully and efficiently perform work for the university in accordance with the requirements set forth in the prequalification application issued by the university, and (II) is responsible and qualified based on its experience with projects similar to that for which the bid or proposal is to be submitted and based on objective written criteria included in the prequalification application issued by the university, and (ii) any subcontractor on the contractor's previous projects, has been in compliance with the provisions of part III of chapter 557 and chapter 558 during the previous five calendar years. The university, in its discretion, may include additional qualification requirements in the notice posted pursuant to subparagraph (A) of this subdivision. (C) The university may issue a confirmation of prequalification for contracts subject to the provisions of this subdivision to any contractor who meets the requirements set forth in subparagraph (B) of this subdivision. Such confirmation of prequalification shall be effective for one year from the date of issuance and, upon receipt of a completed renewal application and any other materials as prescribed by the university, may be renewed for a period not exceeding two years. (D) Notwithstanding the provisions of subparagraph (A) of this subdivision, the board of trustees may approve a total cost basis contract or other contract for the construction of a university project which is estimated to cost more than five hundred thousand dollars that has not been publicly let pursuant to the provisions of said subparagraph (A), provided the board deems the contract to address an emergency. (3) Each bid or proposal shall be kept sealed until opened publicly at the time and place as set forth in the notice soliciting such bid or proposal. The university shall not award any construction contract, including, but not limited to, any total cost basis contract, after public letting, except to the responsible qualified contractor, submitting the lowest bid or proposal in compliance with the bid or proposal requirements of the solicitation document. The university may, however, waive any informality in a bid or proposal, and may either reject all bids or proposals and again advertise for bids or proposals or interview at least three responsible qualified contractors and negotiate and enter into with any one of such contractors that construction contract which is both fair and reasonable to the university. (4) The construction contract, including each total cost basis contract, awarded by the university shall contain such other terms and conditions, and such provisions for penalties as the university may deem appropriate. (5) No payments shall be made by the university on account of any contract for the project awarded by or for the university until the bills or estimates presented for such payment shall have been duly certified to be correct by the university. No payments shall be made from any other fund on account of any contract for any project awarded by or for the university until the bills or estimates presented for such payment shall have been duly certified to be correct by the university. (6) Provision shall be made in each contract to the effect that payment is limited to the amount provided therein and that no liability of the university or state shall and may be incurred beyond such amount. (7) The university shall require, for the protection of the state and the university, such deposits, bonds and security in connection with the submission of bids or proposals, the award of construction contracts and the performance of work as the university shall determine to be appropriate and in the public interest of the state. (8) Any contract awarded by the university shall be a contract with the state acting through the university. (9) (A) The university shall not enter into a construction manager at-risk project delivery contract that does not provide for a maximum guaranteed price for the cost of construction which shall be determined not later than the time of the receipt and approval by the university of the trade contractor bids. Each construction manager at-risk shall invite bids and give notice of opportunities to bid on project elements, by posting any such invitation or notice on the State Contracting Portal. Each bid shall be kept sealed until opened publicly at the time and place as set forth in the notice soliciting such bid. The construction manager at-risk shall, after consultation with and approval by the university, award any related contracts for project elements to the responsible qualified contractor, who shall be prequalified pursuant to section 4a-100 , submitting the lowest bid in compliance with the bid requirements, provided (i) the construction manager at-risk shall not be eligible to submit a bid for any such project element, and (ii) construction shall not begin prior to the determination of the maximum guaranteed price, except (I) for the project elements of site preparation and demolition that have been previously put out to bid and awarded, and (II) for the project elements of site preparation, demolition, public utility installation and connections and building envelope components, including the roof, doors, windows and exterior walls, as provided in subparagraph (B) of this subdivision. (B) Construction may begin prior to the determination of the maximum guaranteed price for the project elements of site preparation, demolition, public utility installation and connections and building envelope components, including the roof, doors, windows and exterior walls, provided (i) the project involves the renovation of an existing building or facility; (ii) the project element or elements involved in such early work have been previously put out to bid and awarded; and (iii) the total cost of construction of the early work does not exceed twenty-five per cent of the estimated cost of construction for the entire project. (C) If such project involves the renovation of an existing building or facility that will be performed in multiple phases while such building or facility remains occupied, the university may enter into a construction manager at-risk project delivery contract that provides for the maximum guaranteed price to be determined for each phase of the project, prior to beginning each such phase, provided each party to the contract complies with all of the requirements of subparagraph (A) of this subdivision, except the timing of the determination of the maximum guaranteed price set forth in subparagraph (A)(ii) of this subdivision. (10) If the university designates a project as suitable for a design-build contract, the university may enter into a single contract with a design-builder recommended by a selection panel and selected by the university. The university shall give notice of such project and specifications for such project by posting such notice on the State Contracting Portal. The university shall establish a selection panel for each project to score the qualifications and past performance of each design-builder who submits a competitive proposal to the university for such project. The selection panel shall score the qualifications and past performance of each design-builder using a predetermined scoring method developed by the university and provided to each design-builder in advance of such design-builder's development of the competitive proposal. The selection panel's scoring method may be unique to each project, but shall consist of combining the score of each design-builder's qualifications and past performance and evaluating the technical merit of the competitive proposal and each design-builder's projected project cost. The design-build contract shall (A) include, but not be limited to, such project elements as permitting, engineering, design, construction and, if applicable, site acquisition, and (B) be based on the competitive proposal submitted by the design-builder that is selected by the university. No design-build contract for which the total cost is estimated to be more than the amount set forth in subdivision (2) of subsection (a) of section 4b-91 may be awarded to a design-builder who is not prequalified for the project in accordance with section 4a-100 . Such design-build contracts shall state the responsibilities of the design-builder to deliver a completed and acceptable project on a date certain and the maximum costs of the project and, if applicable, as a separate item, the cost of any site acquisition. The university shall determine all other requirements and conditions for such competitive proposals, selection of a design-builder and other awards and shall have sole responsibility for all other aspects of such design-build contracts. (d) For the purposes of part III of chapter 557, a project undertaken by the university shall be deemed to be a state public works project and consist of public buildings. (e) (1) Notwithstanding any provision of the general statutes, any license, permit, and approval required or permitted to be issued and any administrative action required or permitted to be taken pursuant to the general statutes in connection with any project by the university shall be issued or taken upon application to the particular commissioner or commissioners having jurisdiction over such license, permit, approval or other administrative action or such other state official as such commissioner shall designate. As used in this section, the term commissioner shall mean commissioners if more than one commissioner has jurisdiction over the subject matter and their designee, if any. No agency, commission, council, committee, panel or other body whatsoever other than such commissioner shall have jurisdiction over or cognizance of any licenses, permits, approvals or administrative actions concerning any project and no notice of any tentative determination or any final determination regarding any such license, permit, approval or administrative action and no notice of any such license, permit, approval or administrative action shall be required except as expressly provided pursuant to this subsection. For purposes of sections 10a-109a to 10a-109y , inclusive, a capital project is a state facility and accordingly, no ordinance, law or regulation promulgated by or any authority granted to any municipality or any other political subdivision of the state shall apply to a capital project. The State Properties Review Board shall have jurisdiction over any project in the same manner as provided in chapter 60 for a priority higher education facility project. Such commissioner may issue licenses and permits, give such approval and take such administrative action as shall be necessary or desirable. (2) All applications, supporting documentation and other records submitted to the commissioner and pertaining to any application for any license, permit, approval or other administrative action, together with all records of the proceedings of the commissioner relating to any license, permit, approval or administrative action shall be a public record and shall be made, maintained and disclosed in accordance with the Freedom of Information Act, as defined in section 1-200 . (3) All applications for licenses, permits, approvals and other administrative action required by any applicable provision of the general statutes shall be submitted to the commissioner as provided in subdivision (1) of this subsection. (4) (A) Any hearing regarding all or any part of any project, provided for by this section, shall be conducted by the particular commissioner having jurisdiction over the applicable license, permit, approval or other administrative action. Legal notice of such hearing shall be published in a newspaper having general circulation in an area which includes the municipality in which the particular part of such project is proposed to be built or is being built not more than ten nor less than five days in advance of such hearing. (B) In rendering any decision in connection with any project, the commissioner shall weigh all competent material and substantial evidence presented by the applicant and the public in accordance with the applicable statute. The commissioner shall issue written findings and determinations upon which the commissioner's decision is based. Such findings and determinations shall consist of evidence presented, including such matters as the commissioner deems appropriate, provided such matters, to the extent applicable to the particular permit, shall include the nature of any major adverse health and environmental impact of any project. The commissioner may reverse or modify any order or action at any time on the commissioner's own motion. The procedure for such reversal or modification shall be the same as the procedure for the original proceeding. (C) Any administrative action taken by any commissioner in connection with any project may be appealed by an aggrieved party to the superior court for the judicial district of New Britain in accordance with the provisions of section 4-183 , except as otherwise provided in sections 10a-109a to 10a-109y , inclusive. Such appeal shall be brought not later than ten days after the date of mailing to the parties to the proceeding of a notice of such order, decision or action by certified mail, return receipt requested, and the appellant shall serve a copy of the appeal on each party listed in the final decision at the address shown in such decision. Failure to make such service within such ten days on parties other than the commissioner who rendered the final decision may not, in the discretion of the court, deprive the court of jurisdiction over such appeal. Within ten days after the service of such appeal, or within such further time as may be allowed by the court, the commissioner who rendered such decision shall cause any portion of the record that had not been transcribed to be transcribed and shall cause either the original or a certified copy of the entire record of the proceeding appealed from to be transmitted to the reviewing court. Such record shall include the commissioner's findings of fact and conclusions of law, separately stated. If more than one commissioner has jurisdiction over the matter, such commissioners shall issue joint findings of fact and conclusions of law. Such appeal shall state the reasons upon which it is predicated and, notwithstanding any provision of the general statutes, shall not stay the development of any project. The commissioner who rendered such decision shall appear as the respondent. Such appeals to the superior court shall each be privileged matters and shall be heard as soon after the return date as practicable. A court shall render its decision not later than twenty-one days after the date that the entire record, with the transcript, is filed with the court by the commissioner who rendered the decision. (D) The court shall not substitute its judgment for that of the commissioner as to the weight of the evidence presented on a question of fact. The court shall affirm the decision of the commissioner unless the court finds that substantial rights of the party appealing such decision have been materially prejudiced because the findings, inferences, conclusions or decisions of the commissioner are: (i) In violation of constitutional or statutory provisions, (ii) in excess of the statutory authority of the commissioner, (iii) made upon unlawful procedure, (iv) affected by an error of law, (v) clearly erroneous in view of the reliable, probative and substantial evidence on the whole record, or (vi) arbitrary, capricious or characterized by abuse of discretion or clearly unwarranted exercise of discretion. (E) If the court finds material prejudice, it may sustain the appeal. Upon sustaining an appeal, the court may render a judgment which modifies the decision of the commissioner, orders particular action of the commissioner or orders the commissioner to take such action as may be necessary to effect a particular action and the commissioner may issue a permit consistent with such judgment. Notwithstanding the foregoing, an applicant may file an amended application and the commissioner may, pursuant to the procedures set forth in sections 10a-109a to 10a-109y , inclusive, consider an amended application for an order, permit or other administrative action following court action. (F) Notwithstanding the provisions of section 3-125 , in consultation with the Attorney General, the university may use the legal services of any private attorney, in connection with the construction, operation and maintenance of any project. The board of trustees shall determine the effective and efficient method or methods of legal services to accomplish the construction, operation and maintenance of all projects, taking into account the capacity, cost and expense of private counsel for such services and the capacity and direct and indirect cost and expense of and identified by the Attorney General for such services. (f) On or before December thirty-first and June thirtieth of each year, the university shall submit a report to the joint standing committee of the General Assembly having cognizance of matters relating to finance, revenue and bonding. Such report shall include the following information: (1) The names and addresses of contractors and subcontractors performing repair, addition, alteration and new construction on the university's campuses in the previous six calendar months, (2) the extent to which such contractors and subcontractors have been in compliance with the provisions of part III of chapter 557 and the provisions of chapter 558, and (3) any actions taken by the university to cooperate with the Labor Department in the enforcement of said provisions.
(P.A. 88-230, S. 1, 12; P.A. 90-98, S. 1, 2; P.A. 93-142, S. 4, 7, 8; P.A. 95-220, S. 4–6; 95-230, S. 14, 45; P.A. 97-47, S. 31; P.A. 99-215, S. 24, 29; May 9 Sp. Sess. P.A. 02-3, S. 7; P.A. 06-134, S. 8, 20; June Sp. Sess. P.A. 07-7, S. 60; P.A. 10-104, S. 7; P.A. 13-177, S. 1; 13-233, S. 7; P.A. 17-230, S. 1; June Sp. Sess. P.A. 17-2, S. 444; P.A. 18-103, S. 4; P.A. 19-32, S. 3; P.A. 23-204, S. 430–432; P.A. 24-151, S. 23.) History: P.A. 95-230 effective June 7, 1995 (Revisor's note: P.A. 88-230, 90-98, 93-142 and 95-220 authorized substitution of “judicial district of Hartford” for “judicial district of Hartford-New Britain”, effective September 1, 1998); P.A. 97-47 amended Subsec. (e)(2) by substituting “the Freedom of Information Act, as defined in Sec. 1-18a” for “chapter 3”; P.A. 99-215 replaced “judicial district of Hartford” with “judicial district of New Britain” in Subsec. (e)(4)(C), effective June 29, 1999; May 9 Sp. Sess. P.A. 02-3 amended Subsec. (a) to delete provision requiring filing with the Commissioner of Public Works for capital improvement projects and, notwithstanding the provisions of Chs. 59 and 60, to vest in the university the authority re such projects, amended Subsec. (c)(2) to provide for consideration of bidders' compliance with certain provisions of Chs. 557 and 558, amended Subsec. (e) to make a technical change in Subdiv. (1) and to delete provisions for a master process for certain approvals necessary for capital improvements in Subdiv. (3) and added Subsec. (f) re report to the General Assembly, effective July 1, 2002; P.A. 06-134 amended Subsec. (a) to eliminate language notwithstanding the provisions of Ch. 59 or 60, effective January 1, 2007, and amended Subsec. (c) by adding language in Subdivs. (2), (3), (4) and (7) re total cost basis contract, monetary threshold requiring project to be publicly let, exception for emergencies and notification to prequalify through advertisement, by replacing “bidder” with “contractor” and adding “proposal” to language re bid throughout said Subdivs. and by adding Subdiv. (9) re construction manager at-risk project delivery contracts, effective July 1, 2006; June Sp. Sess. P.A. 07-7 amended Subsec. (a) to extend the end date from June 30, 2015, to June 30, 2016, effective November 2, 2007; P.A. 10-104 amended Subsec. (a) by extending period during which university has charge and supervision to June 30, 2018, or until completion of UConn 2000 program and made a technical change, effective June 3, 2010; P.A. 13-177 amended Subsec. (c) to add provision re inviting bids and giving notice of opportunities to bid by posting advertisement on the Internet in Subdiv. (9) and add Subdiv. (10) re design-build contracts, effective July 1, 2013; P.A. 13-233 amended Subsec. (a) to extend period during which university has charge and supervision from June 30, 2018, to June 30, 2024, effective July 1, 2013; P.A. 17-230 amended Subsec. (c) to replace provision re advertising notice in newspapers with posting notice on State Contracting Portal in Subdivs. (2)(A) and (9), and to replace provision re posting notice of design-build contracts on the Internet with posting notice on the State Contracting Portal in Subdiv. (10); June Sp. Sess. P.A. 17-2 amended Subsec. (a) to replace “June 30, 2024” with “June 30, 2027”, effective October 31, 2017; P.A. 18-103 made a technical change in Subsec. (e)(4)(C), effective July 1, 2018; P.A. 19-32 made technical changes in Subsec. (e)(4); P.A. 23-204 amended Subsec. (c)(2) by changing reference to notice to prequalify contractors to a notice to submit bids in Subpara. (A), designating existing provisions re notice for contractors to be prequalified as Subpara. (A)(i), re time and place for receipt of responses as Subpara. (A)(ii), re inclusion of additional information if deemed appropriate as Subpara. (A)(iii), re selection of contractors who are prequalified as Subpara. (A)(I), re contractor ability to post surety bonds as Subpara. (A)(II), adding reference to new Subpara. (B) in Subpara. (A)(i) and to Sec. 4b-91 in Subpara. (A)(I), adding Subpara. (A)(III) re no conflict of interest and Subpara. (A)(IV) re prequalification for contracts costing more than $1,000,000, designating existing provisions re requirement for contractors to demonstrate financial managerial and technical ability as new Subpara. (B)(i)(I), re qualification based on experience with similar projects as new Subpara. (B)(i)(II) and re compliance of subcontractors as new Subpara. (B)(ii), adding Subpara. (C) re confirmation of prequalification effective for 1 year, redesignating existing Subpara. (B) re approval of emergency contracts as Subpara. (D), amended Subsec. (c)(3) by removing requirement for giving notice of time and place of public letting to prequalified contractors and amended Subsec. (c)(4) by removing reference to notice to prequalified contractors to submit a proposal, effective October 1, 2023, amended Subsec. (c)(9) by designating existing provisions re construction manager at-risk project delivery contracts as Subpara. (A), redesignating former Subpara. (A) re ineligibility of construction manager at-risk to submit bid and former Subpara. (B) re not beginning construction until determination of maximum guaranteed price as Subparas. (A)(i) and (A)(ii), respectively, redesignating existing provisions in Subpara. (A)(ii) re exception for project elements of site preparation and demolition as subclause (I) and adding Subpara. (A)(ii)(II) re exception for project elements of site preparation, demolition, public utility installation and connections and building envelope components, new Subpara. (B) re conditions for beginning construction prior to the determination of maximum guaranteed price for specific project elements and Subpara. (C) re renovation of existing buildings in multiple phases, effective June 12, 2023, and amended Subsec. (c)(10) by replacing contract amount over which design-builders need to be prequalified from $500,000 to an amount set forth in Sec. 4b-91(a)(2), effective October 1, 2023; P.A. 24-151 amended Subsec. (a) to replace “June 30, 2027” with “June 30, 2031”, effective July 1, 2024.