#29684-a-SPM 2022 S.D. 75
IN THE SUPREME COURT OF THE STATE OF SOUTH DAKOTA
****
ED SUVADA, Plaintiff and Appellant,
v.
GEORGE JOHN MULLER, II and CHRISTINE MULLER, Defendants and Appellees.
APPEAL FROM THE CIRCUIT COURT OF THE FOURTH JUDICIAL CIRCUIT LAWRENCE COUNTY, SOUTH DAKOTA
THE HONORABLE ERIC J. STRAWN Judge
DAVE L. CLAGGETT of Claggett & Dill, Prof. LLC Spearfish, South Dakota Attorneys for plaintiff and appellant.
ROBERT J. GALBRAITH of Nooney & Solay, LLP Rapid City, South Dakota Attorneys for defendants and appellees.
CONSIDERED ON BRIEFS FEBRUARY 14, 2022 OPINION FILED 12/14/22 #29684
MYREN, Justice
[¶1.] Ed Suvada commenced this action to foreclose a materialmen’s lien to
recover for material and labor he expended in renovating a cabin for George (Jack)
and Christine Muller. Suvada also sought damages for breach of contract. The
Mullers counterclaimed for breach of contract and fraud. The jury found in favor of
Suvada on his materialmen’s lien, awarding him damages. The jury also found in
favor of the Mullers on both of their claims but only awarded damages on the
breach of contract claim. Suvada appeals, raising multiple issues. We affirm.
Facts and Procedural History
[¶2.] Suvada is a carpenter with nearly 50 years of experience. In August
2016, Suvada signed a written contract with the Mullers for an addition and
remodeling project on their cabin near Deadwood. The contract covered labor and
materials and included a clause stating that the work 1 would be “substantially
completed on or before the 31st day of May, 2017.” The Mullers agreed to pay
Suvada $131,600.00 plus tax for the material and labor performed, subject to any
authorized change orders. The contract stated, “[a]ll change orders shall be in
writing and signed by both the Owner and the Contractor.” 2 The contract also
included a payment schedule.
[¶3.] The Mullers made timely payments until the end of May 2017, leaving
approximately $5,000.00 to pay under the payment schedule. Ultimately, the
1. The contract included a page itemizing the work to be completed.
2. It is undisputed that the parties only entered into one written change order (involving concrete).
-1- #29684
Mullers withheld $2,690.00, claiming that items within the contract remained
incomplete. Suvada claimed that the Mullers had him complete work beyond what
was called for in the contract (“extras”) between August 2016 and January 2018,
preventing him from completing the contract on time. He asserted that the Mullers
gave him over 60 additional “extras,” which were not part of the written contract,
including installing different siding and soffit.
[¶4.] On January 10, 2018, approximately eight months after the contract’s
expected completion date, Suvada and Jack Muller spoke over the phone. Both
parties acknowledged that the phone call was “heated”; however, they disagreed
about the call’s contents. Jack Muller claimed that he asked Suvada to complete
the contractual work and that they would “figure out the extras after the
contractual work had been completed.” Suvada contended that Jack Muller told
him to stop working. Following the phone call, the Mullers sent Suvada an email
requesting that he bill them for the “extras” and complete the contract work by
March 1, 2018. 3
[¶5.] Suvada did not return to the worksite, and the project remained
incomplete. In February 2018, the Mullers sent Suvada a termination letter. In
March 2018, Suvada served the Mullers with his notice of intent to claim a
3. Over the course of the project, Suvada billed the Mullers for numerous “extras,” which the Mullers paid in addition to the contract amounts. As the project came to its conclusion, Suvada billed the Mullers for “extras” in December 2017 and February 2018. The Mullers initially wrote Suvada checks for the December invoices but later cancelled the checks before Suvada deposited them.
-2- #29684
materialmen’s lien4 on the property. Suvada then filed his lien statement with the
register of deeds in Lawrence County, alleging that the Mullers owed him
$16,389.35 for labor and materials. 5 Shortly after, the Mullers demanded that
Suvada commence suit to enforce the lien under SDCL 44-9-26. Suvada commenced
this action to foreclose the lien and also alleged breach of contract. He requested
the lien sum, costs, and attorney fees. Suvada simultaneously filed a notice of lis
pendens, including a bill of particulars with itemized invoices.
[¶6.] The Mullers filed their answer, denying Suvada’s causes of action and
asserting several affirmative defenses. The Mullers also counterclaimed, alleging
breach of contract, construction defects/negligence, fraudulent misrepresentations,
and seeking declaratory judgment. They demanded a jury trial on all issues triable
to a jury. The Mullers also sought $38,310.55 for the amount they expended to hire
All Star Construction (All Star) to finish the work Suvada allegedly failed to
complete under the contract.
[¶7.] Suvada filed a motion to dismiss and a reply to the Mullers’
counterclaims. Discovery ensued. In September 2020, Suvada filed a motion for a
scheduling order to establish dates to set a pretrial hearing and trial. The parties
agreed to a two-day jury trial starting on March 24, 2021.
4. A mechanic’s and materialmen’s lien grants a person, who “at the request of the owner . . . furnish[ed] skill, labor, services, including light, power, or water, equipment, or materials for the improvement, development, or operation of property” to have a lien thereon. SDCL 44-9-1.
5. The materialmen’s lien did not relate to anything owed under the contract; instead, it related only to the “extras” completed by Suvada at the Mullers’ request.
-3- #29684
[¶8.] On March 9, 2021, Suvada filed an objection to the Mullers’ demand
for a jury trial, arguing that a foreclosure of a materialmen’s lien operates like a
mortgage foreclosure and that foreclosures do not allow for a trial by jury. See First
Nat’l Bank of Phillip v. Temple, 2002 S.D. 36, ¶ 12, 642 N.W.2d 197, 202 (noting
that foreclosure of a mortgage is an equitable action); SDCL 44-9-23 (stating that a
materialmen’s “lien . . . action shall be begun and conducted in the same manner as
actions for the foreclosure of mortgages upon real estate”). He also argued that the
Mullers’ fraud claim and request for punitive damages do not entitle them to a jury
trial. In his view, his “mechanic’s lien is the heart of this litigation,” and “[a]ll other
claims are, at best, pendant [sic]” because “[t]he lien is based on the construction
contract between the parties, the change orders, and payment.”
[¶9.] In response to Suvada’s objection to a jury trial, the Mullers argued
that the parties had agreed to the jury trial in their scheduling order and noted that
Suvada’s complaint included a breach of contract claim, which they asserted was
appropriate for a jury trial. Similarly, they argued that their counterclaims for
breach of contract and fraud were both appropriate for a jury trial. The circuit court
overruled Suvada’s objection.
[¶10.] At the jury trial, Suvada was the sole witness in his case-in-chief. He
testified that when he bid on the job, he calculated that it would take him 224 hours
to install the type of siding and soffit initially selected by the Mullers. Suvada
claimed that after the contract was signed, the Mullers chose new siding and soffit
that required more labor than he estimated in the original bid. He testified that
instead of changing the written contract amount, he and the Mullers agreed that he
-4- #29684
would charge $38.00 per hour, as “extras,” for any time he spent installing the new
siding and soffit that went beyond the budgeted 224 hours (224-hour credit). He
asserted that, but for the “extras,” he would have been able to complete the contract
by the May deadline.
[¶11.] On cross-examination, Suvada acknowledged the completion deadline
and admitted that the parties never executed a written change order about the
completion date. He also admitted that there was no written change order, email,
or text about the 224-hour credit. When asked whether he told the Mullers that his
son would help with the construction project (thus supporting the Mullers’ claim
that even with the “extras,” Suvada represented he would complete the project on
time), his counsel objected and asserted the parol evidence rule. Suvada argued the
terms of the contract must be derived from the four corners of the written contract;
thus, testimony regarding discussions prior to the contract was improper. The
Mullers asserted that the evidence pertained to Suvada’s representations about the
completion timeline. The circuit court overruled the objection.
[¶12.] On the second day of trial, outside the jury’s presence, the parties
addressed the materialmen’s lien with the circuit court. Suvada noted that it was
within the circuit court’s authority to render a decision on the materialmen’s lien.
The Mullers contested the validity of Suvada’s lien, arguing that the lien was not
properly itemized. The circuit court noted it would review the lien “after everything
[was] done” to determine whether it was properly itemized. The Mullers argued
that Suvada could elect which claim to pursue and suggested that if Suvada elected
his materialmen’s lien claim and withdrew his breach of contract claim, the circuit
-5- #29684
court could decide the materialmen’s lien claim. They asserted that if no election
occurred and both issues were presented to the jury, the jury’s decision would bind
the circuit court. The circuit court clarified that if Suvada withdrew his breach of
contract claim, the court “would take the materialmen’s lien under consideration,
and then [the parties] both could brief it out and [the court] could render a decision
on the materialmen’s lien.” The circuit court inquired, “So how do you envision me
giving this to the jury?” Counsel for Suvada suggested that during the settling of
jury instructions, the circuit court would need to decide whether the materialmen’s
lien was sufficiently itemized to be valid. The Mullers agreed but noted that even if
the circuit court found the materialmen’s lien to be deficient, the jury would still
need to decide the breach of contract claim.
[¶13.] After Suvada rested, the Mullers reserved their right to make motions
and called Jack Muller as their first witness. He testified to the terms of the
contract and the clauses contained therein. When Jack Muller was asked whether
Suvada made any representations during contract negotiations that Suvada would
have an additional worker help on the project, Suvada objected, citing the parol
evidence rule. The circuit court overruled the objection, and Jack Muller responded
that Suvada said his son would help. Jack Muller also testified that Suvada never
indicated, before signing the contract, that his son was unavailable. Jack Muller
acknowledged that Suvada completed “extras” but denied that they had agreed to
pay $38.00 per hour for the “extras.” He also testified that he and his wife hired All
-6- #29684
Star to complete the contractual work. 6 Christine Muller testified consistently with
Jack Muller, including that she was never told the project would take more time or
cost more money.
[¶14.] After both parties rested, the Mullers requested a judgment as a
matter of law on their breach of contract claim. Emphasizing that there was no
dispute that the contract required completion by May 31, 2017, the Mullers noted
that SDCL 53-8-7 provides that written contracts can only be modified in two
ways—either by a written contract or an executed oral agreement. They argued
that Suvada did not present evidence showing a written modification of the
contract’s completion date and that the only other viable argument for a change of
the written agreement would be the existence of an executed oral agreement, which
they claimed did not occur because neither party fully performed. The Mullers also
requested the circuit court determine as a matter of law that there was no
agreement for the 224-hour credit concerning the installation of siding and soffit for
the same reasons—there was no written modification of the contract and no
executed oral agreement. In response, Suvada argued that a change order
modifying the contract deadline was unnecessary given the parties’ conduct and
that the Mullers’ payments indicate that an oral contract for the 224-hour credit
existed.
6. The Mullers called an All Star representative to testify at trial. The representative testified that the project was unfinished when All Star got there and that the company quoted the Mullers $38,310.55 to finish the project. All Star ultimately completed the project, and the Mullers paid All Star that amount.
-7- #29684
[¶15.] The circuit court granted the Mullers’ motion for judgment as a matter
of law. First, the circuit court concluded that there was no agreement to modify the
original contract’s completion date, and Suvada breached the contract by failing to
complete the project by that date. Second, the circuit court determined that there
was no executed oral agreement to modify the original contract to create a 224-hour
credit for the installation of siding and soffit. Finally, the circuit court determined
that Suvada’s materialmen’s lien was properly filed.
[¶16.] During the settling of jury instructions, the circuit court overruled
Suvada’s objections to six specific instructions. The parties proceeded with closing
arguments—Suvada requested the jury award him $16,389.35, while the Mullers
asked for an award of $35,620.55. 7
[¶17.] The jury awarded Suvada $8,049.99 for his claims. The jury also
awarded the Mullers $28,505.22 for their breach of contract claim. Although the
jury found Suvada committed fraud, the jury declined to award the Mullers any
damages on the fraud claim. The circuit court denied both parties’ requests for
attorney fees and costs. The circuit court also set off the verdicts resulting in a
judgment for the Mullers for $20,455.23, prejudgment interest in the stipulated
amount of $4,129.80, and post-judgment interest. Suvada appeals, raising the
following issues, which we restate as follows:
1. Whether the circuit court erred in granting the Mullers’ demand for jury trial on all triable issues and in allowing
7. The Mullers initially requested $38,310.55 to cover the work performed by All Star. However, they later reduced it by $2,690.00 to account for the unpaid amount under the original contract with Suvada.
-8- #29684
the jury to determine the amount due, if any, to Suvada on the materialmen’s lien.
2. Whether the circuit court erred in granting the Mullers’ motion for judgment as a matter of law.
3. Whether the circuit court erred in instructing the jury.
4. Whether sufficient evidence supports the verdict granting Suvada damages in an amount smaller than requested.
5. Whether the circuit court abused its discretion in denying Suvada’s application for attorney fees and costs.
6. Whether Suvada is entitled to appellate attorney fees.
Jury trial
[¶18.] Suvada claims the Mullers were not entitled to a jury trial, regardless
of their counterclaims, because, in his view, the “real, meritorious controversy” at
issue was his materialmen’s lien, a primarily equitable action. In response, the
Mullers assert that they have a constitutional right to a jury trial on legal claims,
including Suvada’s breach of contract claim and their counterclaims for breach of
contract and fraud. Additionally, the Mullers note that Suvada suggested to the
circuit court that the jury determine the amount due on the materialmen’s lien.
[¶19.] Article VI, § 6 of the South Dakota Constitution and SDCL 15-6-38(a)–
(b) guarantee the right to a jury trial; nevertheless, that right “does not exist in all
civil cases.” Nizielski v. Tvinnereim, 453 N.W.2d 831, 832–33 (S.D. 1990). “In cases
where the pleadings seek equitable relief . . . , a jury trial is a matter for the trial
court’s discretion. Conversely, when the action is at law, either party has a right to
a jury trial.” Mundhenke v. Holm, 2010 S.D. 67, ¶ 14, 787 N.W.2d 302, 306
-9- #29684
(omission in original) (quoting First Nat’l Bank of Philip v. Temple, 2002 S.D. 36,
¶ 10, 642 N.W.2d 197, 201).
[¶20.] We review de novo whether an action (or claim) is legal or equitable in
nature. Nizielski, 453 N.W.2d at 832–33 (applying de novo review in determining
whether “an action arises at law or equity[.]”). To determine whether an action
seeks equitable or legal relief, the circuit court reviews “the real, meritorious
controversy between the parties. . . . [T]he court looks to the ultimate and entire
relief sought, as presented by the pleadings, including the complaint, answer, cross-
complaint and prayer for relief.” First Nat’l Bank of Philip, 2002 S.D. 36, ¶ 10, 642
N.W.2d at 201 (quoting Arlt v. Langley, 56 S.D. 79, 88, 227 N.W. 469, 473 (1929)).
“[W]hen a case presents both a request for equitable relief and legal relief, the
proper course of action is for the trial court to bifurcate the issues and try the
equitable claims to the court and the legal claims to a jury.” Mundhenke, 2010 S.D.
67, ¶ 16, 787 N.W.2d at 306.
[¶21.] Clearly, the Mullers’ counterclaims for breach of contract and fraud
sought legal relief and were subject to the right to trial by jury. The Mullers
requested a jury trial on these issues, and the circuit court properly granted their
request. Similarly, Suvada’s claim for breach of contract also sought legal relief and
was subject to a request for a jury trial.
[¶22.] We have previously determined that the foreclosure of a mechanic’s
lien is an action in equity. Duffield Constr., Inc. v. Baldwin, 2004 S.D. 51, ¶ 6, 679
N.W.2d 477, 480. Therefore, Suvada’s action to enforce a materialmen’s lien is
equitable in nature, and it is not subject to a jury trial as a matter of right.
-10- #29684
However, this determination does not preclude using a jury to assist the circuit
court and the parties in resolving issues related to the materialmen’s claim. See
First W. Bank, Sturgis v. Livestock Yards Co., 466 N.W.2d 853, 856 (S.D. 1991) (“If
the relief sought is equitable, the decision of whether to empanel an advisory jury is
wholly within the trial court’s discretion.”).
[¶23.] The Supreme Court of Dakota Territory noted in McCormack that “the
progress of the action in the [circuit] court” is a “significant and controlling factor”
in determining the outcome of the case. McCormack, 4 Dak. 506, 532, 34 N.W. 39,
53–54 (1887). In that case, the Court determined that a party could not assert on
appeal that an equitable matter decided by a jury with a general verdict should
instead have been tried to the court after the party stipulated to a jury trial and had
not requested any special findings by the jury. Id. at 532, 34 N.W. at 54.
[¶24.] Likewise, the progress of this action before the circuit court is
significant and controlling. The Mullers did not request a jury trial on Suvada’s
equitable materialmen’s lien claim. Instead, they requested the circuit court find
Suvada’s materialmen’s lien legally deficient because, in their view, it was not
sufficiently itemized as required by statute. The Mullers then suggested that if the
court determined that the lien was legally sufficient, the jury could be utilized to
resolve the factual issue of how much was owed. In response, Suvada noted that
the circuit court could determine the validity of the materialmen’s lien and that
upon finding validity, the court would say, “[j]ury, this is what you need to respond
to.” Suvada later reinforced this contention, stating that the only question for the
-11- #29684
jury is whether the amount he claimed in the lien “is the amount the jury’s going to
come up with, or if they’re going to come up with a different amount.”
[¶25.] As discussed by the parties, the circuit court proceeded to rule on the
legal question of whether Suvada’s materialmen’s lien was legally sufficient, then
tasked the jury with determining what amount was due to Suvada on his lien. See
Lytle v. Morgan, 270 N.W.2d 359, 361 (S.D. 1978) (A party seeking to recover on a
mechanic’s lien does not have “the power to arbitrarily set the value of material and
labor without the necessity of proving the value thereof.”), abrogated on other
grounds by Magner v. Brinkman, 2016 S.D. 50, ¶ 12, 883 N.W.2d 74, 80; SDCL 44-9-
40 (stating that “[j]udgment shall be given in favor of each lien holder for the
amount demanded and proved by him” (emphasis added)). The circuit court’s
instructions informed the jury that Suvada’s materialmen’s lien was valid and that
it was the jury’s job to “determine the amount to award to Mr. Suvada, if any.”
Given the legal claims brought by both parties and the absence of any objection by
Suvada to presenting the question of the amount due under the materialmen’s lien
to the jury, the circuit court did not err in granting the Mullers’ demand for a jury
trial on all triable issues.
Judgment as a matter of law
[¶26.] Suvada argues that the circuit court erred in granting the Mullers’
motion for judgment as a matter of law. He contends that he presented sufficient
evidence to establish an oral agreement for “extras,” which prevented him from
completing the contract in the specified time. He also asserts that there was
evidence in the record to support his claim that there was to be a 224-hour credit
-12- #29684
under the contract. In response, the Mullers assert that the contract’s completion
date was undisputed and that Suvada admitted that he had not completed the work
required by the contract. The Mullers also argue that there was no executed oral
modification of the original contract pursuant to SDCL 53-8-7 8 regarding Suvada’s
claimed 224-hour credit.
[¶27.] The grant or denial of a motion for judgment as a matter of law is a
question of law reviewed de novo. Magner, 2016 S.D. 50, ¶ 13, 883 N.W.2d at 81.
Circuit courts have the authority to grant motions for judgment as a matter of law
under SDCL 15-6-50(a). The statute provides, in relevant part, that:
If during a trial by jury a party has been fully heard on an issue and there is no legally sufficient evidentiary basis for a reasonable jury to find for that party on that issue, the court may determine the issue against that party and may grant a motion for judgment as a matter of law against that party with respect to a claim or defense that cannot under the controlling law be maintained or defeated without a favorable finding on that issue.
SDCL 15-6-50(a)(1). “Factual disputes generally prohibit granting a judgment as a
matter of law.” Alvine Fam. Ltd. P’ship v. Hagemann, 2010 S.D. 28, ¶ 19, 780
N.W.2d 507, 513.
[¶28.] Matters of contract interpretation are questions of law reviewed de
novo, and “[w]hen interpreting a contract, this Court looks to the language that the
parties used in the contract to determine their intention.” Charlson v. Charlson,
2017 S.D. 11, ¶ 16, 892 N.W.2d 903, 908 (quoting Detmers v. Costner, 2012 S.D. 35,
8. SDCL 53-8-7 provides that “[a] contract in writing may be altered by a contract in writing without a new consideration or by an executed oral agreement, and not otherwise.”
-13- #29684
¶ 20, 814 N.W.2d 146, 151). “In order to ascertain the terms and conditions of a
contract, we examine the contract as a whole and give words their plain and
ordinary meaning.” Id. (quoting Nygaard v. Sioux Valley Hosps. & Health Sys.,
2007 S.D. 34, ¶ 13, 731 N.W.2d 184, 191). “To form a contract, there must be a
meeting of the minds or mutual assent on all essential terms.” Jacobson v.
Gulbransen, 2001 S.D. 33, ¶ 22, 623 N.W.2d 84, 90.
[¶29.] The language of the parties’ written contract is controlling. It required
that Suvada “substantially complete[ ]” the contracted work “on or before the 31st
day of May, 2017,” and by its express terms, “[t]he parties agree[d] that time is of
the essence.” Suvada admitted he did not complete the project on time. Moreover,
there is no evidence that the parties agreed, orally or in writing, to extend this
deadline. 9 Under the circumstances presented in this record, the circuit court did
not err by entering a judgment as a matter of law, determining that Suvada
breached the contract by failing to complete the work as required by the terms of
the contract.
[¶30.] Suvada has also failed to establish error by the circuit court in
granting judgment as a matter of law on his claim for “extras.” The contract
required that modifications to the agreement be in writing. It is undisputed that
there was no written modification of the contract to include a requirement that
9. We have held that the parties may waive the time for performance in a written contract, and that an oral waiver of the time for performance “is not an alteration of a written contract.” Hanna v. Landsman, 2020 S.D. 33, ¶ 27, 945 N.W.2d 534, 543 (quoting Johnson v. Sellers, 2011 S.D. 24, ¶ 16, 798 N.W.2d 690, 695). However, Suvada failed to present evidence that the Mullers waived the time is of the essence clause, and he does not argue on appeal that the Mullers waived this provision in the written contract.
-14- #29684
Suvada would be paid for extra work or that the parties agreed to a written change
order to encompass that work. However, Suvada claims that the parties had orally
modified the written contract to allow him to bill the Mullers for any time spent
installing siding and soffit beyond the “224-hour credit.”
[¶31.] Under SDCL 53-8-7, an executed oral agreement can modify a written
contract. Execution would be demonstrated by evidence that both parties completed
the requirements of the oral modification. See Aalseth v. Simpson, 57 S.D. 118, 231
N.W. 289, 291 (1930); 10 see Contract, Black’s Law Dictionary (11th ed. 2019) (noting
that an “executed contract” is one that “has been fully performed by both parties”).
Suvada does not argue that the requirements to modify a written contract under
SDCL 53-8-7 were satisfied or that the Mullers’ partial payment for some “extras”
was legally sufficient to constitute an “executed oral agreement” modifying the
written contract to require payment for Suvada’s time spent installing siding and
soffit beyond the “224-hour credit.”
[¶32.] Suvada admitted that he never completed the work required under the
contract or the “extras” for which he sought payment. Further, even though the
Mullers had paid Suvada for some “extras,” they withheld full payment under the
contract and did not pay the money requested by Suvada for his time spent on other
“extras.” In the absence of evidence that the parties had fully executed an oral
agreement to modify the written contract to require payment for “extras,” Suvada
10. Aalseth looked to Section 908, Rev. Code 1919, which provided that “[a] contract in writing may be altered by a contract in writing, or by an executed oral agreement, and not otherwise.” Section 908, Rev. Code 1919 is substantially similar to SDCL 53-8-7.
-15- #29684
was bound by the terms of the written contract. See, e.g., Share v. Coats, 29 S.D.
603, 137 N.W. 402 (1912) (holding that an oral agency agreement to pay more in
commission than provided in the written agreement was not executed because full
payment had not been made under the oral agreement and thus the rate in written
agreement controlled). The circuit court did not err in granting judgment as a
matter of law on Suvada’s claim for “extras.”
Jury instructions [¶33.] “[A] trial court’s decision to grant or deny a particular jury instruction
[is reviewed] under the abuse of discretion” standard, but jury instructions, as a
whole, are reviewed de novo to determine whether they correctly “state the law and
inform the jury.” State v. Waloke, 2013 S.D. 55, ¶ 28, 835 N.W.2d 105, 112–13
(quoting State v. Roach, 2012 S.D. 91, ¶ 13, 825 N.W.2d 258, 263). “[A] court has no
discretion to give incorrect or misleading instructions, and to do so prejudicially
constitutes reversible error.” State v. McReynolds, 2020 S.D. 65, ¶ 17, 951 N.W.2d
809, 815 (quoting State v. Diaz, 2016 S.D. 78, ¶ 42, 887 N.W.2d 751, 763). “Error is
not reversible unless it is prejudicial. The party asserting error has the burden of
showing prejudice in failure to give a requested instruction.” Bauman v. Auch, 539
N.W.2d 320, 323 (S.D. 1995). “Erroneous instructions are prejudicial under SDCL
15-6-61 when in all probability they produced some effect upon the verdict and were
harmful to the substantial rights of a party.” Schultz v. Scandrett, 2015 S.D. 52,
¶ 22, 866 N.W.2d 128, 136 (quoting Vetter v. Cam Wal Elec. Coop., Inc., 2006 S.D.
21, ¶ 10, 711 N.W.2d 612, 615).
[¶34.] Suvada argues that the circuit court erred by providing jury
instructions 25 (the elements of fraudulent misrepresentation), 25A (the elements of -16- #29684
fraudulent concealment), and 26 (general fraud instruction). He alleges that the
Mullers were not entitled to an independent tort claim for fraud and that jury
instructions on those claims were improper. Intertwined in his argument regarding
fraud is his assertion that the jury heard improper parol evidence about whether he
had represented that he would have additional help to complete the project. He
contends that the testimony went beyond the contract’s four corners and should
have been excluded regardless of the Mullers’ fraud claims. He asserts that the
improperly admitted parol evidence regarding the Mullers’ fraud claim prejudiced
him, warranting a new trial. In response, the Mullers argue that their fraud claim
was properly before the jury and that the evidence was admissible to prove fraud.
[¶35.] “[C]onduct which merely is a breach of contract is not a tort, but the
contract may establish a relationship demanding the exercise of proper care and
acts and omissions in performance may give rise to tort liability.” Schipporeit v.
Khan, 2009 S.D. 96, ¶ 7, 775 N.W.2d 503, 505 (quoting Grynberg v. Citation Oil &
Gas Corp., 1997 S.D. 121, ¶ 18, 573 N.W.2d 493, 500). “Because torts arise out of a
legal duty, the question becomes whether such duty is ‘born of that wider range of
legal duty which is due from every man to his fellow, to respect his rights of
property and person, and refrain from invading them by force or fraud.’” Wright v.
Temple, 2021 S.D. 15, ¶ 57, 956 N.W.2d 436, 454–55 (quoting Grynberg, 1997 S.D.
121, ¶ 21, 573 N.W.2d at 501). We must therefore focus “on whether a legal duty
exists independent of the obligations under the contract.” Id. (quoting Grynberg,
1997 S.D. 121, ¶ 22, 573 N.W.2d at 501).
-17- #29684
[¶36.] While the Mullers maintain that a legal duty existed beyond the
contract obligation, their argument is unfounded. The Mullers claimed that Suvada
misrepresented that he would have enough help to fulfill the contract by the
completion date and that he concealed that he would not have enough help to
complete the contract on time. However, both claims pertain to whether Suvada
satisfied his contractual obligation to complete the project by the contract’s
deadline. Neither assertion involves a claimed violation of a duty that exists
independent of the contract. Consequently, the circuit court erred by allowing the
Mullers’ fraud claims to proceed to the jury and by providing jury instructions on
those claims.
[¶37.] However, Suvada bears the burden of establishing that the erroneous
jury instructions “produced some effect upon the verdict and were harmful to the
substantial rights of a party.” Schultz, 2015 S.D. 52, ¶ 22, 866 N.W.2d 1 at 136
(quoting Vetter, 2006 S.D. 21, ¶ 10, 711 N.W.2d at 615). Here, the jury awarded the
Mullers nothing for their fraud claim, making the error harmless. Suvada has not
advanced any argument that submitting these fraud claims to the jury
inappropriately impacted the jury’s determinations about any other claims. 11
11. Given our holding that the circuit court committed harmless error in submitting the fraud claim to the jury, we decline to address the parol evidence issue related to that claim. Suvada also makes a passing reference in his appellate brief to the circuit court having given a damages instruction (jury instruction 27) that set forth “an improper measure of damages.” Beyond this conclusory statement, Suvada has not provided an argument as to why this instruction was improper. Thus, we decline to review this issue. See SDCL 15-26A-60(6) (requiring an appellant brief to “contain the contentions of the party with respect to the issues presented, the reasons therefore, and the citations to the authorities relied on”); see also State v. Fool (continued . . .) -18- #29684
Sufficiency of the evidence
[¶38.] Suvada asserts “insufficiency of evidence of the record to reduce the
full amount of the mechanic’s lien.” Suvada requested the jury award him
$16,389.35 for services and materials from and after January 10, 2018. He claims
that under general principles of lien statutes, the jury should not have been able to
render a verdict less than his requested amount. We disagree.
[¶39.] As discussed above, Suvada was not automatically entitled to the lien
amount and was instead “obligated to prove that the amount demanded constituted
‘the reasonable value of the work done, and of the skill, material and machinery
furnished.’” Lytle, 270 N.W.2d at 361 (quoting SDCL 44-9-6). Ultimately, the
finder of fact in any lien action must determine the amount “proved” by the lien
holder. See SDCL 44-9-40 (stating that a lien holder is entitled to judgment “for the
amount demanded and proved”). As discussed earlier, these parties agreed to
utilize a jury to determine the amount due under the lien in this case.
[¶40.] “In our review of the sufficiency of the evidence supporting a jury
verdict, ‘[w]e are not to speculate or query how we would have viewed the evidence
and testimony, or what verdict we would have rendered had we been the jury.’”
Wright, 2021 S.D. 15, ¶ 28, 956 N.W.2d at 446 (alteration in original) (quoting
Knecht v. Evridge, 2020 S.D. 9, ¶ 37, 940 N.W.2d 318, 329). “Rather, we determine
whether ‘there [is] any legal evidence upon which the verdict can properly be based,
________________________ (. . . continued) Bull, 2009 S.D. 36, ¶ 46, 766 N.W.2d 159, 169 (declining to address an issue because appellant cited no authority and offered no argument in his brief regarding the propriety of the jury instructions).
-19- #29684
and [whether] the conclusions embraced in and covered by [the verdict were] fairly
reached[.]’” Id. (alterations in original) (quoting Roth v. Farner-Bocken Co., 2003
S.D. 80, ¶ 25, 667 N.W.2d 651, 661). “If the jury’s verdict can be explained with
reference to the evidence, rather than by juror passion, prejudice or mistake of law,
the verdict should be affirmed.” Morrison v. Min. Palace Ltd. P’ship, 1999 S.D. 145,
¶ 14, 603 N.W.2d 193, 197 (quoting Gilkyson v. Wheelchair Express, Inc., 1998 S.D.
45, ¶ 19, 579 N.W.2d 1, 5).
[¶41.] It is the jury’s job, as the trier of fact, to “weigh the conflicting evidence
or decide upon the credibility of the witnesses.” LDL Cattle Co., Inc. v. Guetter,
1996 S.D. 22, ¶ 19, 544 N.W.2d 523, 527. While the parties presented conflicting
evidence on the amount due on the lien, the jury weighed the evidence and
determined that Suvada was entitled to an amount less than he had requested.
This was within the jury’s authority, and Suvada’s argument is unpersuasive. See
Wald, Inc. v. Stanley, 2005 S.D. 112, ¶ 15, 706 N.W.2d 626, 631 (noting a lien holder
recovered a fraction of the original materialmen’s lien amount).
Attorney fees
[¶42.] “We review a trial court’s ruling on the allowance or disallowance of
costs and attorney fees under an abuse of discretion standard.” In re Heupel Fam.
Revocable Tr., 2018 S.D. 46, ¶ 34, 914 N.W.2d 571, 580 (quoting Johnson v. Miller,
2012 S.D. 61, ¶ 7, 818 N.W.2d 804, 806). An abuse of discretion “is a fundamental
error of judgment, a choice outside the range of permissible choices, a decision,
which, on full consideration, is arbitrary or unreasonable.” Arneson v. Arneson,
2003 S.D. 125, ¶ 14, 670 N.W.2d 904, 910. In materialmen’s lien proceedings, the
-20- #29684
circuit court has the discretion to award attorney fees and expenses that it
determines are “warranted and necessary according to the circumstances of each
case[.]” SDCL 44-9-42.
[¶43.] Suvada claims the circuit court abused its discretion in denying his
request for attorney fees, alleging that his fees and expenses were “warranted and
necessary.” See SDCL 44-9-42. Suvada also cites other statutes to support his
contention that he is entitled to attorney fees. 12 Further, Suvada relies on Wald,
where we affirmed an award of attorney fees when the contractor recovered a
fraction of the original materialmen’s lien amount. 2005 S.D. 112, ¶ 15, 706 N.W.2d
at 631.
[¶44.] The circuit court emphasized that the jury awarded the Mullers a
larger award than Suvada, which “favors their position that no attorney’s fees
should be awarded to [Suvada].” The circuit court also distinguished this case from
Wald, emphasizing that the Mullers’ award was nearly three times that of Suvada’s
award and that “the jury found in favor of both parties in their respective breach.”
[¶45.] Suvada provides no citation to statute or decisional law requiring the
circuit court to grant him attorney fees and costs. 13 While he argues our holding in
Wald is applicable, he fails to recognize the most salient distinguishing factor—the
contractor in Wald was the only prevailing party. In contrast, this jury found in
12. He cites SDCL 15-6-54(d)(2), SDCL 15-17-37, and SDCL 15-17-38.
13. SDCL 44-9-42 provides that a “court shall have authority in its discretion” to award fees. Similarly, SDCL 15-17-37 provides that a “prevailing party . . . may recover expenditures[.]” SDCL 15-6-54(d) provides “costs and disbursements, other than attorneys’ fees, shall be allowed as of course to the prevailing party unless the court otherwise directs.”
-21- #29684
favor of both Suvada and the Mullers on their respective claims. The circuit court
had discretion in determining whether to award attorney fees and costs, and
Suvada has not established that the court abused its discretion in denying Suvada’s
request.
Appellate attorney fees
[¶46.] Suvada requested appellate attorney fees of $5,722.50 under SDCL 15-
26A-87.3. He submitted an itemized and verified statement of costs associated with
this appeal. We decline to award him appellate attorney fees.
[¶47.] JENSEN, Chief Justice, and KERN, SALTER, and DEVANEY,
Justices, concur.
-22-