BURGESS, J.
-This is an action by plaintiff as assignee of one James Pryor on six different tax bills aggregating, not including interest when the suit was begun, the sum of $2,515.85, and .issued by Kansas City against six different tracts of land owned by defendant, in Sewer District No. 167, in said city.
On April 18, 1891, an ordinance was passed by Kansas City establishing Sewer District No. 167, which embraced the land against which the tax bills involved in this litigation were issued. Thereafter on June 10, 1891, an ordinance No. 3247 was passed, authorizing the construction of sewers in said district,- by which it was provided that “the work should be completed within ninety days from the .time a contract binds and takes effect,” the ordinance reciting that “this work the Board of Public Works and Common Council deem necessary for sanitary and drainage purposes.”
The work was let by contract to said Pryor, and approved by ordinance of date July 23, 1891. By its terms work was to [589]*589be begun in ten days and to be completed in ninety days from tbe time tbe contract was executed. The contract provided that the contractor should not be entitled to any portion of the contract price until the work was completed to the satisfaction of the city engineer, and -then only in tax bills. The time in which the work was to be completed expired October 21, 1891. The work was begun, and continued up to August 21, 1891, when Jennie O. 'Wiltsee and others brought suit against the contractors and Kansas City, and obtained a temporary injunction restraining them from a continuation of the work. The injunction was dissolved on October 31, 1891, but from the time it was granted until its dissolution, no work was done on the sewer.
The contract provides that:
“6. The work embraced in this contract shall be begun within ten days after this contract binds and takes effect, and shall be prosecuted regularly'and uninterruptedly thereafter (unless the engineer shall specially direct otherwise in writing) with such force as to secure its full completion within ninety days from the date of its confirmation; the time of beginning, rate of progress, and time of completion being essential conditions of this contract. And if the contractor shall fail to complete the work within the time above specified, an amount equal to the sum of ten dollar’s per day for each and every day thereafter, until such completion, shall be deducted as liquidated damages for such breach of this contract from the amount of the final estimate of said work..
“T. If, in the opinion of the engineer, the first party, at any time during the progress of the work, is not prosecuting the work with a sufficient force to insure its completion within the time specified in this contract, he may notify the first party to employ such additional force as he deems sufficient; and on the failure of said first party to comply with such notice within three days after its delivery, the engineer may put on [590]*590such additional force at the cost of the said first party or he may, at his option, declare the contract annulled.
“And the power is reserved to the city engineer by Kansas 'City to suspend or annul this contract or to suspend the doing ■of any work thereunder at any time for any failure on the part of the first party to fulfill the same, or for other good cause; and any action of the city engineer in suspending or annulling this contract, or suspending the doing of the work thereunder, and his decision as to the existence of cause or reason for such annulment or suspension shall be conclusive as to the existence ■of such cause or reason in any controversy or litigation between the parties hereto, or others claiming under them. And if this contract be so suspended or annulled, the said first party ■shall not be entitled to anything on account of damages thereby nor shall such annulment or suspension in any wise affect the right of said Kansas City to damages and penalties claimed by it on account of the failure of said first party.”
The evidence showed that work amounting to $4,000 at the contract price, was done up to February 11, 1892.
On February 4, 1892, the city engineer, Butts, wrote Pryor, the contractor, and his sureties on his bond as contractor, to proceed with the work in three days, and on his failure to do so he would annul the contract, which he, -the ■engineer in so far as he had power to do so did on February 11, 1892, because Pryor would not proceed with the work, and, so notified the board of public works.
Butts, the engineer, went out of office in May, 1892, and was succeeded by John Donnelly. Pryor paid no attention to the cancellation of his contract by Butts, but continued to work on said sewer with the full knowledge and consent of Donnelly, the successor of Butts, until October 24, 1893, when the Common Council of Kansas City passed an ordinance, No. 5453, to construct a district sewer in Sewer District No. 167, .and by it repealed ordinance No. 3247 entitled: “An Ordi[591]*591nance to establish and cause to be constructed district sewer in Sewer District No. 167,” approved June 10, 1891.
This last named ordinance makes no reference to the ordinance approving the contract between the city and the contractor, nor does it refer to the contract.
On December 6, 1893, the Common Council of Kansas City passed “an ordinance to repeal an ordinance of Kansas City No. 5453, entitled: ‘An ordinance to construct a district sewer in Sewer District No. 167,’ approved October 24, 1893.”
On March 19, 1894, said council passed an ordiance extending the time for the completion of said work under the original ordinance, No. 3247, to April 1, 1894.
The tax bills were issued March 20, 1894.
At the close of all the evidence the defendant interposed, and the court sustained, a demurrer to the evidence, and in accordance therewith ruled that plaintiff was not entitled t) recover, and rendered judgment for defendant.
Plaintiff then filed motion for new trial, which was overruled and he appeals.
By express provision of the ordinance under which the-work was done, it was to be completed within ninety days from the time a contract for the work bound and took effect, and by the terms of the contract entered into between Pryor and the city for the work it was provided that “the work embraced in this contract shall be begun within ten days after the contract, binds and takes effect., and shall be prosecuted regularly and uninterruptedly thereafter (unless the engineer shall specially direct otherwise in writing) with such force as to secure its frill completion within ninety days from the date of its confirmation; the time of beginning, rate of progress, and time of completion being essential conditions of this contract. And if the-contractor shall fail to complete the work within the time above-specified an amount equal to the sum of ten dollars per day for each and every day thereafter, until such completion,, [592]*592shall be deducted as liquidated damages for such breach of this contract from the amount of the final estimate of said work.”
That the work was not completed within the time prescribed by the ordinance and contract under which it wás done, is not disputed, and as time was the essence of the contract and material, the tax bills issued for the work and here sued on must be held void (Rose v. Trestrail, 62 Mo. App. 352; McQuiddy v.
Free access — add to your briefcase to read the full text and ask questions with AI
BURGESS, J.
-This is an action by plaintiff as assignee of one James Pryor on six different tax bills aggregating, not including interest when the suit was begun, the sum of $2,515.85, and .issued by Kansas City against six different tracts of land owned by defendant, in Sewer District No. 167, in said city.
On April 18, 1891, an ordinance was passed by Kansas City establishing Sewer District No. 167, which embraced the land against which the tax bills involved in this litigation were issued. Thereafter on June 10, 1891, an ordinance No. 3247 was passed, authorizing the construction of sewers in said district,- by which it was provided that “the work should be completed within ninety days from the .time a contract binds and takes effect,” the ordinance reciting that “this work the Board of Public Works and Common Council deem necessary for sanitary and drainage purposes.”
The work was let by contract to said Pryor, and approved by ordinance of date July 23, 1891. By its terms work was to [589]*589be begun in ten days and to be completed in ninety days from tbe time tbe contract was executed. The contract provided that the contractor should not be entitled to any portion of the contract price until the work was completed to the satisfaction of the city engineer, and -then only in tax bills. The time in which the work was to be completed expired October 21, 1891. The work was begun, and continued up to August 21, 1891, when Jennie O. 'Wiltsee and others brought suit against the contractors and Kansas City, and obtained a temporary injunction restraining them from a continuation of the work. The injunction was dissolved on October 31, 1891, but from the time it was granted until its dissolution, no work was done on the sewer.
The contract provides that:
“6. The work embraced in this contract shall be begun within ten days after this contract binds and takes effect, and shall be prosecuted regularly'and uninterruptedly thereafter (unless the engineer shall specially direct otherwise in writing) with such force as to secure its full completion within ninety days from the date of its confirmation; the time of beginning, rate of progress, and time of completion being essential conditions of this contract. And if the contractor shall fail to complete the work within the time above specified, an amount equal to the sum of ten dollar’s per day for each and every day thereafter, until such completion, shall be deducted as liquidated damages for such breach of this contract from the amount of the final estimate of said work..
“T. If, in the opinion of the engineer, the first party, at any time during the progress of the work, is not prosecuting the work with a sufficient force to insure its completion within the time specified in this contract, he may notify the first party to employ such additional force as he deems sufficient; and on the failure of said first party to comply with such notice within three days after its delivery, the engineer may put on [590]*590such additional force at the cost of the said first party or he may, at his option, declare the contract annulled.
“And the power is reserved to the city engineer by Kansas 'City to suspend or annul this contract or to suspend the doing ■of any work thereunder at any time for any failure on the part of the first party to fulfill the same, or for other good cause; and any action of the city engineer in suspending or annulling this contract, or suspending the doing of the work thereunder, and his decision as to the existence of cause or reason for such annulment or suspension shall be conclusive as to the existence ■of such cause or reason in any controversy or litigation between the parties hereto, or others claiming under them. And if this contract be so suspended or annulled, the said first party ■shall not be entitled to anything on account of damages thereby nor shall such annulment or suspension in any wise affect the right of said Kansas City to damages and penalties claimed by it on account of the failure of said first party.”
The evidence showed that work amounting to $4,000 at the contract price, was done up to February 11, 1892.
On February 4, 1892, the city engineer, Butts, wrote Pryor, the contractor, and his sureties on his bond as contractor, to proceed with the work in three days, and on his failure to do so he would annul the contract, which he, -the ■engineer in so far as he had power to do so did on February 11, 1892, because Pryor would not proceed with the work, and, so notified the board of public works.
Butts, the engineer, went out of office in May, 1892, and was succeeded by John Donnelly. Pryor paid no attention to the cancellation of his contract by Butts, but continued to work on said sewer with the full knowledge and consent of Donnelly, the successor of Butts, until October 24, 1893, when the Common Council of Kansas City passed an ordinance, No. 5453, to construct a district sewer in Sewer District No. 167, .and by it repealed ordinance No. 3247 entitled: “An Ordi[591]*591nance to establish and cause to be constructed district sewer in Sewer District No. 167,” approved June 10, 1891.
This last named ordinance makes no reference to the ordinance approving the contract between the city and the contractor, nor does it refer to the contract.
On December 6, 1893, the Common Council of Kansas City passed “an ordinance to repeal an ordinance of Kansas City No. 5453, entitled: ‘An ordinance to construct a district sewer in Sewer District No. 167,’ approved October 24, 1893.”
On March 19, 1894, said council passed an ordiance extending the time for the completion of said work under the original ordinance, No. 3247, to April 1, 1894.
The tax bills were issued March 20, 1894.
At the close of all the evidence the defendant interposed, and the court sustained, a demurrer to the evidence, and in accordance therewith ruled that plaintiff was not entitled t) recover, and rendered judgment for defendant.
Plaintiff then filed motion for new trial, which was overruled and he appeals.
By express provision of the ordinance under which the-work was done, it was to be completed within ninety days from the time a contract for the work bound and took effect, and by the terms of the contract entered into between Pryor and the city for the work it was provided that “the work embraced in this contract shall be begun within ten days after the contract, binds and takes effect., and shall be prosecuted regularly and uninterruptedly thereafter (unless the engineer shall specially direct otherwise in writing) with such force as to secure its frill completion within ninety days from the date of its confirmation; the time of beginning, rate of progress, and time of completion being essential conditions of this contract. And if the-contractor shall fail to complete the work within the time above-specified an amount equal to the sum of ten dollars per day for each and every day thereafter, until such completion,, [592]*592shall be deducted as liquidated damages for such breach of this contract from the amount of the final estimate of said work.”
That the work was not completed within the time prescribed by the ordinance and contract under which it wás done, is not disputed, and as time was the essence of the contract and material, the tax bills issued for the work and here sued on must be held void (Rose v. Trestrail, 62 Mo. App. 352; McQuiddy v. Brannock, 70 Mo. App. 535; New England Safe Deposit & Trust Co. v. James, 77 Mo. App. 616), unless they are rendered valid by some act of the Common Council of Kansas City.
It is, however, claimed by defendant that the penalty prescribed by the contract for failure to complete the work within the time specified was an amount equal to the sum of ten dollars pe'r day for each and every day thereafter until such completion, to be deducted as liquidated ‘damages for such breach of the contract, from the amount of the final estimate of the work, and that this provision controls, and not that which prescribes the time, and-makes it material in which the work was to be done.
But this provision in the contract is not in harmony with section 2, of ordinance No. 3247, under which the contract, was let, which requires the work to be completed in ninety days from the time the contract takes effect.
The effect of this provision was to extend the 'time prescribed by ordinance for the completion of the work to any time that might suit the convenience of the contractor, the only penalty for which was ten dollars per day for every day over that in which the contract was to be completed to be deducted from the amount of the final estimate.
In passing upon a similar provision in a contract for the same kind of work in McQuiddy v. Brannock, supra,Ellison, J., speaking for the court on page 540, said: “It is argued that the provision agreeing upon a forfeiture of $10 for each [593]*593clay of failure to complete tire work within the time is an implied concession that the work might not be completed within the time and yet the contract remain binding. In our opinion, this provision of the contract can not be applied to any substantial departure from the contract as to time.” The provision for the extension of time in the contract in this case is not only a substantial departure from the contract, with respect thereto, but is not in harmony with the ordinance under which the contract was let and must yield thereto.
It is further insisted that the common council by ordinance No. 2384, passed July 16, 1891, approved this contract in all its terms. Conceding this to be true, the tax bills were not thereby validated, because by the very terms of the contract it was provided that the work should be prosecuted regularly and uninterruptedly with such force as to secure its full completion in ninety days and the city engineer might, if-the force of men in his opinion was insufficient, employ men at the contractor’s expense, or he might annul the contract.
Moreover, it was recited in the ordinance under which the contract was let, which w¡as a part of the contract, that “this work the Board of Public Works and Common Council deem necessary for sanitary and drainage purposes,” and also, provided “that the work should be completed within ninety days from the time a contract binds and takes effect,” thereby showing beyond any question that the time in which the contract was to be completed was of -the essence of the contract and material thereto.
The contractor ceased work on the contract, and the city engineer on the fourth day of February, 1892, notified him that unless work was resumed within three days from the receipt of the notice with such a force of workmen as to warrant the completion of his contract within a reasonable time from that date, his contract would be annulled, and, on the ninth day of February, 1892, the engineer did attempt [594]*594to annul Ms contract for the reasons stated in said notice, and so notified the Board of Public Works on the eleventh day of February, 1892.
But defendant contends that the power to annul the contract was legislative in its character, devolved upon the city alone, and even if possessed by it could not be delegated to the city engineer, and, that his act in attempting to terminate the contract, as well as the ordinance approving the contract in that regard, were void.
There is a clear distinction between legislative and ministerial powers; the former can not be delegated, the latter may. Thus in Ruggles v. Collier, 43 Mo. loc. cit. 365, it is said: “There is a clear distinction to be observed between legislative and ministerial powers. The former can not be delegated; the latter may. Legislative power implies judgment and discretion upon the part of those who exercise it, and a special confidence and trust upon the part of those who confer it.”
So in St. Louis to use of Murphy v. Clemens, 43 Mo. loc. cit. 403, in speaking of the delegation of power to the engineer by the city council, the court observed: “The law requires them to act not only in view of their direct responsibility to those who elected them, but also that they should exercise their united wisdom for the general good of the public. They can not delegate a duty plainly and expressly devolved upon them to the mere discretion, and perhaps caprice, of a single individual.” See, also, St. Joseph ex rel. v. Wilshire, 47 Mo. App. 130.
WMle the city by virtue of the legislative powers conferred upon it'by the city charter has the power and authority to establish sewers in the city, and, to provide plans and means for their construction, the city could not delegate such powers, they being legislative, and implying judgment and discretion, to any person or persons, by contract or otherwise. Nor could the city have terminated the contract in question in the absence of a provision in the contract authorizing it to do so. Besides [595]*595sucli power could no more be delegated to the city engineer than could the power to establish the sewer.
It is true the city could have reserved to itself, the right to have terminated the contract at any time, upon failure of the contractor to comply substantially with its terms, but she reserved no such right, but chose in so far as she could do so, to •confer the power upon the city engineer.
Defendant relies upon a number of adjudications as sustaining the power of the city engineer to terminate the contract, among which is Chapman v. City of Lowell, 4 Cush. 380. But in that case the city by contract retained control over the work which was to be done under and by the direction and supervision of a committee, both as -to quality of the work and time of completion, and the contractor was notified to stop the work, by the city, and not by the committee. Besides there was no question as to the delegation of such power by the city, in the committee to terminate the contract.
Bierty v. New Orleans, 24 La. Ann. 21, is another case relied upon by defendant. But in that case the contract expressly provided that the city might cancel the contract, '“in case the council be dissatisfied with the manner in which the work is being done.” This as we have said might be done, but in the case at bar no such power was reserved to the city.
Easton v. Canal Co., 13 Ohio, 79; Williams v. Railroad, 112 Mo. 463, and Chapman v. Railroad, 114 Mo. 542, are also relied upon by defendant but the contracts in those cases were between individuals, and private corporations possessing ordinary contractual powers in which were involved no legislative powers, or the delegation thereof, hence not in point.
Our conclusion is that the act of the city engineer in annulling the contract was without authority and void.
We think it.clear that it was beyond the power of Kansas 'City, by ordinance No. 5453, approved October 24, 1893, to impair the rights of plaintiff which existed under the contraen .at'the time of the passage of such ordinance, as such legisla[596]*596tion with respect to such a contract was unconstitutional and void. [Section 15, article II, Constitution of Missouri.]
Tire ordinance extending tbe time for the completion of the work made after the contract had been forfeited did not have the effect of vitalizing a contract which had theretofore been forfeited, nor create a new liability on the part of defendant upon tax bills issued upon such contract.
Our conclusion is that the time within which the contract was to be completed was an essential element in the contract, and, made so by the terms thereof for prudential reasons upon the part of the city, and that, as the contract was not complete within the time prescribed thereby, the tax bills issued for the work, and which form the basis of this action are null and void. "We therefore affirm the judgment'.
Uantt,R.J.,cou•curs; Sherwood, J., absent.