Maxine Thomas v. Housing Louisiana Now, L.L.C., Tracy F. Robinson, Master Builders & Contractors, L.L.C., Richard J. Mithun, Dean's Air Condition & Heating, L.L.C., and Dean Walters

• Court: Louisiana Court of Appeal
• Decided: March 21, 2024
• Docket: 2023-CA-0296
• Status: Published

Opinion

MAXINE THOMAS * NO. 2023-CA-0296

VERSUS * COURT OF APPEAL HOUSING LOUISIANA NOW, * L.L.C., TRACY F. ROBINSON, FOURTH CIRCUIT MASTER BUILDERS & * CONTRACTORS, L.L.C., STATE OF LOUISIANA RICHARD J. MITHUN, ******* DEAN'S AIR CONDITION & HEATING, L.L.C., AND DEAN WALTERS

APPEAL FROM CIVIL DISTRICT COURT, ORLEANS PARISH NO. 2018-08574, DIVISION “F-14” Honorable Jennifer M Medley, ****** Judge Daniel L. Dysart ****** (Court composed of Judge Daniel L. Dysart, Judge Sandra Cabrina Jenkins, Judge Karen K. Herman)

Philip Anthony Franco ADAMS AND REESE LLP 701 Poydras Street 4500 One Shell Square New Orleans, LA 70139-6534

COUNSEL FOR PLAINTIFF/APPELLEE

Terese M. Bennett THE LAW OFFICE OF TERESE M. BENNETT 813 S. Carrollton Avenue New Orleans, LA 70118

COUNSEL FOR DEFENDANT/APPELLANT

AMENDED, AND AS AMENDED, AFFIRMED MARCH 21, 2024 DLD This case involves a claim for breach of contract. The claim arises out of a SCJ KKH contract to perform repairs to a home that was severely damaged by several tornadoes in New Orleans on February 7, 2017. The homeowner, Maxine Thomas,

filed a breach of contract suit for nonperformance, defective performance and

delay in performance against defendant, Housing Louisiana Now, LLC (“HLN”),

who is the only appellant in this appeal. Other defendants named in plaintiff’s

petition included Tracy Robinson (the manager of HLN), Master Builders &

Contractors LLC (“MBC”), Richard J. Mithun (the manager of MBC), Dean’s Air-

Conditioning & Heating LLC, and Dean Walters (the manager of Dean’s).1 HLN,

MBC and Mithun filed reconventional demands for outstanding balances allegedly

owed to them by plaintiff, Thomas. The trial court rendered judgment in favor of

plaintiff and against defendant, HLN, in the amount of $83,597.03. All other

claims were dismissed with prejudice.

Plaintiff, an elderly widow, initially entered into a contract with MBC on

February 12, 2017, whereby MBC agreed to repair plaintiff’s home for the amount

of her insurance loss proceeds, $181,517.60. Subsequent to the execution of that

agreement, HLN and MBC decided to work together in an arrangement whereby 1 Plaintiff’s claims against Dean’s Air Conditioning and Heating, LLC, and Dean Walters were

severed prior to trial and are not relevant to this appeal. 1 HLN would be the general contractor on the project and MBC would work as one

of HLN’s subcontractors. A contract between plaintiff and HLN was then

executed on March 13, 2017, which superseded the original contract between

plaintiff and MBC. This subsequent contract provided that the prior contract with

MBC would be attached as the scope of work, and that the payment HLN would

receive for this project would be limited to the amount of plaintiff’s insurance

proceeds.

Because plaintiff had a reverse mortgage on her property, her insurance

company issued a check for the initial portion of the insurance proceeds to

plaintiff’s mortgage company. The mortgage company then issued a check that

was made payable to plaintiff and HLN in the amount of $83,597.03. This check

was dated May 5, 2017. Plaintiff endorsed the check and tendered the full amount

to HLN.

Tracy Robinson, the manager of HLN, accepted the check from plaintiff on

behalf of HLN, but subsequently decided not to go forward with the project for

several reasons, including because she believed that the repairs would cost more

than the amount of insurance proceeds due to plaintiff under her policy. She

testified that when she came to this conclusion, she initially wanted to return

plaintiff’s check and let plaintiff find another contractor.

However, Mr. Mithun told Ms. Robinson that MBC wanted the project so -

unbeknownst to plaintiff - HLN, through Ms. Robinson, endorsed the check for the

initial portion of plaintiff’s insurance proceeds over to MBC. It is unclear from the

record exactly when the check was deposited by MBC, but Ms. Robinson

estimated that she received it from plaintiff in late May 2017. A handwritten note

2 on the copy of the check in the record states that the check was deposited on June

9, 2017.

Ms. Robinson testified that she instructed Mr. Mithun to execute a new

contract between MBC and plaintiff. It is undisputed that this was never done.

On August 21, 2017, plaintiff sent a written notice terminating HLN as

contractor stating in the notice that the reason for the termination was “lack of

communication, sloppy work and no show.” She also stated, “I have not heard

from HLN since the check was picked up in May.” She further stated, “I do not

have a contract with Richard Mithum [sic].” When plaintiff sent the notice of

termination, she had no knowledge at that time that months earlier HLN had

decided not to go forward with the project, had given the project to MBC along

with $83,597.03 of plaintiff’s insurance proceeds or that MBC had been instructed

by Ms. Robinson to execute a new contract between MBC and plaintiff. Mr.

Mithun was asked at trial to explain why he did not take steps to execute a new

contract with plaintiff on behalf of MBC after Ms. Robinson told him that HLN did

not want to go forward with the project. He replied, “I don’t know that I have a

good answer for that.” The $83,597.03 check that HLN accepted from plaintiff

and endorsed to MBC was never returned to plaintiff. This suit by plaintiff for

breach of contract followed.

Following trial, judgment was entered in favor of plaintiff and against HLN

in the amount of $83,597.03 for breach of contract for nonperformance and delay

in performance. Plaintiff’s claims against the other remaining defendants were

dismissed with prejudice. Additionally, the reconventional demands filed against

plaintiff by defendants, HLN, MBC and Mithun, were dismissed with prejudice.

This appeal by HLN followed. 3 On appeal, HLN asserts the following assignments of error:

(1) The trial court erred by holding HLN liable for breach of contract and in failing to credit HLN for the performance of the solidary obligation by the subcontractor, MBC, despite having determined that the subcontractor had satisfactorily performed;

(2) The trial court erred in ordering HLN to repay plaintiff $83,597.03 that was paid to HLN, when the trial court determined that the value of the work already performed at the time of the termination equaled the amount of money plaintiff had paid to HLN as its initial payment under the HLN contract; and

(3) The trial court judgment contains an error of law in its attempted dismissal of Tracy Robinson, with prejudice, because she had been dismissed with prejudice two years earlier by the previous presiding judge on an exception of prescription, and therefore was not a defendant before the trial court at the trial of this matter.

Before addressing the arguments in the first two assignments of error, we

note that they are based in part on statements found in the trial court’s written

reasons for judgment. “[T]he district court’s oral or written reasons for judgment

form no part of the judgment, and … appellate courts review judgments, not

reasons for judgment.” Wooley v. Lucksinger, 2009-0571, p. 77 (La. 4/1/11), 61

So. 3d 507, 572, quoting Bellard v. American Cent. Ins. Co., 2007-1335 p. 25 (La.

4/18/08), 980 So.2d 654, 671; Greater New Orleans Expressway Comm’n v.

Olivier, 2002-2795, p. 3 (La. 11/18/03), 860 So.2d 22, 24 (“Appeals are taken from

the judgment, not the written reasons for judgment.”); La. C.C.P. arts. 1918, 2082

and 2083.

In the first assignment of error, HLN argues that the trial court erred by

holding HLN liable to plaintiff for breach of contract and in failing to credit HLN

for the performance of MBC. HLN contends that it did not breach its contract with

plaintiff. It further contends that HLN and MBC were solidary obligors, and that

4 HLN should have been credited for the work performed by MBC on plaintiff’s

home.

Plaintiff argues that the testimony and other evidence established that HLN

breached the contract with her by nonperformance, defective performance and

delay in performance of its obligation to repair her home, and by abandoning the

contract. Plaintiff further contends that because she had no contractual relationship

with MBC at the time of HLN’s breach, HLN and MBC were not solidary obligors

and HLN should not be credited for work performed by MBC on her home.

According to plaintiff, HLN accepted the $83,597.03 check from her that

she had already endorsed. Instead of endorsing and depositing the check to an

HLN account, HLN endorsed the check over to MBC and abandoned the contract

having no further involvement. Plaintiff said the evidence shows no one from

HLN ever visited the house before or during the project, communicated with her

on the progress of work or had any familiarity with the daily operations of the

work.

The “elements of a breach of contract claim are the existence of a contract,

the party’s breach thereof, and resulting damages.” Payphone Connection Plus,

Inc. v. Wagners Chef, LLC, 2019-0181, p. 8 (La.App. 4 Cir. 7/31/19), 276 So.3d

589, 595, quoting 1100 S. Jefferson Davis Parkway, LLC v. Williams, 2014-1326,

p. 5 (La.App. 4 Cir. 5/20/15), 165 So.3d 1211, 1216. The “party claiming the

rights under the contract bears the burden of proof.” Id., 2019-0181, p. 9, 276

So.3d at 595.

In Brenner v. Zaleski, 2014-1323 (La. App. 4 Cir. 6/3/15), 174 So.3d 76, this

Court set forth the standard of review for a breach of contract claim as follows:

5 A trier of fact's factual conclusions respecting a breach of contract claim are governed by the manifest error or clearly wrong standard of review. See Tarifa v. Riess, 02–1179, p. 10 (La.App. 4 Cir. 5/7/03), 856 So.2d 21, 27, as clarified on reh’g (9/3/03), writ denied, 03–2776 (La.12/19/03), 861 So.2d 574 and writ denied, 03–2755 (La.12/19/03), 861 So.2d 577. Where there is conflicting testimony, reasonable evaluations of credibility and inferences of fact should not be disturbed by the reviewing court. Rosell v. ESCO, 549 So.2d 840, 844 (La.1989). Where there are two permissible views of the evidence, the trier of fact’s choice between them cannot be manifestly erroneous or clearly wrong. Id. However, where one or more trial court legal errors interdict the fact-finding process, the manifest error standard is no longer applicable, and, if the record is otherwise complete, the appellate court should make its own independent de novo review of the record and determine a preponderance of the evidence. Evans v. Lungrin, 97-0541, 97-0577, pp. 6-7 (La.2/6/98), 708 So.2d 731, 735.

Brenner, 2014-1323, p. 3, 174 So.3d at 79.

Finding no legal errors interdicting the fact-finding process, the manifest

error or clearly wrong standard of review applies here.

Regarding the first element of a breach of contract claim, it is undisputed

that a contract existed between plaintiff and HLN whereby HLN would act as

general contractor for repairs to plaintiff’s home. The scope of work to be

performed by MBC, the subcontractor, was attached to the contract between

plaintiff and HLN.

With regard to the second element, the party’s breach of a contract, the

record established that HLN endorsed the check from plaintiff’s mortgage

company to MBC and turned the project over to MBC. HLN took these actions

without plaintiff’s knowledge or consent. Ms. Robinson stated at trial that she

decided for a variety of reasons that she no longer wanted to be directly involved

with this project so, in her words, “I handed it off to a subcontractor that was

already involved in the job, that already had a relationship with the homeowner,

that was experienced and knew exactly how to bring this job together.” Ms. 6 Robinson testified that she instructed Mr. Mithun to execute a new contract

between MBC and plaintiff, but this was never done.

Ms. Robinson testified that it was her understanding that HLN would still

have some involvement in the project, although not direct involvement, after her

conversation with Mr. Mithun about turning the project over to MBC. However,

her testimony also confirmed that no one from HLN supervised or directed the

work at plaintiff’s home. Ms. Robinson stated she allocated those responsibilities

to MBC.

The contract between plaintiff and HLN, as the contractor, included the

clause stating that “Contractor shall supervise and direct the Work and accepts

responsibility for construction means, methods, techniques, sequences and

procedures required to complete the Home Renovation Project in compliance with

the Contract Documents.” The record is clear that HLN breached this section of

the contract.

In addition to failing to perform the work it contracted to do, HLN also later

abandoned the contract when it endorsed the check from plaintiff’s mortgage

company to MBC, and turned the project over to MBC, all without plaintiff’s

knowledge or consent. The record supports a finding that HLN also breached its

contract with plaintiff by abandonment.

As for the third element required in a breach of contract claim, resulting

damages, the record establishes that the check for $83,597.03, representing a

portion of plaintiff’s insurance proceeds, was never returned to her. Additionally,

the evidence showed that plaintiff was required to engage other contractors to

perform the repairs on her house after she terminated her contract with HLN for

7 HLN’s breach of its responsibilities under the contract. Plaintiff testified that she

incurred additional expenses beyond those covered by her insurance proceeds.

In addition to arguing that it was not in breach of contract, HLN contends

that HLN and MBC were solidary obligors, and that HLN should have been

credited for the work performed by MBC on plaintiff’s home. HLN alleges that

the value of the work performed by MBC on plaintiff’s home prior to the date of

plaintiff’s termination notice exceeded the amount of the check that HLN endorsed

to MBC and discharges HLN’s liability to plaintiff under the law of solidary

obligations.

Louisiana Civil Code article 1794 states:

An obligation is solidary for the obligors when each obligor is liable for the whole performance. A performance rendered by one of the solidary obligors relieves the others of liability toward the obligee.

Louisiana Civil Code article 1796 provides:

Solidarity of obligation shall not be presumed. A solidary obligation arises from clear expression of the parties’ intent or from the law.

The record shows that HLN and MBC were not solidary obligors to plaintiff.

The earlier contract plaintiff had with MBC had been superseded by the contract

between plaintiff and HLN. After the subsequent contract between plaintiff and

HLN was executed, MBC became a subcontractor of HLN, and thereafter had no

contractual relationship with plaintiff.2

2 Although plaintiff alleged in her petition that HLN and MBC were liable to her in solido, the

evidence presented at trial established that they were not solidary obligors. In Littleton v. Montelepre Extended Care Hosp., 94-1661 (La.App. 4 Cir. 6/7/95), 657 So.2d 572, this Court rejected the argument that parties should be treated as solidary obligors because solidarity was alleged in the petition. “Solidarity is a legal relationship whose existence must depend upon facts required to support it.” Id., p. 2, 657 So.2d at 573. 8 We find no merit in HLN’s argument that the trial court erred in holding

HLN liable for breach of contract and in failing to credit HLN for the performance

of its subcontractor, MBC.

In the second assignment of error, HLN argues that the trial court erred in

ordering it to repay plaintiff $83,597.03 that was paid to HLN. As stated above,

HLN contends that the value of the work already performed by MBC at the time of

plaintiff’s termination of the HLN contract exceeded the amount of money plaintiff

had paid to HLN as its initial payment under the contract.

In support of this argument, HLN cites Louisiana Civil Code article 2765,

which states, “The proprietor has a right to cancel at pleasure the bargain he has

made, even in case the work has already been commenced, by paying the

undertaker for the expense and labor already incurred, and such damages as the

nature of the case may require.” However, in this case, we find the applicable

Civil Code article is Article 2769, which states, “If an undertaker fails to do the

work he has contracted to do, or if he does not execute it in the manner and at the

time he has agreed to do it, he shall be liable in damages for the losses that may

ensue from his non-compliance with his contract.”

As stated above, HLN and MBC were not solidary obligors. Plaintiff and

MBC did not have a contractual relationship after its earlier contract was

superseded by the contract between plaintiff and HLN.

HLN is not entitled to credit for work performed by another contractor with

whom plaintiff had no contractual relationship. HLN failed to supervise and direct

the work on plaintiff’s home as required by its contract with plaintiff, and

abandoned the contract by turning the project over to MBC without plaintiff’s

knowledge or consent. 9 Louisiana Civil Code article 1994 states:

An obligor is liable for the damages caused by his failure to perform a conventional obligation. A failure to perform results from nonperformance, defective performance, or delay in performance.

Plaintiff is entitled to the return of the full amount of her insurance proceeds

that were paid to HLN. HLN’s unilateral decision to endorse the check to MBC

and give the project for repairs of plaintiff’s home to MBC was not a decision for

which plaintiff is responsible. HLN argues that it incurred certain pre-termination

expenses related to the project, but the record does not include evidence supporting

payment by HLN for any such expenses. Louisiana Civil Code article 2299 states,

“A person who has received a payment or a thing not owed to him is bound to

restore it to the person from whom he received it.” We find the trial court did not

err in ordering HLN to repay plaintiff $83,597.03.

In its third assignment of error, HLN argues that the trial court judgment

contains an error of law in its attempted dismissal of Tracy Robinson, with

prejudice, because she had been dismissed with prejudice two years earlier by the

previous presiding judge on an exception of prescription, and therefore was not a

defendant before the trial court at the trial of this matter. We find this assignment

of error has merit.

In a previous appeal in this matter, this Court affirmed a trial court judgment

maintaining an exception of prescription filed by Tracy Robinson, and dismissing

her from this lawsuit with prejudice. Thomas v. Hous. Louisiana Now, L.L.C.,

2020-0183 (La. App. 4 Cir. 9/30/20), 369 So.3d 392. This Court found that

because plaintiff’s claim against Robinson was for intentional interference with a

contract, which is subject to a one-year prescriptive period, the claim against her

10 had prescribed because plaintiff’s petition was filed more than one year after the

termination of the contract between plaintiff and HLN. Id. Accordingly, because

Ms. Robinson was already dismissed with prejudice from this litigation prior to

trial of this matter, we will amend the trial court judgment in the instant appeal to

delete the reference to Tracy Robinson’s dismissal.

For the reasons stated above, the trial court judgment is amended to delete

the reference to the dismissal with prejudice of Tracy Robinson. In all other

respects, the trial court judgment is affirmed.

AMENDED, AND AS AMENDED, AFFIRMED