FILED Dec 30 2020, 9:05 am
CLERK Indiana Supreme Court Court of Appeals and Tax Court
ATTORNEYS FOR APPELLANT ATTORNEYS FOR APPELLEE Michael L. Einterz, Jr. Mark J. R. Merkle Michael L. Einterz William J. Barkimer Einterz & Einterz Krieg DeVault LLP Zionsville, Indiana Carmel, Indiana
IN THE COURT OF APPEALS OF INDIANA
Maples Health Care, Inc., December 30, 2020 Appellant-Plaintiff, Court of Appeals Case No. 20A-PL-1095 v. Appeal from the Hamilton Superior Court Firestone Building Products, The Honorable Appellee-Defendant. William J. Hughes, Judge Trial Court Cause No. 29D03-1603-PL-2240
Kirsch, Judge.
[1] Following the 2001 installation of its roof, Maples Health Care, Inc. (“Maples”)
had two warranties issued to it by Firestone Building Products (“Firestone”),
the Red Shield Roofing System Limited Warranty (“Red Shield Warranty”)
and Roofing Membrane Limited Warranty (“Membrane Warranty”). After a
bench trial covering both liability for breach of warranty and damages, the trial
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 1 of 27 court entered a judgment in favor of Maples, finding Firestone liable for breach
of warranty and awarding Maples damages in the amount of $9,500.00.
Following the trial court’s denial of Maples’s request for clarification and
motion to correct error, Maples raises the following issues for our review:
I. Whether the judgment finding Firestone liable for breach was as to both warranties; and
II. Whether the damage award was supported by the evidence.
[2] We affirm in part, reverse in part, and remand with instructions.
Facts and Procedural History [3] Maples owns an approximately one-hundred-year-old, five-story facility in
Bluefield, West Virginia, which it operates as a nursing home, long-term care,
and assisted living facility. Appellant’s App. Vol. 2 at 24; Tr. Vol. 2 at 19, 126.
Maples purchased a Firestone-brand roof, which was installed by MetalTec
Roofing, Inc. in March 2001. Appellant’s App. Vol. 2 at 24; Ex. Vol. 3 at 5-9. On
March 10, 2001, Firestone issued two warranties for the roof installation: a
fifteen-year Red Shield Warranty and a twenty-year Membrane Warranty. Ex.
Vol. 3 at 11-14.
[4] The Red Shield Warranty covers the Firestone Roofing System and provides
that it is limited to “the Firestone brand membranes, Firestone brand
insulations, and other Firestone brand accessories when installed in accordance
with Firestone technical specifications.” Id. at 14. Under the Red Shield
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 2 of 27 Warranty, Firestone agreed to repair leaks, specifying that Maples’s “sole and
exclusive remedy and Firestone’s liability shall be limited to the repair of the
leak.” Id. The Red Shield Warranty also included a provision regarding the
parties’ obligations specifying that, if Firestone determined that the cause of the
leak is “outside the scope of [the Red Shield Warranty],” Firestone was
required to “advise” Maples of “the type and/or extent of repairs required to be
made at [Maples’s] expense” to prevent the Red Shield Warranty from lapsing.
Id.
[5] The Red Shield Warranty excluded damage occurring from, among other
sources, “[d]eterioration or failure of building components, including, but not
limited to, the roof substrate, walls, mortar, HVAC units, etc.” and for
“[c]ondensation or infiltration of moisture in, through, or around the walls,
copings, rooftop-hardware or equipment, building structure or underlying or
surrounding materials” from warranty coverage. Id. The Red Shield Warranty
also provided that neither Firestone nor Maples could “commence or prosecute
any suit, proceeding, or claim [regarding the Red Shield Warranty] other than
in courts of Hamilton County in the State of Indiana or the United States
District Court, Southern District of Indiana, Indianapolis Division.” Id. The
Red Shield Warranty also contained the following language: “THIS LIMITED
WARRANTY SHALL BE THE OWNER’S SOLE AND EXCLUSIVE
REMEDY AGAINST FIRESTONE AND FIRESTONE SHALL NOT BE
LIABLE FOR ANY CONSEQUENTIAL, SPECIAL, INCIDENTAL OR
OTHER DAMAGES INCLUDING, BUT NOT LIMITED TO, LOSS OF
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 3 of 27 PROFITS OR DAMAGE TO THE BUILDING OR ITS CONTENTS OR
THE ROOF DECK.” Id.
[6] The Membrane Warranty, which covers the Firestone Roofing Membrane,
provides that it is limited to “the Firestone brand Membrane when installed in
accordance with Firestone Technical Specifications” and is a separate warranty
for leaks occurring through the Membrane as a result of weathering. Id. at 11.
The Membrane Warranty provides that Maples’s “sole and exclusive remedy
and Firestone’s liability shall be limited to the supply of replacement membrane
material sufficient to replace the affected area of membrane” as the remedy. Id.
The Membrane Warranty also contains provisions requiring Firestone to notify
Maples if the cause of a leak through the membrane is outside the scope of the
warranty, excluding damages from certain sources, and language disclaiming
Firestone’s liability for consequential, special, incidental, or other damages. Id.
Unlike the Red Shield Warranty, the Membrane Warranty does not include a
provision allowing for a lawsuit; instead, it provides that a dispute “shall be
settled by final and binding arbitration in accordance with the American
Arbitration Association’s rules for the construction industry.” Id.
[7] Maples first notified Firestone of a leak on June 29, 2006, and Firestone began
a leak tracer report to track the repair. Appellant’s App. Vol. 2 at 24; Ex. Vol. 3 at
122-30. Firestone Division Manager for Technical Services Ken Crocker
(“Crocker”) explained that a leak tracer report is a “tracking mechanism for any
activity on the project” that catalogues leak reports and includes the purchase
orders that Firestone receives from the responding contractor. Tr. Vol. 2 at 134-
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 4 of 27 35. From June 29, 2006 through December 8, 2015, Firestone issued a total of
twenty-two purchase orders for the investigation and repair of leaks that Maples
had reported pursuant to the Red Shield Warranty, and the leak tracer reports
and purchase orders were not provided to Maples until litigation was instituted.
Ex. Vol. 3 at 16; Tr. Vol. 2 at 21, 162. Crocker stated that the leak tracer reports
are subject to a “not to exceed” amount, which is a cost-control mechanism but
that “it’s a no-dollar limit warranty,” and “in some cases” Firestone had “spent
two or three times what the original roof cost,” but the not-to-exceed amount
“is placed on the contractor to go out with no further communication to us and
effect a repair.” Id. at 135.
[8] An invoice from Dunford Roofing, the contractor Firestone sent to respond to
the leak, that accompanied a May 4, 2009 leak repair contained a note about
the repair, which stated, “[l]ocated opening at scupper flashing due to severe
bridging.” Ex. Vol. 3 at 144. Crocker indicated that bridging is tied to the
freeze/thaw cycle which puts “stress on that membrane” and over time “the
membrane may or may not hold.” Tr. Vol. 2 at 142. Leaks continued to occur,
but James Montgomery (“Montgomery”), a project and facility manger for
Maples, explained that in October 2014 Maples began renovation work on its
fifth floor for use as rooms for residents. Tr. Vol. 2 at 41-42; Appellant’s App. Vol.
2 at 24. During the renovation, Maples’s contractor, Rick Blizzard
(“Blizzard”), discovered areas of the ceiling, insulation, and walls in the fifth,
fourth, and third floors of the building that were water-damaged, and he
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 5 of 27 contacted Firestone on November 14, 2014, requesting an investigation of the
roof. Tr. Vol. 2 at 43-44; Ex. Vol. 3 at 32-38.
[9] In a November 24, 2014 email to Blizzard, Firestone representative for Quality
and Building Services Tom Julian (“Julian”) explained that up to that point
there had been no previous investigation of the roof, but he suspected that “the
exterior masonry walls are a plausible and likely cause of the water penetration
into the building.” Ex. Vol. 3 at 41. He noted that “the photos of the leak
locations all appear to be near to [a] wall,” which is “consistent with water
penetration through the wall.” Id. Julian wrote that there were “substantial
repairs to the bridged flashing, but the bridged flashing was likely not leaking”
because the “repairs would have eliminated any leak source in the system along
these wall areas.” Id. at 42. He recommended to Blizzard an evaluation of “the
exterior masonry wall as a source or contributor to the water penetration at the
building.” Id.
[10] Firestone assigned Mark Christian (“Christian”) to perform the investigation in
January 2015. Ex. Vol. 3 at 106; Appellant’s App. Vol. 2 at 26. A January 8, 2015
email forwarded to Christian regarding the Maples investigation showed that
Julian wanted to “keep all correspondence (including this email) confidential to
Firestone personnel, don’t share it w/ the building owner, consultant, roofing
contractor or sales rep.” Ex. Vol. 3 at 111. In a January 15, 2015 email to
Dunford Roofing and Julian, Christian reported the results of his investigation,
writing that, “[a]long the south east wall of the penthouse I found that the
bridging EPDM has pulled the termination bar away from the masonry wall of
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 6 of 27 the penthouse” and that “about 22 feet of wall flashing that needs to be
repaired.” Id. at 106. He added that, if it could be repaired for “$2000.00 or
less, (less being great for us),” Julian could approve the repair immediately, but
if it would cost more than $2,000.00, a repair proposal would be necessary. Id.
The investigation results were not shared with Maples. Tr. Vol. 2 at 61.
[11] Dunford Roofing performed the repair identified in the investigation on
January 26, 2015 for $1,972.72. Ex. Vol. 4 at 21; Appellant’s App. Vol. 2 at 26.
Following the repair, Maples continued with the fifth-floor renovation project,
completing the work in early March 2015 but incurring additional costs to
address the water damage and construction delays. Tr. Vol. 2 at 63-65, 72-73.
After the renovation was complete, another leak was reported on March 26,
2015 and was repaired at a cost of $990.04. Ex. Vol. 4 at 24-30. Maples
reported another leak on November 4, 2015 that was repaired by Dunford
Roofing. Ex. Vol. 4 at 32-36. Maples approached Dunford Roofing to
determine what needed to be done to address the leaks. Tr. Vol. 2 at 66-67.
Dunford Roofing provided Maples with a roof repair estimate dated November
11, 2015, at a cost of $9,500.00, which included the removal of “280 [linear
feet] of old bridged out EPDM wall flashing” along with installation of “new
base tie in detail at wall perimeters” and to “[s]plice new EPDM roof
membrane into existing roof . . . .” Ex. Vol. 3 at 116. Montgomery stated that
Maples did not pursue this work because it “thought that the issues on the roof
should have been covered by Firestone because of our ongoing problems with
the roof.” Tr. Vol. 2 at 67.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 7 of 27 [12] Maples reported another leak on December 7, 2015, which was repaired by
Dunford Roofing. Ex. Vol. 4 at 38-45. After this leak notification, Ronald
Scherer (“Scherer”), Maples’s Chairman, sent Julian a letter on January 12,
2016 regarding the leaks that had occurred since 2006.1 Tr. Vol. 2 at 122-23; Ex.
Vol. 3 at 119-21. Scherer wrote that the issues Maples had experienced were a
result of “improper installation” by “[Firestone’s] authorized installer
[MetalTec Roofing, Inc.].” Id. at 120. Scherer added that the roof’s issues
resulted in a “substantial loss of revenue,” and in the renovation of its fifth-floor
rooms, Maples had to spend additional money to repair water-damaged areas
because of the roof. Id. at 121. Noting that, with “only months left under
warranty,” Scherer requested that “Firestone take steps to properly install a new
replacement roof system to correct the failures we have experienced to date.”
Id. Scherer acknowledged that “one of the two warranties either called for
mediation or arbitration,” but Firestone did not respond to his letter. Tr. Vol. 2
at 124.
[13] As to the leak repairs that had occurred at Maples’s facility, Crocker explained
that, although he had never visited the facility, “every time we did a leak, we
may have been repairing one here, but we’re disturbing the membrane here and
1 Scherer’s letter begins, “[w]e have discovered yet another new failure in the roofing system. This is the 19th or 20th warranty claim since 2006 resulting in more than 25 individual repair areas,” and it is not clear whether this was reporting a new leak or if it was a reference to the December 7, 2015 leak that had been repaired. Ex. Vol. 3 at 120; Ex. Vol. 4 at 38-45. Scherer’s letter does not appear to have specifically requested either mediation or arbitration. Ex. Vol. 3 at 119-21.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 8 of 27 here on both sides of where we were working,” which resulted in the leaks
“[w]alking down the wall” over time. Id. at 148.
[14] On March 9, 2016, one day before the expiration of the Red Shield Warranty,
Maples filed a complaint alleging that Firestone failed to repair the leaks over
the period of 2006 through 2016 and refused “to perform necessary repairs in
2015 and 2016” and seeking damages for the breach. Appellant’s App. Vol. 2 at 4.
Maples’s complaint principally referred to the Red Shield Warranty but also
mentioned the Membrane Warranty, and it attached a copy of the Red Shield
Warranty but did not attach a copy of the Membrane Warranty. Id. Firestone
filed its answer on May 12, 2016, in which it denied that Maples was entitled to
the recovery of damages for the alleged breach of warranty and asserted
affirmative defenses. Id. at 6-11. The parties filed motions for summary
judgment, which were denied, and the case proceeded to a bench trial.
Appellant’s App. Vol. 2 at 63, 120.
[15] The bench trial began on February 24, 2020 and addressed both liability and
damages. Tr. Vol. 2 at 2. As to damages, Montgomery testified that Maples
suffered monetary damages in the amount of $308,600.00, and he provided a
breakdown of the costs involved in that proposed award. Id. at 70-75.
Regarding the value of the fifth-floor construction and renovation work,
Montgomery stated that the amount was “roughly around $100,000[.00],”
which included “drywall replacement . . . tearing out the walls and ceilings,
replacing insulation[,]” rewiring damaged electrical outlets, and replacing
“rusted out” ceiling struts. Id. at 72. The value of employing Blizzard for the
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 9 of 27 additional time and labor was “about an additional $25,000[.00] . . . for the
additional two months.” Id. at 72-73. Montgomery stated that the value of the
loss of use of thirteen rooms on the fifth floor for two months was $54,600.00.
Id. at 73.
[16] Montgomery added that Maples incurred additional labor and maintenance
costs of $10,000.00 because its maintenance personnel “were involved,
obviously almost continuously on the roof.” Id. at 73. He stated that, each
time it rains, “we have to go around and reinspect all the rooms” to avoid “a
citation from the State of West Virginia” on account of possible health issues
and not “lose those patients, or even potentially lose our license . . . we literally
have to go into every room, reinspect everything. We reinspect the roof every
time it rains or snows, and we’ll have to continue doing that until this problem
is solved.” Id. Montgomery based the $10,000.00 figure on an estimate of the
employees’ “[n]umber of hours times their hourly rate plus incentive, plus their
benefit” as part of the additional labor and maintenance costs. Id. at 74.
Montgomery also proposed a figure of $50,000.00 for the value of “additional
employee time,” which included his own time and that of “the owner, his wife,
the nursing home, nursing director, housekeeping . . . to go in there . . . to
reclean all those rooms and everything and the LPN.” Id. He also testified that
the quote for Maples to get a new roof was $69,000.00, which was included in
the proposed damage award. Id. at 75. He also added that the damages could
be much more than that because Maples did not yet know the “damage to the
roof deck itself cause until we remove that membrane, we don’t even know
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 10 of 27 what’s under there due the extensive damage from water constantly going
through our roof deck itself.” Id. Maples did not submit any documentation,
invoices, or estimates or otherwise provide any additional evidence as to its
damages. Id. at 70-75.
[17] On cross-examination, Montgomery acknowledged having received the
$9,500.00 repair estimate from Dunford Roofing. Id. at 76. In response to
whether its claims “relating to lost use of the premises on the fifth floor would
have been alleviated” if Maples had done the repairs identified in the $9,500.00
repair estimate from Dunford Roofing, Montgomery stated “[t]hat’s what they
were presenting. I do not know that.” Id. at 76. Firestone also elicited
testimony from Montgomery that no expert had ever determined that the
membrane was defective and that no masonry repairs such as tuckpointing or
caulking around windows had occurred. Id. at 78-80. In response to a question
about whether the damages that Montgomery had proposed in his direct
testimony were excluded under the language in the Red Shield Warranty,
which disclaimed Firestone’s liability for “any consequential, special, or
incidental or other damages, including, but not limited to loss of profits or
damage to the building or its contents or the roof deck,” Montgomery
responded “[o]kay. I, again, that’s a legal area. I’m not a lawyer, so I, I
couldn’t tell you.” Id. at 80-81.
[18] In closing, as to damages, counsel for Maples stated that Firestone had an
“obligation under the warranty to fully repair this leak when they first found it”
but that they did not do it and it caused Maples “[$308,600.00] in damages and
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 11 of 27 therefore that award of damages to Maples is proper here.” Id. at 157.
Firestone’s counsel argued that “as a matter of mitigation of damages, [Maples]
had known back in November of ’14 [sic] that Dunford Roofing would have
allegedly completed the total repair for [$9,500.00]. So, at that point in time,
[Maples] could have gone forward and made the repairs and mitigated the
damages.” Id. at 167-68. Firestone’s counsel engaged in the following
exchange with the trial court over the matter of the warranty’s exclusions for
lost profits and damages to the building:
THE COURT: Doesn’t that only apply if you comply with the warranty and breach of warranty includes consequential damages, even if it’s a breach of a specific warranty[?]
....
MR. MERKLE: Actually the law is, is, is quite explicit that you can have both . . . that just because, even if you were to fail to make the repair warranty, that does not exclude or, or invalidate the ah, claims for the ah, inconsequential, the disclaimer of inconsequential and [sic] incidental damage. That’s the Rheem versus Phelps Heating case, 746 N.E.2d 941 by our Supreme Court on May 9, 2001.[2]
2 Rheem Mfg. Co. v. Phelps Heating & Air Conditioning, Inc., 746 N.E.2d 941, 948 (Ind. 2001) (explaining that with respect to an exclusion of incidental and consequential damages in a limited warranty that even where a remedy in a limited warranty fails of its essential purpose that such an exclusion is valid unless the exclusion is unconscionable).
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 12 of 27 THE COURT: Okay.
MR. MERKLE: So, what we have here . . . Your Honor, is that . . . there’s no determination [the] disclaimers of the damages that are at the bottom of the warranty should not be enforced and so, if ah, if the Court were to even determine that there was a breach of the repair under the warranty, the disclaimers is still valid and would be ah, ah, and would keep out any of these claims over and above the $9500[.00] which is what has been the evidence shows as the cost of the repair.
Id. at 168-69. In reply, as to the disclaimer of consequential damages and
Rheem, Maples’s counsel was “not familiar with the Rheem case” but
contended that Firestone was arguing “if we don’t do what we’re supposed to
and fix the leak, you can’t do anything except ask us to fix it later. Well, the
problem is if you don’t fix a leak, you get water damage.” Id. at 171. Maples
further contended that it should be awarded the full $308,600.00 in damages
because Firestone did not “appropriately respond” to the report of the roof’s
bridging in 2009 that it “can’t now come back and claim defense of the contract
when they are the ones in breach,” and that Maples “incurred a whole slew of
damages solely because of [Firestone’s] breach.” Id.
[19] After the bench trial, the trial court issued a judgment “in favor of [Maples] and
against [Firestone] on [Maples’s] complaint for breach of warranty” and that
Maples had “proved damages in the sum of $9,500[.00] as a result of
[Firestone’s] breach of warranty.” Appellant’s App. Vol. 2 at 146-47. Maples
then filed a request for clarification and motion to correct errors, seeking to
clarify whether the trial court’s order finding Firestone in breach extended to Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 13 of 27 both the Red Shield Warranty and the Membrane Warranty and the proper
measure of damages for the breach. Id. at 148-57. Firestone responded,
arguing that Firestone was in breach only as to the Red Shield Warranty, which
it maintained was the sole warranty claim Maples alleged in its complaint, and
that the trial court correctly determined Maples’s damages. Id. at 159-65.
[20] On May 5, 2020, the trial court held a hearing on Maples’s request for
clarification and motion to correct error and heard argument from the parties.
Tr. Vol. 2 at 173. At that hearing, Maples’s counsel first argued that
clarification as to which warranty was breached was necessary because it
believed it had argued at trial that the Membrane Warranty had also been
breached but that it was “not sure if the [Membrane Warranty]” was included
in the judgment. Id. at 176. As to damages stemming from the breach, Maples
maintained that “[t]he question is not ah, whether or not the warranty failed in
its essential purpose for whether or not the warranty was unconscionable” but
that Firestone did not comply with its obligations to repair the leaks and that
when there is a “breach of contract, the appropriate measure of damages are
those that are reasonably foreseeable consequences of not performing your
obligations under the contract.” Id. at 177. Maples argued that Firestone’s
failure to fix the bridging, the underlying problem, caused water damage and
delays in construction resulting in damages of $308,600.00 from Firestone’s
failure to fix those leaks. Id. at 178. It contended that the award of $9,500.00
was not supported by the evidence, that the water damage was not disputed,
and that it should have been awarded the full $308,600.00. Id.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 14 of 27 [21] Firestone argued that the only competent evidence to support the measure of
damages was the $9,500.00 estimate from Dunford Roofing to repair the roof
and that the Red Shield Warranty provides “for the repairs of leaks, not the
repair of other items, so until the bridging actually exhibited a leak, ah there
would not be a necessity to actually complete a repair,” and the trial court’s
damage award reflects this consideration in its use of the $9,500.00 repair
estimate. Id. at 178-79. It also argued that Rheem provided a guide to the trial
court’s award of damages because the parties’ dispute, like the dispute in
Rheem, involved “a [sale] of goods between merchants,” keeping it within the
ambit of the sales provisions of the Indiana Uniform Commercial Code
(“UCC”). Id. at 179. It further argued that, under Rheem, when a limited
warranty of repair fails, that a disclaimer of consequential or incidental
damages is not invalidated unless the disclaimer is unconscionable and that
unconscionability was not raised by Maples. Id. at 179-80. Firestone noted that
there was a breach but that the “remedy is the damages resulting from that
exact breach of the repair,” which was the $9,500.00 that the trial court
awarded. Id. at 181. Finally, Firestone’s counsel stated that Rheem “stands on
all fours with our case” because “there was no failure in essential purpose of the
limited remedy and also even if there had been, it would not disclaim, it would
not result in the, the other [consequential] damages being allowed to be
recovered by [Maples.]” Id.
[22] Counsel for Maples disagreed with the applicability of Rheem and the UCC to
the dispute over damages, countering that “our claim is that Firestone breached
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 15 of 27 its obligations under the warranty, therefore the UCC is not applicable here.”
Id. at 183. Counsel maintained that, because the trial court determined
Firestone “failed to carry” its “obligations under the warranty . . . the
consequential damages here include all of the water damages, all of the lost
employee time, all of the delays” and should be reflected in the damage award.
[23] At the conclusion of the hearing, the trial court orally denied Maples’s request
for clarification and motion to correct errors. Id. at 183-84. The trial court
entered a written order on its oral denial of the request for clarification and
motion to correct errors, stating that its judgment finding breach was “as to all
claims made by [Maples] in its complaint” and that the damages entered were
“the maximum damages supported by competent evidence.” Id. at 166-
67. Maples now appeals.
Discussion and Decision [24] Maples appeals following the denial of its request for clarification and motion
to correct error, seeking to clarify whether the finding of breach was as to both
the Red Shield Warranty and the Membrane Warranty and arguing that the
damage award was not supported by the evidence.3 We review a trial court’s
denial of a motion to correct error for an abuse of discretion. Allstate Ins. Co. v.
3 To the extent Firestone contends that Indiana Trial Rule 52(A) represents the standard of review in this case, we note that while this is an appeal from a bench trial the trial court made no findings and conclusions.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 16 of 27 Hammond, 759 N.E.2d 1162, 1165 (Ind. Ct. App. 2001). We reverse only when
“the trial court’s decision was against the logic and effect of the facts and
circumstances before it, together with the inferences that can be drawn
therefrom.” Hockema v. J.S., 832 N.E.2d 537, 541 (Ind. Ct. App. 2005), trans.
denied.
I. Did the Judgment Cover Breach of Both Warranties? [25] Maples maintains that the judgment of breach extends to both the Red Shield
Warranty and the Membrane Warranty. It argues that the trial court’s
statement in its order on Maples’s request for clarification and motion to correct
error, which stated that the judgment was “as to all claims made by [Maples] in
its complaint,” amounts to a conclusion by the trial court that it was entitled to
the relief it sought in the complaint, specifically for water damages and the cost
of repairs to its facility due to breach of both warranties. Appellant’s Br. at 12
(quoting Appellant’s App. Vol. 2 at 166-67).
[26] We disagree that Maples made a separate claim under the Membrane Warranty
in its complaint. First, the Membrane Warranty expressly provided that “any
dispute, controversy, or claim” between Maples and Firestone concerning the
Membrane Warranty “shall be settled by final and binding arbitration in
accordance with the American Arbitration Association’s rules for the
construction industry.” Ex. Vol. 3 at 11. The dispute resolution provision of the
Membrane Warranty called for arbitration and did not authorize the filing of a
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 17 of 27 lawsuit in the event of a dispute, controversy, or claim between the parties.
Second, paragraph 4 of Maples’s complaint alleged as follows:
Firestone granted Maples a 15-year Roofing System Limited Warranty and a 20-year Roofing Membrane Warranty. A copy of the Roofing System Limited Warranty (“Warranty”) is attached as exhibit A. By the terms of the Warranty, the 15[- ]year period began March 10, 2001 and had not yet expired on the date this Complaint was filed. As required by the Warranty, Maples has requested that Firestone mediate this dispute.
Appellant’s App. Vol. 2 at 2. It is clear that the complaint mentioned the
existence of the Membrane Warranty, but it did not otherwise specifically raise
a claim under the Membrane Warranty and did not attach a copy of the
Membrane Warranty. See Ind. Trial Rule 9.2(A) (“When any pleading allowed
by these rules is founded on a written instrument, the original, or a copy
thereof, shall be included in or filed with the pleading.”). In the complaint,
Maples used the defined term “Warranty” in reference to the 15-year Roofing
System Limited Warranty, attached that warranty to the complaint, and
referred throughout the complaint to the “Warranty” which, as noted, referred
only to the 15-year Roofing System Limited Warranty. Id. at 2-4. In particular,
Maples’s complaint alleged that it had requested Firestone “pursuant to the
Warranty, complete the full repairs, but Firestone failed and refused to perform
any additional repairs.” Id. at 3 (emphasis added). Similarly, in paragraph 12
of the complaint, Maples contended that “Firestone’s insufficient repairs from
2006 until 2016 constitute a breach of the Warranty with Maples” entitling it to
“damages incurred as a consequence of the breach, including water damage
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 18 of 27 suffered to its property.” Id. (emphasis added). Similarly, paragraph 13, the
complaint’s other request for relief, stated that “Firestone’s failure and refusal to
perform necessary repairs in 2015 and 2016 constitutes [an] additional Breach
of the Warranty with Maples,” entitling it to “recover damages incurred as a
consequence of breach, including the cost to perform the necessary repairs by a
contractor of Maples’[s] choice.” Id. at 4 (emphasis added). Thus, the
complaint is best read as encompassing only the Red Shield Warranty, and, as
noted, the proper venue for a dispute under the Membrane Warranty was an
arbitral panel and not the trial court. Ex. Vol. 3 at 11. Therefore, the trial
court’s judgment finding Firestone liable for breach extends only to the Red
Shield Warranty as it was the sole claim alleged in the complaint that was
properly before the trial court, and we affirm that judgment only as to breach of
the Red Shield Warranty.4
II. Was the Damage Award Supported by the Evidence? [27] We next address whether the damage award was supported by the evidence.
Maples argues that the damage award is unsupported by the evidence because it
does not take into account Montgomery’s testimony, which estimated Maples’s
damages at $308,600.00. The computation of damages for a breach of contract
is a matter within the sound discretion of the trial court. City of Jeffersonville v.
Env’t Mgmt. Corp., 954 N.E.2d 1000, 1015 (Ind. Ct. App. 2011). We will not
4 On remand, we order the trial court to refer any dispute, claim, or controversy arising under the Membrane Warranty to arbitration.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 19 of 27 reverse a damage award upon appeal unless it is based on insufficient evidence
or is contrary to law. Id. In determining whether an award is within the scope
of the evidence, we may not reweigh the evidence or judge the credibility of
witnesses. Id. A factfinder may not award damages on the mere basis of
conjecture and speculation. Sheek v. Mark A. Morin Logging, Inc., 993 N.E.2d
280, 287 (Ind. Ct. App. 2013) (citing Indianapolis City Mkt. Corp. v. MAV, Inc .,
915 N.E.2d 1013, 1024 (Ind. Ct. App. 2009)), trans. denied. Instead, the award
must be supported by probative evidence. Id. (citing Four Seasons Mfg., Inc. v.
1001 Coliseum, LLC, 870 N.E.2d 494, 507 (Ind. Ct. App. 2007)). “Accordingly,
a damage award must reference some fairly defined standard, such as cost of
repair, market value, established experience, rental value, loss of use, loss of
profits, or direct inference from known circumstances.” Farah, LLC v. Architura
Corp., 952 N.E.2d 328, 337 (Ind. Ct. App. 2011) (quoting Coffman v. Olson & Co.,
P.C., 906 N.E.2d 201, 210 (Ind. Ct. App. 2009), trans. denied.). In a breach of
contract action, the measure of damages is the loss actually suffered by the
breach. Sisters of St. Francis Health Servs., Inc. v. EON Props., LLC, 968 N.E.2d
305, 313 (Ind. Ct. App. 2012). That said, the non-breaching party is not
entitled to be placed in a better position than it would have been if the contract
had not been broken. Id.
[28] Here, without any explanation, the trial court’s order awarded damages to
Maples in the amount of $9,500.00. Appellant’s App. Vol. 2 at 146. Similarly, in
denying Maples’s request for clarification and motion to correct error, the trial
court’s order again stated, without further explanation, that the amount of
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 20 of 27 damages was “the maximum damages supported by competent evidence.” Id.
at 167. Neither the trial court’s damage order, nor its denial of Maples’s request
for clarification and motion to correct error, expressly state what the damage
award was based upon or the method used to determine that $9,500.00 was an
appropriate measure of Maples’s damages and neither contains any findings or
conclusions. Id. at 146, 166-67.
[29] Maples bases its proposed damage award principally on the testimony of
Montgomery, who explained that the $308,600.00 covered Maples’s costs for
construction and renovation, including additional contractor time, additional
labor and maintenance expenses to monitor the roof, additional employee time
to monitor the rooms, and the cost of a replacement roof, and contending that
Montgomery’s figures were not questioned or refuted on cross-examination,
that his testimony was not based on speculation, and that Firestone did not
propose any alternative figures. Appellant’s Br. at 14-17. Maples asserts that the
damage award is an “all-or-nothing proposal: either Firestone is not liable, or,
if Firestone is liable, they are responsible for the ‘loss actually suffered’ by
Maples -- the $9,500[.00] figure does not correspond to any evidence regarding
the losses suffered by Maples.” Id. at 18.
[30] Here, the $9,500.00 repair quote from Dunford Roofing appears to have been
the trial court’s evidentiary basis for the damage award. Ex. Vol. 3 at 116. The
trial court was not required to accept Maples’s much higher figure as the
amount of its damages, see Farah, 952 N.E.2d at 339-40, but it is unclear
whether the trial court concluded that the $9,500.00 in fact reflected the cost of
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 21 of 27 repair as the measure of Maples’s damages, as it stated only that Maples
“proved damages of $9,500[.00]” and in the order on Maples’s request for
clarification and motion to correct error that the damage award reflected “the
maximum damages supported by competent evidence.” Appellant’s App. Vol. 2
at 146, 166-67; Tr. Vol. 2 at 67, 78; Ex. Vol. 3 at 116. We agree with Maples that
the record also shows a history of spot-repairs to address recurrent leaks that
had the effect of “[w]alking [the leaks] down the wall” over time. Tr. Vol. 2 at
148. Maples raises a number of other arguments that are connected with the
trial court’s basis for its damage award. Specifically, that the duty to mitigate
its damages5 does not support the trial court’s $9,500.00 award and that neither
the UCC’s sales provisions6 nor the holding of Rheem regarding the validity of
limitations on incidental or consequential damages 7 in a limited warranty under
5 Generally, the non-breaching party to a contract has a duty to mitigate damages that stem from the breach. Fischer v. Heymann, 12 N.E.3d 867, 871 (Ind. 2014) (citations omitted). Regarding mitigation, we note that a discussion about the possibility of water infiltration into the facility through the exterior masonry walls occurred with Blizzard, but there is no indication that Maples was directly informed of the possible masonry issues. Tr. Vol. 2 at 61, 102; Ex. Vol. 3 at 41-42. Likewise, the roof investigation and leak tracer reports were also not provided to Maples until litigation ensued, and it is unclear whether any of the recommendations in those reports were stated verbally to Maples personnel. Tr. Vol. 2 at 61, 162; Ex. Vol. 3 at 111. 6 We note that the UCC provides “[u]nless the context requires otherwise, IC 26-1-2 applies to transactions in goods.” Ind. Code § 26-1-2-102. It defines “goods”, in pertinent part, as “all things (including specially manufactured goods) which are movable at the time of identification to the contract for sale, other than the money in which the price is to be paid, investment securities (IC 26-1-8.1), and things in action.” Ind. Code § 26-1-2-105. The Indiana Supreme Court has noted that “[m]any modern commercial transactions cannot be classified as transactions purely for goods or for services, but are ‘mixed,’ involving both goods and services.” Insul-Mark Midwest, Inc. v. Mod. Materials, Inc., 612 N.E.2d 550, 553-54 (Ind. 1993). In such situations, courts typically require the application of the predominant thrust analysis to determine whether the UCC is applicable to a transaction. Id. at 556. The record shows that MetalTec Roofing, Inc. installed the roof in March 2001, and that Firestone sold the two warranties to Maples. Ex. Vol. 3 at 5-9. 7 Generally, consequential damages may be awarded for breach when the non-breaching party’s loss flows naturally and probably from the breach and was contemplated by the parties when the contract was made. Johnson v. Scandia Assocs., Inc., 717 N.E.2d 24, 31 (Ind. 1999). The UCC also allows for the recovery of incidental or consequential damages upon breach and for limitations on remedies and damages. See Ind.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 22 of 27 Indiana Code section 26-1-2-719(3) apply to the present dispute. Although the
parties argued below about these topics, the trial court’s orders regarding
damages were silent as to whether it concluded the parties’ dispute was subject
to the UCC’s sales provisions or governed by the common law of contracts,
whether the $308,600.00 in damages that Maples sought were incidental or
consequential damages unavailable to it pursuant to Rheem, or whether Maples
failed to mitigate its damages. To the extent the trial court’s damage award is
based on the $9,500.00 repair invoice, it is within the evidence presented, but
we cannot say that the $9,500.00 award is based on probative evidence in light
of the record of spot-repairs as to the measure of Maples’s damages. See
Whitaker v. Brunner, 814 N.E.2d 288, 296 (Ind. Ct. App. 2004) (“The damage
award cannot be based on speculation, conjecture, or surmise, and must be
supported by probative evidence.”) (emphasis added), trans. denied. We,
therefore, reverse the damage award and the order on the request for
clarification and motion to correct error as to damages. We remand with
instructions to hold another hearing on damages that addresses: (1) the
appropriate measure of damages, including (if necessary) the use of a third-
party expert to review the pleadings and evidence and render an opinion on the
calculation of damages; (2) whether Maples failed to mitigate its damages; and
Code § 26-1-2-715 (providing for the recovery incidental and consequential damages on breach); Ind. Code § 26-1-2-316(4) (“Remedies for breach of warranty can be limited in accordance with the provisions of IC 26-1- 2-718 and IC 26-1-2-719 on liquidation or limitation of damages and on contractual modification of remedy.”) In addition, “[c]onsequential damages may be limited or excluded unless the limitation or exclusion is unconscionable.” Ind. Code § 26-1-2-719(3); see also Rheem, 746 N.E.2d at 948.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 23 of 27 (3) whether the UCC applies and if Rheem limits Maples’s proposed damage
award; with an order containing findings and conclusions that explain the
damage award.
[31] Affirmed in part, reversed in part, and remanded with instructions.
Pyle, J. concurs.
Tavitas, J., concurs in part and dissents in part with separate opinion.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 24 of 27 IN THE COURT OF APPEALS OF INDIANA
Maples Health Care, Inc., Court of Appeals Case No. 20A-PL-1095 Appellant-Plaintiff,
v.
Firestone Building Products, Appellee-Defendant.
Tavitas, Judge, concurs in part and dissents in part.
[32] I respectfully concur in part and dissent in part. I agree with the majority’s
determination affirming the trial court as to breach of the Red Shield Warranty.
I dissent, however, regarding the majority’s reversal of the damage award. I
conclude that the trial court’s damage award is supported by the evidence, and I
would affirm.
[33] The majority notes that the trial court awarded $9,500.00 in damages to Maples
without any explanation. The parties, however, did not request findings of fact
and conclusions thereon pursuant to Indiana Trial Rule 52, and the trial court
did not issue findings of fact and conclusions thereon. “In the absence of
special findings, we review a trial court decision as a general judgment and, Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 25 of 27 without reweighing evidence or considering witness credibility, affirm if
sustainable upon any theory consistent with the evidence.” Baxendale v. Raich,
878 N.E.2d 1252, 1257 (Ind. 2008). “In reviewing a general judgment, we must
presume that the trial court correctly followed the law.” Perdue Farms, Inc. v.
Pryor, 683 N.E.2d 239, 240 (Ind. 1997).
[34] The computation of damages is a matter within the discretion of the trial court.
Ponziano Const. Servs. Inc. v. Quadri Enterprises, LLC, 980 N.E.2d 867, 873 (Ind.
Ct. App. 2012). Mathematical certainty is not required, but the amount
awarded must be supported by evidence in the record and may not be based on
mere conjecture, speculation, or guesswork. Id. “When the specific issue on
review relates to a question of inadequate or excessive damages, we will not
reverse a damage award if it is within the scope of the evidence before the trial
court . . . .” Id.
[35] Here, the Red Shield Warranty provided that Maples’s “sole and exclusive
remedy and Firestone’s liability shall be limited to the repair of the leak.” Ex. Vol.
III p. 13 (emphasis added). The Red Shield Warranty excluded damage
occurring from “[d]eterioration or failure of building components, including,
but not limited to, the roof substrate, walls, mortar, HVAC units, etc.” and for
“[c]ondensation or infiltration of moisture in, through, or around the walls,
copings, rooftop-hardware or equipment, building structure or underlying or
surrounding materials” from warranty coverage. Id. The Red Shield Warranty
also provided: “THIS LIMITED WARRANTY SHALL BE THE OWNER’S
SOLE AND EXCLUSIVE REMEDY AGAINST FIRESTONE AND
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 26 of 27 FIRESTONE SHALL NOT BE LIABLE FOR ANY CONSEQUENTIAL,
SPECIAL, INCIDENTAL OR OTHER DAMAGES INCLUDING, BUT
NOT LIMITED TO, LOSS OF PROFITS OR DAMAGE TO THE
BUILDING OR ITS CONTENTS OR THE ROOF DECK.” Id.
[36] Pursuant to the Red Shield Warranty, Firestone’s liability was limited to the
repair of the leak and excluded consequential damages. James Montgomery
testified that Dunford Roofing gave him an estimate of $9,500.00 to repair the
roof. The trial court found that Maples proved damages in the amount of
$9,500.00. The trial court’s damage award was within the scope of the
evidence, and I would affirm. Accordingly, I dissent from the majority’s
reversal and remand of the damage award.
Court of Appeals of Indiana | Opinion 20A-PL-1095 | December 30, 2020 Page 27 of 27