First Hartford Realty Corporation v. Food Ventures North America, Inc.
This text of First Hartford Realty Corporation v. Food Ventures North America, Inc. (First Hartford Realty Corporation v. Food Ventures North America, Inc.) is published on Counsel Stack Legal Research, covering Superior Court of Delaware primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.
Opinion
IN THE SUPERIOR COURT OF THE STATE OF DELAWARE
FIRST HARTFORD REALTY ) CORPORATION, ) ) Plaintiff / Counterclaim-Defendant, ) ) v. ) C.A. No. N23C-06-085 PRW ) FOOD VENTURES NORTH AMERICA, ) INC., d/b/a WILD FORK FOODS, ) ) Defendant / Counterclaim-Plaintiff. )
Submitted: August 25, 2025 Decided: November 25, 2025
DECISION AFTER TRIAL
G. Kevin Fasic, Esquire, Charles A. McCauley III, Esquire, and Bradley T. Meyer, Esquire, OFFIT KURMAN, P.A., Wilmington, Delaware, Attorneys for Plaintiff/Counterclaim-Defendant First Hartford Realty Corporation.
R. Montgomery Donaldson, Esquire, Richard G. Placey, Esquire, and Stephania A. Rosca, Esquire, MONTGOMERY, MCCRACKEN, WALKER & RHOADS LLP, Wilmington, Delaware; John P. Storti, Esquire, and Shane O’Connor, Esquire, BERG, HILL, GREENLEAF, RUSCITTI, LLP, Boulder, Colorado, Attorneys for Defendant/Counterclaim-Plaintiff Food Ventures North America Inc., d/b/a Wild Fork Foods.
WALLACE, J. Among other things, this case is about a transformer, decorative lighting, a
sidewalk, and a brick monument sign welcoming visitors to Horsham, Pennsylvania.
These are the sort of finishing touches that a store’s passersby would hardly notice.
But here, those small elements set off a much larger conflict. A disagreement over
who should pay for some lighting or a welcome sign gradually expanded into a
dispute between two seasoned commercial entities. In fact, what began on one parcel
in Horsham ultimately infected projects more than a thousand miles away, with each
side claiming the other fell short of its obligations under the parties’ broader
development agreements. The once-isolated quibbles have grown into competing
demands exceeding a million dollars and span from Pennsylvania to Texas.
But while the record is long and the parties’ claims now wide-ranging, the
core questions remain mostly simple: Who was supposed to foot a few certain bills
and which party—if either—breached certain parts of the overall bargain?
I. THE TRIAL
During the four-day bench trial, the Court heard the in-court testimony of:
Kathrine Szurek John Toic Ryan Zelek Patrick Luther Julian Falgons David Arnoldi Alex Bord1
1 Joint Stipulated Facts, ¶¶ 9-10 [hereinafter “Joint Stip. Facts”] (D.I. 96). Katherine Szurek, Ryan Zelek, Julian Falgons, and Alex Bord gave their testimony via live video teleconference. John Toic, Patrick Luther, and David Arnoldi testified in-person. Ricardo Marotta and Scott Walker’s trial testimony was received in the form of depositions offered under Del. Super. Ct. Civ. R. 32(a)(3). Id.
-1- The parties submitted over 70 exhibits without objection.2 Now, the Court will
determine the liability of each party under the respective claims and counterclaims,
as well as, appropriate damages, if any.3
II. APPLICABLE LEGAL PRINCIPLES AND STANDARDS
The Court has examined all exhibits submitted by the parties and considered
the testimony of all witnesses, both direct and cross, live and by deposition. During
trial, the Court applied the Delaware Rules of Evidence to the testimony and the
exhibits presented. Consistent with the Court’s knowledge of those rules and the
specific rulings the Court articulated during both pre-trial and trial proceedings, the
Court has relied only on the evidence allowed under those rules and rulings in
reaching its verdict.
As this was a bench trial, the Court is the sole finder of fact. 4 In turn, the
Court has made its own assessment of each witness’s credibility and reconciled, to
the best of its ability, any inconsistencies in the testimony and documentary
evidence.5 The Court then reviewed and applied the same instructions that it would
2 D.I. 90 (Letter from Bradley T. Meyer, Esquire, Enclosing Three Flash Drives of Joint Trial Exhibits Admitted During the Bench Trial Held on April 21, 2025); Joint Stip. Facts, ¶ 3. 3 In addition to the trial evidence and arguments made by counsel, the Court also now has the benefit of the parties’ post-trial briefing and stipulated facts. D.I. 96-100. 4 Pouls v. Windmill Ests., LLC, 2010 WL 2348648, at *4 (Del. Super. Ct. June 10, 2010). 5 Pencader Assoc., LLC v. Synergy Direct Mortg. Inc., 2010 WL 2681862, at *3 (Del. Super. Ct. June 30, 2010) (“[I]n a bench trial, it is the Court’s role to resolve the conflicts in witnesses’ testimony and weigh their credibility.”); Interim Healthcare, Inc. v. Spherion Corp., 884 A.2d 513, 545–46 (Del. Super. Ct. 2005) (setting forth “the customary Delaware standard” a trial judge -2- give a jury in these circumstances.6
The Court has remained mindful throughout its deliberations that the party
seeking judgment and relief on its pled claim or counterclaim must prove each
element thereof by a preponderance of the evidence.7
In reaching its verdict, the Court has considered all applicable law—both
Delaware’s and other relevant state’s—and each party’s respective arguments—both
oral and written—on the merits of the parties’ claims, defenses, and the weight to be
accorded to witness testimony and other forms of evidence submitted.8
III. FINDINGS OF FACT
Each of the parties’ claims in this action is rooted in the development of a
property located in Horsham, Pennsylvania (the “Horsham Property”). Together, the
applies when assessing trial testimony and evidence in a bench trial). 6 See, e.g., Del. Super. Ct. Civ. Pattern Jury Instr. 4.1 (Burden of Proof by a Preponderance of the Evidence); id. at 4.2 (Evidence Equally Balanced); id. at 23.1 (Evidence—Direct or Circumstantial); id. at 23.9 (Credibility of Witnesses—Weighing Conflicting Testimony); id. at 23.10 (Expert Testimony). 7 Pouls, 2010 WL 2348648, at *4; Surf’s Up Legacy Partners, LLC v. Virgin Fest, LLC, 2024 WL 1596021, at *15 (Del. Super. Ct. Apr. 12, 2024), reargument denied, 2024 WL 3273427 (Del. Super. Ct. July 2, 2024) (“A party must prove each element by a preponderance of the evidence.”). See Grand Acquisition, LLC v. Passco Indian Springs DST, 145 A.3d 990, 994 (Del. Ch. 2016), as revised (Sept. 7, 2016), aff’d, 158 A.3d 449 (Del. 2017) (explicating the preponderance of evidence standard); see also Reynolds v. Reynolds, 237 A.2d 708, 711 (Del. 1967) (defining preponderance of the evidence: “The side on which the greater weight of the evidence is found is the side on which the preponderance of the evidence exists.”); Newark Shopping Ctr. Owner, L.L.C. v. Saudades Grp., LLC, 2025 WL 655063, at *3 (Del. Super. Ct. Feb. 26, 2025) (same). 8 The Court may highlight certain facts and legal principles uniquely applicable to this case. But the fact that a certain principle is expressly mentioned here does not indicate that the Court did not consider other legal principles applicable to this case and to the parties’ claims and defenses during its deliberations.
-3- parties were working in tandem to develop a growing number of retail projects across
the United States—a relationship valued in the multi-millions. But that coupling
soured over a disagreement as to which party was financially responsible for one
$288,866.00 change order (the “Change Order”) that arose during the Horsham
project.
A. THE FIRST HARTFORD-WILD FORK RELATIONSHIP
Wild Fork, a specialty supermarket chain, sought to expand into additional
American markets, including Pennsylvania and Texas.9 To facilitate that expansion,
Free access — add to your briefcase to read the full text and ask questions with AI
IN THE SUPERIOR COURT OF THE STATE OF DELAWARE
FIRST HARTFORD REALTY ) CORPORATION, ) ) Plaintiff / Counterclaim-Defendant, ) ) v. ) C.A. No. N23C-06-085 PRW ) FOOD VENTURES NORTH AMERICA, ) INC., d/b/a WILD FORK FOODS, ) ) Defendant / Counterclaim-Plaintiff. )
Submitted: August 25, 2025 Decided: November 25, 2025
DECISION AFTER TRIAL
G. Kevin Fasic, Esquire, Charles A. McCauley III, Esquire, and Bradley T. Meyer, Esquire, OFFIT KURMAN, P.A., Wilmington, Delaware, Attorneys for Plaintiff/Counterclaim-Defendant First Hartford Realty Corporation.
R. Montgomery Donaldson, Esquire, Richard G. Placey, Esquire, and Stephania A. Rosca, Esquire, MONTGOMERY, MCCRACKEN, WALKER & RHOADS LLP, Wilmington, Delaware; John P. Storti, Esquire, and Shane O’Connor, Esquire, BERG, HILL, GREENLEAF, RUSCITTI, LLP, Boulder, Colorado, Attorneys for Defendant/Counterclaim-Plaintiff Food Ventures North America Inc., d/b/a Wild Fork Foods.
WALLACE, J. Among other things, this case is about a transformer, decorative lighting, a
sidewalk, and a brick monument sign welcoming visitors to Horsham, Pennsylvania.
These are the sort of finishing touches that a store’s passersby would hardly notice.
But here, those small elements set off a much larger conflict. A disagreement over
who should pay for some lighting or a welcome sign gradually expanded into a
dispute between two seasoned commercial entities. In fact, what began on one parcel
in Horsham ultimately infected projects more than a thousand miles away, with each
side claiming the other fell short of its obligations under the parties’ broader
development agreements. The once-isolated quibbles have grown into competing
demands exceeding a million dollars and span from Pennsylvania to Texas.
But while the record is long and the parties’ claims now wide-ranging, the
core questions remain mostly simple: Who was supposed to foot a few certain bills
and which party—if either—breached certain parts of the overall bargain?
I. THE TRIAL
During the four-day bench trial, the Court heard the in-court testimony of:
Kathrine Szurek John Toic Ryan Zelek Patrick Luther Julian Falgons David Arnoldi Alex Bord1
1 Joint Stipulated Facts, ¶¶ 9-10 [hereinafter “Joint Stip. Facts”] (D.I. 96). Katherine Szurek, Ryan Zelek, Julian Falgons, and Alex Bord gave their testimony via live video teleconference. John Toic, Patrick Luther, and David Arnoldi testified in-person. Ricardo Marotta and Scott Walker’s trial testimony was received in the form of depositions offered under Del. Super. Ct. Civ. R. 32(a)(3). Id.
-1- The parties submitted over 70 exhibits without objection.2 Now, the Court will
determine the liability of each party under the respective claims and counterclaims,
as well as, appropriate damages, if any.3
II. APPLICABLE LEGAL PRINCIPLES AND STANDARDS
The Court has examined all exhibits submitted by the parties and considered
the testimony of all witnesses, both direct and cross, live and by deposition. During
trial, the Court applied the Delaware Rules of Evidence to the testimony and the
exhibits presented. Consistent with the Court’s knowledge of those rules and the
specific rulings the Court articulated during both pre-trial and trial proceedings, the
Court has relied only on the evidence allowed under those rules and rulings in
reaching its verdict.
As this was a bench trial, the Court is the sole finder of fact. 4 In turn, the
Court has made its own assessment of each witness’s credibility and reconciled, to
the best of its ability, any inconsistencies in the testimony and documentary
evidence.5 The Court then reviewed and applied the same instructions that it would
2 D.I. 90 (Letter from Bradley T. Meyer, Esquire, Enclosing Three Flash Drives of Joint Trial Exhibits Admitted During the Bench Trial Held on April 21, 2025); Joint Stip. Facts, ¶ 3. 3 In addition to the trial evidence and arguments made by counsel, the Court also now has the benefit of the parties’ post-trial briefing and stipulated facts. D.I. 96-100. 4 Pouls v. Windmill Ests., LLC, 2010 WL 2348648, at *4 (Del. Super. Ct. June 10, 2010). 5 Pencader Assoc., LLC v. Synergy Direct Mortg. Inc., 2010 WL 2681862, at *3 (Del. Super. Ct. June 30, 2010) (“[I]n a bench trial, it is the Court’s role to resolve the conflicts in witnesses’ testimony and weigh their credibility.”); Interim Healthcare, Inc. v. Spherion Corp., 884 A.2d 513, 545–46 (Del. Super. Ct. 2005) (setting forth “the customary Delaware standard” a trial judge -2- give a jury in these circumstances.6
The Court has remained mindful throughout its deliberations that the party
seeking judgment and relief on its pled claim or counterclaim must prove each
element thereof by a preponderance of the evidence.7
In reaching its verdict, the Court has considered all applicable law—both
Delaware’s and other relevant state’s—and each party’s respective arguments—both
oral and written—on the merits of the parties’ claims, defenses, and the weight to be
accorded to witness testimony and other forms of evidence submitted.8
III. FINDINGS OF FACT
Each of the parties’ claims in this action is rooted in the development of a
property located in Horsham, Pennsylvania (the “Horsham Property”). Together, the
applies when assessing trial testimony and evidence in a bench trial). 6 See, e.g., Del. Super. Ct. Civ. Pattern Jury Instr. 4.1 (Burden of Proof by a Preponderance of the Evidence); id. at 4.2 (Evidence Equally Balanced); id. at 23.1 (Evidence—Direct or Circumstantial); id. at 23.9 (Credibility of Witnesses—Weighing Conflicting Testimony); id. at 23.10 (Expert Testimony). 7 Pouls, 2010 WL 2348648, at *4; Surf’s Up Legacy Partners, LLC v. Virgin Fest, LLC, 2024 WL 1596021, at *15 (Del. Super. Ct. Apr. 12, 2024), reargument denied, 2024 WL 3273427 (Del. Super. Ct. July 2, 2024) (“A party must prove each element by a preponderance of the evidence.”). See Grand Acquisition, LLC v. Passco Indian Springs DST, 145 A.3d 990, 994 (Del. Ch. 2016), as revised (Sept. 7, 2016), aff’d, 158 A.3d 449 (Del. 2017) (explicating the preponderance of evidence standard); see also Reynolds v. Reynolds, 237 A.2d 708, 711 (Del. 1967) (defining preponderance of the evidence: “The side on which the greater weight of the evidence is found is the side on which the preponderance of the evidence exists.”); Newark Shopping Ctr. Owner, L.L.C. v. Saudades Grp., LLC, 2025 WL 655063, at *3 (Del. Super. Ct. Feb. 26, 2025) (same). 8 The Court may highlight certain facts and legal principles uniquely applicable to this case. But the fact that a certain principle is expressly mentioned here does not indicate that the Court did not consider other legal principles applicable to this case and to the parties’ claims and defenses during its deliberations.
-3- parties were working in tandem to develop a growing number of retail projects across
the United States—a relationship valued in the multi-millions. But that coupling
soured over a disagreement as to which party was financially responsible for one
$288,866.00 change order (the “Change Order”) that arose during the Horsham
project.
A. THE FIRST HARTFORD-WILD FORK RELATIONSHIP
Wild Fork, a specialty supermarket chain, sought to expand into additional
American markets, including Pennsylvania and Texas.9 To facilitate that expansion,
Wild Fork entered into a contractual relationship with First Hartford, a real estate
development company.10 The parties memorialized this arrangement in a
Memorandum of Understanding (the “MOU”) in August of 2020.11 The MOU
established the underlying terms and conditions to facilitate the parties’ collaboration
on various new Wild Fork store-development projects across the U.S.12 By year’s
end, the parties executed a ground lease (the “Lease” or “Ground Lease”).13 The
Lease governed First Hartford’s role as a landlord, and Wild Fork’s as a tenant for
9 Joint Stip. Facts, ¶ 7. 10 Id., ¶ 5; Trial Tr. Day 1, 6 (D.I. 91). 11 Joint Stip. Facts, ¶ 23. 12 Id., ¶ 23. 13 Id., ¶¶ 24-25.
-4- the property located in Horsham, Pennsylvania.14
Between June and October of 2021, the parties executed a series of contracts
further defining their relationship and obligations.15 The parties entered into a
Master Development Contract (the “MDC”).16 The MDC obligated First Hartford
to identify real estate and, upon Wild Fork’s approval, develop projects in
accordance with the MDC and either the Development Agreement or Lease.17
Contemporaneous with the MDC, the parties executed a Form of MDC New
Property Supplement (the “MDC Supplement”).18 The MDC Supplement
specifically governed the Horsham Property and included a site plan and budget.19
B. THE HORSHAM PROJECT
At the heart of this dispute is a lease project, the Horsham Property.20 As a
lease project, its development and the parties’ obligations are governed by the MDC,
the Lease, and the MDC Supplement.21 The financial responsibilities of each party
are defined by the MDC and the Lease.22 First Hartford is financially responsible,
14 Id. 15 See id., ¶¶ 26-31. 16 Id., ¶ 26. 17 See id., ¶¶ 27-30; TX-5 (“Master Development Contract”). 18 Joint Stip. Facts, ¶ 31. 19 Id. 20 See id., ¶ 33. 21 See id., ¶ 34; Master Development Contract. 22 See TX-2 (“Ground Lease”); Master Development Contract.
-5- under Article 7 of the MDC, for “all development and/or construction required of
[First Hartford] under the applicable Lease in order to deliver [Wild Fork] a pad-
ready site, such as the costs of site development work and utility hook-ups.”23 The
Lease further defines First Hartford’s responsibilities with respect to delivering to
Wild Fork a pad-ready site.24 Wild Fork is financially responsible, under Article 7
of the MDC, for funding “the remainder of the construction . . . for the full scope of
turn-key construction, including interior buildout, furniture, fixtures, and
equipment.”25 The Lease also defines Wild Fork’s financial responsibilities with
respect to a pad-ready site.26
Located on the Horsham Property was a then-existing bank building.27 The
parties originally contemplated remodeling the building but ultimately Wild Fork
decided to demolish it and construct a whole new storefront.28 First Hartford
engaged Project Builders Incorporated (“PBI”), as the general contractor for the
work on the Horsham site.29 During construction, disputes arose over certain work
performed by PBI.
23 Master Development Contract, at Art. 7. 24 See Ground Lease, at Ex. B. 25 Master Development Contract, at Art. 7. 26 See Ground Lease, at Ex. B. 27 See Joint Stip. Facts, ¶ 36. 28 See id., ¶ 36; Trial Tr. Day 1, 25-26 (D.I. 91). 29 Trial Tr. Day 1, 40-41.
-6- Such work included requests made by Horsham Township and various
modifications required in the construction of the new storefront. 30 The Township
wanted the parties to include a “Welcome to Horsham” sign on the property and to
use certain decorative lighting, similar to the Township’s lighting on properties
nearby.31 The new storefront also required certain utility service modifications.32
First Hartford conducted off-site water and sewer utility work which needed
to be completed to service the new storefront.33 Additionally, and central to this
dispute, the electrical service, which previously had been connected to a pole-
mounted transformer, required a redesign.34 It seems, PECO Energy Company
(“PECO”) required certain electrical service modifications, including the installation
of a new electrical transformer.35 After learning of Wild Fork’s electrical needs,
PECO mandated the new transformer which, due to its size and capacity, needed to
be placed in a vault.36 But after initial installation and inspection, PECO required
the vault be moved due to its proximity to certain other utility services.37
30 See Joint Stip. Facts, ¶ 49. 31 Trial Tr. Day 1, 20. 32 Id., 31-32. 33 Id. 34 Id., 32. 35 Id. 36 Id., 34. 37 Id., 39-40. Wild Fork and its in-house architect had been consulted on the first vault location. Id.
-7- Between May and July 2022, First Hartford submitted a series of
communications to Wild Fork identifying what it described as a “change order
list.”38 That list included the relocation of the transformer, the decorative lighting
and conduit, the “Welcome to Horsham” sign, and the construction of new
sidewalks.39 The total cost of that specific work was $288,866.40 Confusion arose
between the parties as to who was ultimately financially responsible for the Change
Order and as a result, PBI went unpaid.41
When PBI didn’t receive timely payment for the Change Order items, it
recorded a mechanic’s lien against the Horsham Property in September 2022.42 On
February 28, 2023, counsel for PBI issued a formal demand for payment.43 By the
summer of 2023, PBI had filed suit against both First Hartford and Wild Fork.44
Wild Fork eventually settled the matter, paying PBI the amount in dispute in
exchange for release of the liens and dismissal of the pending litigation.45
38 See Joint Stip. Facts, ¶¶ 41-48. 39 Id., ¶ 49. 40 Id., ¶ 51. 41 See id., ¶ 54. At one point during this time of uncertainty, Mr. Falgons of Wild Fork marked the Change Order as “approved.” Id., ¶ 55. 42 Id., ¶ 54. 43 Id., ¶ 59. 44 See id., ¶¶ 60-63. 45 Id., ¶ 64.
-8- C. THE LEASE AMENDMENT AND PROFIT-SHARING PROVISION
The Lease provided that Wild Fork would pay an initial annual rent at the
Horsham Property of $130,000.46 This amount represented 7.5% of First Hartford’s
budgeted construction costs.47 Recognizing the development had exceeded its initial
budget, in March of 2023, First Hartford submitted a request to Wild Fork to amend
the Lease (the “Lease Amendment”).48 The Lease Amendment would increase Wild
Fork’s annual rent to $143,000.49 Wild Fork responded to the Lease Amendment
request in May of 2023; Wild Fork sought to “discuss a comprehensive resolution
to all outstanding issues.”50 Specifically, Wild Fork took issue with certain payments
then being withheld by First Hartford to which Wild Fork believed it was entitled
under the MDC.51
The MDC included a Profit-Sharing Provision that entitled Wild Fork to a
portion of the proceeds from any sale of a Lease Project.52 At roughly the same time
the Horsham project was underway, First Hartford and Wild Fork were engaged in
46 Id., ¶ 65. 47 Id. 48 Id., ¶ 66. 49 Id. 50 Id., ¶¶ 65-67. 51 Id., ¶ 74. 52 See id., ¶¶ 27-30; Master Development Contract.
-9- other projects, including multiple properties in Texas.53 First Hartford sold four such
properties but withheld approximately $891,000 in profit-sharing payments owed to
Wild Fork reasoning that—due to the Horsham goings-on—Wild Fork had breached
their agreements, and therefore, no payments were due under the MDC.54
D. PROCEDURAL BACKGROUND AND THE PARTIES’ CONTENTIONS
In June of 2023, First Hartford filed its initial complaint in this Court.55
Following motion practice that narrowed and framed the issues, the following First
Hartford claims proceeded to trial: Breach of Contract (MDC) (Count 1); Breach of
Lease Agreement (Count 2); Quantum Meruit (Count 3); Unjust Enrichment (Count
4); Violation of CASPA (Count 5); Declaratory Judgment for Rent Adjustment
(Count 6).56 Wild Fork answered with a single breach-of-contract counterclaim.57
The Court heard trial of these counts58 and all post-trial briefing is complete.59
First Hartford contends that Wild Fork breached the MDC and Lease by
failing to pay for the Change Order costs related to work performed by PBI on the
53 Joint Stip. Facts, ¶ 68. 54 See id., ¶¶ 68-75. 55 See D.I. 1 (First Hartford’s first complaint). 56 See Amended Complaint (D.I. 38). The Court earlier dismissed two of First Hartford’s counts: Declaratory Judgment on Termination of the MDC (Count 7) and Tortious Interference (Count 8). D.I. 77. 57 See generally Defendant/Counterclaim-Plaintiff Food Ventures North America Inc.’s Answer, Affirmative Defenses, and Counterclaims (D.I. 12). 58 D.I. 86 (Trial Worksheet). 59 D.I. 96-100.
- 10 - Horsham Property. It argues that the Change Order was related to the construction
of the building, which Wild Fork is obligated to pay under the Lease. Additionally,
First Hartford complains that Wild Fork approved and agreed to pay the Change
Order, and its failure to timely do so caused PBI to place a mechanic’s lien on the
property which adversely affected First Hartford’s ability to sell the property.60
First Hartford also charges that Wild Fork failed to execute a required Lease
Amendment.61 And, insists First Hartford, Wild Fork’s failure to do so caused the
property to sell at a significantly lower price than it otherwise would have.62
Additionally, First Hartford says it’s excused from making the profit-sharing
payments to Wild Fork for the Texas Properties because Wild Fork materially
breached the Master Development Contract.63 It asks the Court to find Wild Fork in
breach of the agreements and for an award of damages it claims to have suffered as
a direct and foreseeable result of Wild Fork’s conduct.64
Wild Fork denies that it breached the agreements in any way. According to
Wild Fork, the at-issue work performed by PBI and the related Change Order’s costs
60 See generally Post-Trial Brief of Plaintiff/Counterclaim Defendant First Hartford Realty Corporation, at 22-28 (D.I. 97) [hereinafter Pl.’s Post-Trial Br.]. 61 See id., at 28-29. 62 See id., at 28-31. 63 See id. 64 See generally Pl.’s Post-Trial Br.
- 11 - were “site work” which First Hartford is obligated to pay under the Lease.65 Wild
Fork counters that it wasn’t obligated to execute the Lease Amendment.66 It says
First Hartford ignored Wild Fork’s request to engage in any meaningful discussion
on the issue; choosing instead to file this lawsuit.67
In its counterclaim, Wild Fork charges that First Hartford breached its
indemnification obligations under both the MDC and the Horsham Lease by refusing
to indemnify Wild Fork for the Change Order amounts it paid to PBI.68 Additionally,
Wild Fork alleges that First Hartford is in breach of the MDC for withholding
amounts it is owed under the profit-sharing provision for the sale of the Texas
properties.69 Wild Fork asks the Court for an award of $1,180,247.50 which includes
amounts it says are owed for the Texas Properties, reimbursement for its payment to
clear PBI’s mechanic’s lien, reasonable fees and costs, as well as pre- and post-
judgment interest under Delaware law.70
IV. CHOICE OF LAW
The MDC and the Lease each contain choice-of-law provisions stating that
65 See generally Defendant/Counterclaim-Plaintiff’s Opening Post-Trial Brief, at 45-46 (D.I. 98) [hereinafter Def.’s Post-Trial Br.]. 66 See id., at 37-39. 67 See id. 68 See id., at 43-45. 69 See id., at 28-43. 70 Id., at 51-54.
- 12 - the contracts shall be governed by, construed, and interpreted in accordance with the
law of the state in which the applicable project is located.71 Delaware courts “will
generally honor a contractually-designated choice of law provision so long as the
jurisdiction selected bears some material relationship to the transaction.”72 Thus,
when a choice-of-law question arises, the Court first determines whether the parties
made an effective contractual selection; if they did, that selection controls. 73
The Horsham Property is located in Pennsylvania.74 For disputes arising from
that project—including the Change Order and the Lease Amendment—the contracts
71 Master Development Contract, at Art. 13; Ground Lease, at § 30. Per Art. 13 of the MDC, Delaware is the exclusive venue for any dispute arising from it. 72 J.S. Alberici Const. Co., Inc. v. Mid-West Conveyor Co., Inc., 750 A.2d 518, 520 (Del. 2000); FinClusive Capital, Inc. v. Q2 Software, Inc., 2021 WL 5225860, at *6 (Del. Super. Ct. Oct. 28, 2021) (“Delaware courts ‘are bound to respect the chosen law of contracting parties, so long as that law has a material relationship to the transaction.’”) (quoting ABRY Partners V, L.P. v. F&W Acquisition LLC, 891 A.2d 1032, 1048 (Del. Ch. 2006)). 73 Certain Underwriters at Lloyds, London v. Chemtura Corp., 160 A.3d 457, 464 (Del. 2017) (citations omitted) (“Delaware follows the Second Restatement’s ‘most significant relationship’ analysis when considering choice of law in contract disputes. There are, in essence, three components to this choice-of-law analysis: i) determining if the parties made an effective choice of law through their contract; ii) if not, determining if there is an actual conflict between the laws of the different states each party urges should apply; and iii) if so, analyzing which state has the most significant relationship.”). Delaware Courts will decline to decide whether one or another jurisdiction’s laws applies “if there is a ‘false conflict.’” Gea Systems North Am. LLC v. Golden State Foods Corp., 2020 WL 3047207, at *4 (Del. Super. Ct. June 8, 2020) (relying on In re Bay Hills Emerging Partners I, L.P., 2018 WL 3217650, at *5 (Del. Ch. July 2, 2018); BHEP GP I, LLC v. Kentucky Ret. Sys., 191 A.3d 292 (Del. 2018); Standard Gen. L.P. v. Charney, 2017 WL 6498063, at *9 (Del. Ch. Dec. 19, 2017)). And a “false conflict” exists if there is no material difference between the laws of competing jurisdictions. Deuley v. DynCorp Int’l, Inc., 8 A.3d 1156, 1161 (Del. 2010). 74 Joint Stip. Facts, ¶¶ 24-25.
- 13 - designate Pennsylvania law, and the parties don’t contest that selection.75 Because
those choice-of-law provisions are effective and Pennsylvania bears a direct
relationship to the Horsham Project, the Court applies Pennsylvania law to those
claims and counterclaims.
The dispute concerning the MDC’s Profit-Sharing provision, however, arises
from projects located in Texas.76 Again, under the MDC, the governing law for each
dispute is the law of the state in which the applicable project is situated. 77 The profit-
sharing issue concerns profits generated from the Texas properties and withheld in
connection with the Texas projects. 78
First Hartford says that Texas law shouldn’t apply.79 But the parties expressly
agreed to a project-specific choice-of-law structure. And this Court may apply the
governing law of different states to different claims where the contracts call for it;
such a bifurcated analysis poses no problem under Delaware law.80 Rather, it simply
reflects the parties’ negotiated expectations in multi-state commercial
75 See generally Joint Stip. Facts; Pl.’s Post-Trial Br.; Def.’s Post-Trial Br. 76 See Joint Stip. Facts, ¶¶ 68-75. 77 Master Development Contract, at Art. 13; Ground Lease, at § 30. 78 See Joint Stip. Facts, ¶¶ 68-75. 79 Pl.’s Post-Trial Br., at 32-35. 80 See generally Chemtura, 160 A.3d at 465; see also Vichi v. Koninklijke Philips Elecs., N.V., 85 A.3d 725, 769-71 (Del. Ch. 2014); Laugelle v. Bell Helicopter Textron, Inc., 2013 WL 5460164, at *3 (Del. Super. Ct. Oct. 1, 2013) (noting in tort actions: “Choice-of-law determinations must be made as to each issue when presented, not to the case as a whole.”).
- 14 - arrangements.81 Here, Texas plainly has a material relationship to the profit-sharing
dispute: the properties are located in Texas, and the profits at issue arose directly
from the Texas projects.82 The existence of separate Pennsylvania-based claims
doesn’t override the parties’ distinct and effective selection of Texas law for disputes
tied to the Texas properties.
Because the Court must honor the parties’ contractual choice of law, and
because Texas has a substantial relationship to the profit-sharing dispute, the Court
applies Texas law to that issue.
V. LEGAL FINDINGS AND CONCLUSIONS
As this was a civil trial, both parties had the burden of proving their respective
claims by a preponderance of the evidence.83
At the heart of this dispute are competing breach-of-contract claims stemming
from a disagreement over which party is financially responsible for the Horsham
Project Change Order. The result of this issue is foundational to nearly all other
claims asserted. As such, the Court will first address the parties’ competing breach-
of-contract claims thereon. The Court will then turn to First Hartford’s CASPA
81 Chemtura, 160 A.3d at 464; Gea Systems, 2020 WL 3047207, at *4. 82 See Joint Stip. Facts, ¶¶ 68-75. 83 See, e.g., Navient Sols., LLC v. BPG Off. P’rs XIII Iron Hill LLC, 2023 WL 3120644, at *10 (Del. Super. Ct. Apr. 27, 2023) (“Each party bears the burden of proving their respective claims and defenses by a preponderance of the evidence.”); Discover Bank v. Booker, 259 A.3d 493, (Pa. Super. Ct. 2021) (“A party claiming breach [of contract] must establish its elements by a preponderance of evidence.”).
- 15 - count. Third, the Court addresses Wild Fork’s counter that First Hartford is in breach
of the MDC Profit-Sharing provision. Fourth, the Court will resolve First Hartford’s
quantum meruit and unjust enrichment claims. And lastly, the Court addresses First
Hartford’s claim that it is entitled to a rent adjustment.
A. WILD FORK DID NOT BREACH THE MASTER DEVELOPMENT CONTRACT OR THE GROUND LEASE.
Under Pennsylvania law, three elements must be proven to establish a breach
of contract: “(1) the existence of a contract, including its essential terms, (2) a breach
of the contract; and, (3) resultant damages.”84 Both parties have satisfied the first
and third elements of a breach-of-contract claim.85 There is no dispute that this
project was governed by three primary agreements, the MDC, the MDC supplement,
and the Lease.86 As to damages, First Hartford contends Wild Fork’s failure to timely
pay for the Change Order resulted in various cascading effects including lost
property value and irreparable harm to its business relationships. 87 Wild Fork
eventually settled PBI’s litigation by paying it for the $288,866.00 Change Order but
contends it is owed damages in the amount of the Change Order (exclusive of
84 Meyer, Darragh, Buckler, Bebenek & Eck, P.L.L.C. v. aw. Firm of Malone Middleman, P.C., 137 A.3d 1247, 1258 (Pa. 2016). 85 See Mula Design, LLC D/B/A Mula Group v. Bestchoice Realty, Inc., 2025 WL 3090137, at *5 (Pa. Super. Ct. Nov. 4, 2025) (quoting Pops PCE TT, LP v. R&R Rest. Grp., LLC, 208 A.3d 79, 87 (Pa. Super. Ct. 2019)). 86 Joint Stip. Facts, ¶ 34. 87 Pl.’s Post-Trial Br., at 19-20.
- 16 - interest) plus its reasonable fees and costs arising out of the PBI litigation.88
The true contest, therefore, is over the second element. That is, whether either
party has established by a preponderance that the other is in breach of the MDC or
Lease.89 To answer this question, the Court first will look to the relevant MDC and
Lease provisions to determine the financial responsibilities of each party.
1. The financial responsibilities defined in the MDC and Lease are unambiguous.
It is well-established in Pennsylvania, “that under the law of contracts, in
interpreting an agreement, the court must ascertain the intent of the parties.”90
Where the contract is written “the intent of the parties is to be ascertained from the
document itself.”91 Pennsylvania courts resist what we’d call here the “twisting” of
contractual language; also like Delaware’s, those courts refuse to “distort the
meaning of the language or resort to a strained contrivance in order to find an
ambiguity.”92 Only if the terms are ambiguous, is “parol evidence [ ] admissible to
88 Def.’s Post-Trial Br., at 51-54. 89 See generally Mula Design, 2025 WL 3090137, at *5. 90 Lenau v. Co-eXprise, Inc., 102 A.3d 423, 429-30 (Pa. Super. Ct. 2014) (quoting Kripp v. Kripp, 849 A.2d 1159, 1163 (Pa. 2004)). 91 Id.; Hutchison v. Sunbeam Coal Corp., 519 A.2d 385, 390 (Pa. 1986) (“The intent of the parties is to be ascertained from the document itself when the terms are clear and unambiguous.”); Pines Plaza Bowling, Inc. v. Rossview, Inc., 145 A.2d 672, 676 (Pa. 1958) (discussing the various circumstances that the Commonwealth’s courts use may determine intent). 92 Madison Const. Co. v. Harleysville Mut. Ins. Co., 735 A.2d 100, 106 (Pa. 1999); Steuart v. McChesney, 444 A.2d 659, 663 (Pa. 1982) (“[T]he plain meaning of language hinders parties dissatisfied with their agreement from creating a myth as to the true meaning of the agreement through subsequently exposed extrinsic evidence.”); see also Lorillard Tobacco Co. v. Am. Legacy - 17 - explain or clarify or resolve the ambiguity, irrespective of whether the ambiguity is
patent, created by the language of the instrument, or latent, created by extrinsic or
collateral circumstances.”93
Under Article 7 of the MDC, First Hartford’s responsibilities are defined as
follows:
[First Hartford] will, at [First Hartford’s] cost and expense (and without a right of reimbursement from [Wild Fork] unless said expense is an Approved Expenditure) undertake due diligence, design, permitting, entitlement and will pay the costs to purchase the applicable property (without a right of reimbursement from [Wild Fork]). Such costs of [First Hartford], which are not reimbursable by [Wild Fork], shall include all development and/or construction required of [First Hartford] under the applicable Lease in order to deliver to [Wild Fork] a pad- ready site, such as the costs of site development work and utility hook- ups.94
Article 7 of the MDC defines Wild Fork’s responsibilities as follows:
[Wild Fork] will fund the remainder of the construction which shall be managed by [First Hartford] (with no management, development or other fee payable to [First Hartford]) for the full scope of turn-key construction, including interior buildout, furniture, fixtures, and equipment.95
As it relates to the instant dispute, First Hartford is financially responsible for
Found., 903 A.2d 728, 739 (Del. 2006) (“Delaware courts will not destroy or twist [contract] language under the guise of construing it.”). 93 Lenau, 102 A.3d at 429-30; Steuart, 444 A.2d at 663; In re Herr’s Estate, 161 A.2d 32, 34 (Pa. 1960). 94 Master Development Contract, at Art. 7. 95 Id.
- 18 - all items defined in the Lease to deliver a pad-ready site to Wild Fork; Wild Fork is
financially responsible for the remainder of construction, generally limited to
projects related or connected to Wild Fork’s storefront.96 The question of breach,
therefore, boils down to whether the Change Order is related to those items
designated as First Hartford’s responsibility under the Lease, which the Court will
refer to as “Site Work,” or “the remainder of construction” designated as Wild Fork’s
responsibility, which the Court will refer to as “Building Work.”
2. The Change Order items are all “Site Work” and First Hartford’s financial responsibility.
The Change Order largely arises from the parties’ decision to demolish an
existing building and reconstruct a new Wild Fork storefront from the ground up.97
The Change Order included four primary components.98 Those are: (1) the
relocation of an electrical transformer; (2) the decorative lighting required by
Horsham Township; (3) the “Welcome to Horsham” sign; and, (4) the construction
of new sidewalks.99 The Court will address each below and relies on Pennsylvania
law, as discussed above, to make each determination.
96 Joint Stip. Facts, ¶¶ 37-38. 97 See id., ¶ 49. 98 TX-7 (The “Change Order”). 99 Joint Stip. Facts, ¶ 49; Change Order.
- 19 - i. The Electrical Transformer
Section 4 of the Lease provides:
[First Hartford] shall cooperate in causing the Premises to be supplied with adequate water, sewer rents, sewer charges, heat, gas and electricity service. . . . Notwithstanding the foregoing, [First Hartford’s] responsibility to supply the aforesaid utilities to the Premises shall be limited to the applicable requirements listed in [Exhibit B].100
First Hartford is required to provide adequate electricity service, limited only
by Exhibit B.101 For the site to be “pad-ready,” Exhibit B of the Lease requires First
Hartford, at its sole expense, to “prepare the site plans” and to provide “Electrical
Service to the Building (within 5’ of Building or within curb line whichever is
closer).”102 The Lease requires “adequate” electricity service.103
At trial, First Hartford’s president explained that PECO “dictated that the
property could not be serviced simply by the existing pole-mounted transformer.”104
To accommodate Wild Fork’s electrical needs, PECO required a new transformer
which, due to its size and capacity, needed to be placed in a vault.105 Stated
differently, the new transformer was required to provide adequate electricity service
100 TX-2 (the “Ground Lease”). 101 Ground Lease, at § 4. 102 Id., at Ex. B (“Work to be Performed by Landlord for ‘Pad Ready’ Sites”). 103 Id., at § 4, id., at Ex B. 104 Trial Tr. Day 1, 5, id., at 33-34; id. at 107-08 (“As I came to understand it, it was because of the requirements of the large amount of freezer equipment located in the building.”). 105 Trial Tr. Day 1, 34.
- 20 - for the property’s intended use.
Under Section 4 (and Exhibit B) of the Ground Lease, First Hartford was
obligated to provide adequate electricity service to the Premises as part of delivering
a “pad-ready” site, including preparing the site plans and bringing electrical service
to within five feet of the building or the curb line.106 The Lease’s requirement of
“adequate” electrical service encompasses whatever electrical infrastructure was
reasonably necessary to meet the tenant’s anticipated operational needs and to satisfy
the utility provider’s requirements.107
The evidence at trial established that the existing pole-mounted transformer
could not supply sufficient power for the Premises’ intended use. Testimony from
First Hartford itself—together with other evidence—demonstrated that PECO
required installation of a new, larger transformer to meet the building’s electrical
load, and that the transformer’s size and capacity necessitated placement within a
vault. The Court finds that installation of this upgraded transformer and vault fell
within First Hartford’s contractual obligation to provide “adequate . . .electricity
service” under the Lease. Simply put, the new transformer was “Site Work.”
ii. The Decorative Lighting and “Welcome to Horsham” Sign
Next, the Court begins by examining the Lease provisions governing First
106 Ground Lease. 107 Id., at § 4.
- 21 - Hartford’s responsibility to deliver the site in “pad-ready” condition. Under Lease
Exhibit B, as part of that delivery, First Hartford was required to “provide site
lighting per the Wild Fork Foods approved lighting plan.”108 To interpret this
obligation, the Court “must view the contract as a whole and not in discrete units.”109
First Hartford seeks to avoid financial responsibility by drawing a distinction
between “site lighting” and “township-mandated decorative lighting,” thereby
arguing that the lighting that the Township sought was Wild Fork’s responsibility
(e.g., building work rather than site work).110 Not so. The Lease states that site
lighting is First Hartford’s responsibility. 111 The Court must “resort to the plain
meaning of [that] language” rather than the “myth” of other types of lighting not
contemplated by the agreement but admitted through “extrinsic evidence.”112
But even if the Court agreed that the decorative lighting was somehow
different than other lighting on the property contemplated in the plain meaning of
108 Id., at Ex. B. 109 Bethlehem Steel Corp. v. MATX, Inc., 703 A.2d 39, 42 (Pa. Super. Ct. 1997) (citing Halpin v. LaSalle Univ., 639 A.2d 37, 39 (Pa. 1994)). See Southwestern Energy Prod. Co. v. Forest Res., LLC, 83 A.3d 117, 187 (Pa. Super. Ct. 2013) (citing Shehadi v. Northeastern Nat’l Bank, 378 A.2d 304, 306 (Pa. 1977) (“It is fundamental that one part of a contract cannot be so interpreted as to annul another part and that writings which comprise an agreement must be interpreted as a whole.”); Pines Plaza Bowling, Inc. v. Rossview, Inc., 145 A.2d 672, 676 (Pa. 1958) (“In construing a contract, the agreement must be interpreted as a whole, and the words given their ordinary meaning.”). 110 Pl.’s Post-Trial Br., at 11. 111 Ground Lease, at Ex. B. 112 Steuart, 444 A.2d at 663.
- 22 - the agreement—which the Court does not—the Lease expressly places on First
Hartford the obligation to obtain all local approvals, perform off-site improvements
required by governmental authorities, and cooperate in causing the Premises to be
supplied with utilities.113 The trial evidence established that the decorative lighting
was incorporated into the project because the Township considered it important to
securing its full support for the site’s change of use.114 Thusly, not only does the
Court find that the Lease required First Hartford to provide “site lighting” that would
cover the lights at issue, but these additional provisions collectively demonstrate that
First Hartford undertook the obligations necessary to secure governmental approval
and prepare the site for Wild Fork’s operations.115
Had the parties intended to exclude such lighting from the Lease’s broad
requirement to provide “site lighting,” they could have expressly done so. They did
not. Under these circumstances, the Court finds that whether termed “site lighting”
113 Ground Lease, at Ex. B. 114 First Hartford’s president testified that the Township “made it pretty clear” that incorporation of the decorative lighting was “above and beyond what the township was looking to have incorporated as part of the project in order to garner its full support to change the use of the site from what was a bank to a new Wild Fork location.” Trial Tr. Day 1, 21. The incorporation of the decorative lighting was, in part, a strategic decision to gain the Township’s support. Id. Wild Fork approved the lighting during the 2020 design process, well before redesigning the storefront or finalizing the project budget. See Trial Tr. Day 1, 23-26; Trial Tr. Day 2, 23-24. 115 LJL Transp., Inc. v. Pilot Air Freight Corp., 962 A.2d 639, 647 (Pa. 2009) (“[I]n determining the intent of the contracting parties, all provisions in the agreement will be construed together and each will be given effect.”); Murphy v. Duquesne Univ. of The Holy Ghost, 777 A.2d 418, 429 (Pa. 2001) (“The whole instrument must be taken together in arriving at contractual intent.”).
- 23 - or “decorative lighting,” the cost is properly characterized as “Site Work” falling
within First Hartford’s financial responsibility.116
The same reasoning applies to the “Welcome to Horsham” sign. Wild Fork’s
financial obligations relate principally to “improvements,” defined in the Lease and
MDC as building-related structures and amenities tied to the Wild Fork store and its
operation.117 Under the MDC “Improvements” is defined as
each [Wild Fork] Store and related improvements, for each Project, as shown on the applicable Site Plan and Plans Specifications, which shall include, without limitation all buildings, structures and other improvements to be located on the Land or within improved building space, in accordance with the applicable MDC New Property Supplement, Lease and/or Development Agreement.118
The Township sign, however, is a free-standing brick and concrete structure located
near the public sidewalk.119 It bears no relationship to Wild Fork’s store and is not
connected to the building in any physical or functional way. The Court can’t take a
myopic look at just isolated portions of the contract and find for First Hartford; in
fact, it is prohibited from doing so.120 As with the decorative lighting, the sign was
116 The decorative lighting is both site lighting and deemed by both parties as being necessary to gain the Township’s support and approval “to construct and operate a Wild Fork Foods store.” Ground Lease, at Ex. B. 117 Id., at § 8.3. 118 Master Development Contract, at “Definitions”. 119 See TX-3. 120 Bethlehem Steel Corp., 703 A.2d at 42 (instructing that the Court “must view the contract as a whole . . .”).
- 24 - included because both parties believed it necessary to obtain full Township support
for redevelopment of the site—support that was First Hartford’s to obtain.121 First
Hartford was to obtain “Local approvals”, provide “retaining walls” and
“landscaping”, and other “off-site improvements required by any governmental
authority.”122 No doubt, the sign is not specified as a responsibility of either party,
but when the Lease is read as a cohesive whole, the sign is properly understood as
site work for which First Hartford is responsible.123
In sum, the Court concludes that the decorative lighting and the “Welcome to
Horsham” sign are components of the site work required for First Hartford to deliver
the Premises in pad-ready condition. The Lease, its incorporated exhibits, and the
evidence presented at trial all demonstrate that these government-driven, publicly
oriented improvements fall squarely within First Hartford’s obligations, and First
Hartford remains financially responsible for them.
iii. The Sidewalks
The Court also finds that the sidewalk-related work identified in the Change
Order constitutes “Site Work” for which First Hartford is financially responsible.
121 Like the decorative lighting, the parties believed the sign to be a necessary improvement “to garner [the Township’s] full support to change the use of the site from what was a bank to a new Wild Fork location.” Trial Tr. Day 1, 21; Ground Lease, at Ex. B. 122 Ground Lease, at Ex. B. 123 Id.
- 25 - Exhibit B of the Lease expressly assigns to First Hartford the obligation to prepare
“the subgrade for Building sidewalks” and to provide all “curb cuts, concrete curbs,
access driveways, and public sidewalks.”124 These provisions reflect a broad
allocation of responsibility for the construction and installation of sidewalks and
related public-access features.125
Although Lease Section 8.3 makes Wild Fork financially responsible for
“improvements,” including certain amenities such as sidewalks, that provision
applies only after Wild Fork has received all required approvals and has authorized
new construction by written notice126—further, its obligations to construct sidewalks
are only for that of a “typical Wild Fork Food grocery store” and not sidewalks
required for government approval.127 Section 8.3 thus governs Wild Fork’s
responsibilities during its interior build-out phase—after First Hartford has already
delivered a pad-ready site.128 This is reinforced by Exhibit B, which states that Wild
Fork is responsible only for work directly tied to the building foundation, such as
124 Id. 125 See generally id.; Bethlehem Steel Corp., 703 A.2d at 42. 126 Ground Lease., at § 8.3. 127 Id. (“(ii) construct, or caused to be constructed, on the Premises a typical Wild Fork Food grocery store consisting of approximately 3,963 square feet, together with infrastructure, facilities and amenities necessary or desirable in connection therewith (e.g. sidewalks, parking spaces, trash receptacles, landscaping, lighting, etc.) . . .”). 128 See id.
- 26 - excavation, backfill, forming, pouring, and related inspections.129 Nothing in
Exhibit B shifts responsibility for site-level sidewalks to Wild Fork.
When the relevant provisions are read together, the general structure of the
Lease becomes clear: First Hartford must deliver all site-level improvements and
public-facing access features necessary to make the Premises pad-ready;130 Wild
Fork assumes responsibility only for building-specific improvements undertaken
after approvals are secured.131 First Hartford’s obligations were to provide “public
sidewalks in accordance with the site plans.”132
Accordingly, the Court concludes that the sidewalk work at issue falls
squarely within First Hartford’s contractual obligations as “Site Work,” and First
Hartford is financially responsible for the costs reflected in the Change Order.
3. First Hartford is in breach of the MDC’s indemnity provision.
First Hartford has failed to establish that Wild Fork breached the MDC or
Lease for Wild Fork’s alleged failure to pay the Change Order. The Change Order
projects were all related to “site work” and thus First Hartford’s financial
responsibility. Similarly, Wild Fork is not in breach of the MDC or the Lease for
129 Ground Lease, at Ex. B. 130 Id. 131 Ground Lease, at § 8.3. 132 Ground Lease, at Ex. B; see also Master Development Contract (“The Improvements may consist of but not be limited to the following: a building (or portion thereof), sidewalks, service drives, parking aisles, driveways, parking area, . . .”).
- 27 - failing to remove the PBI lien earlier than it did.
That said, the record reflects two additional points: (1) Wild Fork’s
representative at one point signaled that Wild Fork would pay for the work at
issue,133 and (2) Wild Fork ultimately did pay PBI for that work to resolve the
mechanic’s lien and related litigation.134 Those facts, however, do not alter the
Court’s conclusion that, under the governing contracts, the Change Order items were
“Site Work” and thus First Hartford’s financial responsibility in the first instance.
As a result, the Court finds that First Hartford is in breach of the MDC for
failing to indemnify Wild Fork in connection with the PBI lien and litigation. Article
9 of the MDC addresses indemnification.135 The provisions applicable to each party
are nearly identical. As relevant here, First Hartford agreed:
[First Hartford] shall indemnify, defend, protect and hold harmless [Wild Fork] . . . from and against any and all liabilities, damages, obligations, judgments, losses, demands, claims, causes of action, costs and expenses, of any kind or nature (including without limitation, reasonable attorneys’ fees and technical consultants’ fees and expenses), as they come due and amounts paid in judgment or settlement incurred or sustained by or asserted against [Wild Fork] in any manner directly or indirectly arising out of or resulting from: . . .
(a)(ii) [First Hartford’s] failure to make timely payments to any third-party related to a Project, . . . 136
133 Joint Stip. Facts, ¶ 55. 134 Id., ¶ 64. 135 Master Development Contract, at Art. 9. 136 Id.
- 28 - Because the Court has already found that the Change Order projects were
“Site Work” and First Hartford’s financial responsibility, PBI’s mechanic’s lien and
lawsuit plainly “directly or indirectly” arose from First Hartford’s failure to make
timely payments to PBI, a third-party related to the Project.137 Under Article 9(a)(ii),
First Hartford was obligated to indemnify Wild Fork for the amounts it paid to
resolve PBI’s claims, as well as Wild Fork’s associated fees and costs.138
Accordingly, Wild Fork is entitled to recover from First Hartford the $288,866.00
Change Order amount, exclusive of interest, plus its reasonable fees and costs arising
out of the PBI litigation.
B. FIRST HARTFORD’S CASPA CLAIM FAILS BECAUSE WILD FORK WAS NOT FINANCIALLY RESPONSIBLE FOR THE CHANGE ORDER.
First Hartford has said that it is owed damages due to a violation of
Pennsylvania’s Contractor and Subcontractor Payment Act (“CASPA”).139 The
CASPA mandates timely payment to contractors and subcontractors involved in
construction contracts.140 But the Court finds that CASPA does not govern here.
137 See id. 138 The Court does not find—given the circumstances it then faced—Wild Fork’s decision to ultimately pay PBI and settle the litigation relieves First Hartford of its financial responsibility. Although Mr. Falgons of Wild Fork okayed the payment in order to have the lien removed, the Court does not find that Mr. Falgons was authorized by Wild Fork to alter its financial obligations in that instance. In the Court’s view, Wild Fork clearly paid under a reservation of rights to contest that particular change order. 139 Pl.’s Post-Trial Br., 37-43. See 73 PA. STAT. AND CONS. STAT. ANN. § 501, et. seq. (West 2022). 140 El-Gharbaoui v. Ajayi, 260 A.3d 944, 954 (Pa. Super. Ct. 2021).
- 29 - For the reasons set out above, Wild Fork was not required to pay for any of
the expenses of the Change Order.
As Pennsylvania’s Superior Court has explained:
By its terms, CASPA applies to construction contracts. One must first establish a contractual right to payment pursuant to either a written or oral contract, and breach of that contract, to be entitled to CASPA relief. Thus, the construction contract is the starting point of any CASPA analysis. CASPA does not supplant the traditional breach of contract action between contracting parties; it merely makes additional remedies available to contractors and subcontractors when they are not promptly paid by the party with which they contracted.141
Given this, the statute is inapplicable. And so, the Court need not even approach
the other CASPA-determinative questions of whether Wild Fork was the “owner” of
the Horsham Property or First Hartford Wild Fork’s “contractor.”142 It is enough to
find that the CASPA only applies when a contractor or sub isn’t “promptly paid by
the party with which [it] contracted.”143 Because Wild Fork is not required to pay
for any part of the Change Order, the CASPA does not apply.
141 Scungio Borst & Associates v. 410 Shurs Lane Developers, LLC, 106 A.3d 103, 109 (Pa. Super. Ct. 2014). 142 73 PA. STAT. AND CONS. STAT. ANN. § 502 (West 2022) (“‘Contractor.’ A person authorized or engaged by an owner to improve real property.” . . . ‘Owner.’ A person who has an interest in the real property that is improved and who ordered the improvement to be made. The term includes successors in interest of the owner and agents of the owner acting with their authority.”) 143 Scungio Borst & Associates, 106 A.3d at 109.
- 30 - C. FIRST HARTFORD IS IN BREACH OF THE MASTER DEVELOPMENT CONTRACT’S PROFIT-SHARING PROVISION UNDER TEXAS LAW.
In its counterclaim, Wild Fork contends that First Hartford is in breach of the
MDC’s Profit-Sharing provision, which obligates First Hartford to pay Wild Fork
$891,381.50 in retained profits from the Texas properties.144 Under Texas law, a
plaintiff must establish “the existence of a valid contract, performance or tendered
performance by the plaintiff, the defendant breached the contract, and damages
resulting from the breach.”145 The parties do not dispute the existence of the MDC
or that both sides performed under it. And Wild Fork has also shown that, if First
Hartford is in breach, it has suffered damages in the amount of the withheld profit-
sharing payments. Accordingly, the only remaining question is whether First
Hartford breached the MDC’s Profit-Sharing provision.
For the reasons explained above, the Court has already found that Wild Fork
didn’t breach the MDC or the Lease by refusing to pay the Change Order. The
Change Order work was “Site Work” and First Hartford’s financial responsibility.
Wild Fork’s refusal to assume those costs therefore had no effect—legal or
practical—on First Hartford’s independent obligation to share profits from the Texas
144 See Master Development Contract, at Art. 7. 145 Dixie Carpet Installations, Inc. v. Residences at Riverdale, LP, 599 S.W.3d 618, 625 (Tex. Ct. App. 2020).
- 31 - properties under the MDC.146
But even if the Court had found some breach by Wild Fork in connection with
the Horsham Project—which, again, it has not—that would not excuse First
Hartford’s profit-sharing obligations under Texas law. The dispositive question
would then be whether any such breach was material.147 And that question is
determinative because, under Texas law, it resolves whether a party is excused from
performance—here, payment under the MDC—or whether damages is the
appropriate remedy.148
As the Texas Supreme Court explained thoroughly in Bartush-Schnitzius
Foods Co. v. Cimco Refrigeration, Inc.:
It is a fundamental principle of contract law that when one party to a contract commits a material breach of that contract, the other party is discharged or excused from further performance. By contrast, when a party commits a nonmaterial breach, the other party is not excused from future performance but may sue for the damages caused by the breach. The latter principle is consistent with settled Texas law regarding the elements of a contract claim. The claim requires a finding of breach, not a finding of material breach. . . . Accordingly, a material breach by [a contracting party] would have excused [the other party] from making further contractual payments, while a nonmaterial breach would have simply given rise to a claim for damages.149
Texas Courts apply the Restatement (Second) of Contracts for determining
146 See Master Development Contract, at Art. 7. 147 Bartush-Schnitzius Foods Co. v. Cimco Refrigeration, Inc., 518 S.W.3d 432, 436 (Tex. 2017). 148 Id. 149 Id. (cleaned up).
- 32 - whether a breach is material.150 Section 241 thereof identifies the following non-
exclusive factors:
(a) the extent to which the injured party will be deprived of the benefit which he reasonably expected; (b) the extent of which the injured party can be adequately compensated for the part of that benefit of which he will be deprived; (c) the extent to which the party failing to perform or to offer to perform will suffer forfeiture; (d) the likelihood that the party failing to perform or to offer to perform will cure his failure, . . ; (e) the extent to which the behavior of the party failing to perform or to offer to perform comports with standards of good faith and fair dealing.151
Applying these factors, First Hartford was not deprived of the benefit it
reasonably expected from its relationship with Wild Fork—ownership of a
developed property and rental income from a functioning Wild Fork store.152 Wild
Fork substantially performed its obligations; any alleged shortfall related to the
Change Order did not undermine the core economic exchange between the parties.153
By contrast, excusing First Hartford’s performance under the MDC’s Profit-Sharing
150 Both Texas and Pennsylvania apply the same factors when determining whether a breach is material. Compare Mustang Pipeline Co., Inc. v. Driver Pipeline Co., Inc., 134 S.W.3d 195, 199 (Tex. 2004), and Pasha & Sina, Inc. v. Shields Ltd. Partnership, 2023 WL 2422485, at *6 (Tex. Ct. App. March 9, 2023), with International Diamond Importers, Ltd. v. Singularity Clark, L.P., 40 A.3d 1261, 1271 (Pa. Super. Ct. 2012) and Widmer Engineering, Inc. v. Dufalla, 837 A.2d 459, 468 (Pa. Super. Ct. 2003). 151 RESTATEMENT (SECOND) OF CONTRACTS § 241 (A.L.I. 1981). 152 See RESTATEMENT (SECOND) OF CONTRACTS § 241(a). 153 See Hernandez v. Gulf Group Lloyds, 875 S.W.2d 691, 693 (Tex. 1994); Widmer Engineering, Inc. v. Dufalla, 837 A.2d 459, 468-69 (Pa. Super. Ct. 2003).
- 33 - provision would impose a significant forfeiture on Wild Fork.154 It would stand to
lose nearly $900,000 in profit-sharing from the Texas properties and potentially
further economic benefit from its Horsham operations—all over a dispute that:
(1) had little to do with the Texas sales; and (2) the Court has already found involved
work that was First Hartford’s financial responsibility in the first instance.155 What’s
more, Wild Fork ultimately paid PBI. To the extent any earlier payment could have
been made, the evidence showed that Wild Fork acted in good faith based on a
reasonable belief that the Change Order work constituted “Site Work” for which
First Hartford was responsible, and that First Hartford certainly had ready means to
mitigate any damage from the delay.
Considering the parties’ relationship as a whole, the Court cannot conclude
that—even if one existed—any alleged breach by Wild Fork related to Horsham was
so substantial as to justify First Hartford treating the MDC as effectively terminated
or using it as a basis to withhold profit-sharing on the Texas projects.156 First
Hartford is not excused from its obligations under the Profit-Sharing provision. It
must pay Wild Fork its profit share of $891,381.50.
Texas law also permits recovery of “reasonable attorney’s fees from an
154 See RESTATEMENT (SECOND) OF CONTRACTS § 241(c). 155 See id. 156 See Hernandez v. Gulf Group Lloyds, 875 S.W.2d 691, 693 (Tex. 1994) (“The less the non- breaching party is deprived of the expected benefit, the less material the breach.”).
- 34 - individual or organization . . . in addition to the amount of a valid claim and costs,
if the claim is for . . . an oral or written contract.”157 Texas Civil Practice and
Remedies Code Section 38.001 requires that the claimant prevail on the underlying
claim and recover damages in order to recover attorney’s fees.158 As First Hartford
recognizes, “[t]he Texas Statute automatically awards attorneys’ fees to [Wild Fork]
in this case, assuming they are successful on their Counterclaim for breach of the
MDC.”159 Having found Wild Fork to be the prevailing party on its breach-of-
contract counterclaim as to the MDC Profit-Sharing provision, and that it is entitled
to damages, the Court further finds that Wild Fork is entitled to recover its reasonable
attorney’s fees under § 38.001 for this particular issue and claim.160
D. FIRST HARTFORD’S QUANTUM MERUIT AND UNJUST ENRICHMENT CLAIMS FAIL BECAUSE THE RELATIONSHIP IS GOVERNED ENTIRELY BY VALID OPERATIVE CONTRACTS.
Pennsylvania law makes clear that a “claim for damages in quantum meruit is
fundamentally an equitable claim of unjust enrichment.”161 But the “absence of an
157 TEX. CIV. PRAC. & REM. CODE ANN. § 38.001 (West 2025). 158 See In re Nalle Plastics Family Ltd. Partnership, 406 S.W.3d 168, 173 (Tex. 2013) (“To recover attorney’s fees under this statute, a party must first prevail on the underlying claim and recover damages.”). . 159 Pl.’s Post-Trial Br., 33-34. 160 James Constr. Grp., LLC v. Westlake Chemical Corp., 650 S.W.3d 392, 418 (Tex. 2022); TEX. CIV. PRAC. & REM. CODE ANN. § 38.001 (West 2025). 161 Meyer, Darragh, Buckler, Bebenek & Eck, P.L.L.C. v. L. Firm of Malone Middleman, P.C., 179 A.3d 1093, 1102 (Pa. 2018) (quoting Shafer Elec. & Const. v. Mantia, 96 A.3d 989, 993 (Pa. 2014)).
- 35 - enforceable contract at law is the seed from which an unjust-enrichment claim in
equity sprouts.”162 Thus, “quantum meruit and unjust enrichment, by definition,
imply that no valid and enforceable written contract exists between the parties.”163
Where, as here, the parties’ rights and obligations are defined by comprehensive,
enforceable contracts, the doctrine of unjust enrichment does not apply.164 Because
the MDC, the Lease, and the related supplements fully govern the parties’
relationship,165 First Hartford cannot pursue recovery in quantum meruit or unjust
enrichment; these claims fail as a matter of law.
E. FIRST HARTFORD WAS ENTITLED TO THE RENT ADJUSTMENT.
The evidence also establishes a separate issue concerning the adjustment of
base rent under the Lease. Article 7 of the MDC provides that “the final initial rent
payable by [Wild Fork] to [First Hartford] under a Lease shall be established by
imposing a capitalization rate of 7.5% of [First Hartford’s] costs.”166 But in the event
the Actual Project Costs exceed the initial estimate of Developer’s Costs, Article 7
provides, in relevant part:
162 Wilson v. Parker, 227 A.3d 343, 353 (Pa. Super. Ct. 2020). 163 Id. (quoting Shafer Elec. & Const. v. Mantia, 67 A.3d 8, 13 (Pa. Super. Ct. 2013), aff’d on other grounds, 96 A.3d 989 (Pa. 2014)); Shafer Elec. & Const., 67 A.3d at 13 (“Critically . . . the doctrine of unjust enrichment is inapplicable when the relationship between the parties is founded upon a written agreement or express contract.”). 164 Shafer Elec. & Const., 67 A.3d at 13. 165 See Joint Stip. Facts, ¶ 34. 166 Master Development Contract, at Art. 7.
- 36 - in the event the Actual Project Costs exceed the initial estimate of Developer’s Costs by an amount greater than one thousand dollars ($1,000.00) and less than a sum equal to one hundred ten percent (110%) [] of the initial estimate of Developer’s Costs, then Developer and [Wild Fork] will enter into a mutually agreed upon Lease amendment (each in its reasonable discretion as to the form of the Lease amendment) on or before the ninetieth (90th) day following Developer’s delivery and [Wild Fork’s] acceptance of each Project in order to increase the final initial annual base rent based on the same formula.167
Wild Fork’s initial annual rent amount was set at $130,000.00, reflecting 7.5%
of the Horsham Project’s estimated costs.168 The initial estimated budget was
$1,740,000.00.169 The final actual cost was $1,922,053.55.170 For purposes of the
rent increase formula, Article 7 of the MDC places a cap on actual costs at 110% of
the initial estimated budget.171 110% of the original budget is $1,914,000.00.
Therefore, the adjusted annual base rent should be 7.5% of $1,914,000.00, or
$143,550.00. This provision was triggered in March of 2022 when First Hartford
delivered the property to Wild Fork.172 As such, the Court finds the annual base rent
amount should have been $143,550.00 and Wild Fork was obligated to pay this
amount beginning in March of 2022 (the time of the store opening) and through to
167 Id. 168 Joint Stip. Facts, ¶ 65. 169 TX-62. 170 Id. 171 Master Development Contract, at Art. 7. 172 Id.
- 37 - the sale of the property in October 2023. 173
Too, the Court finds that First Hartford has proven by a preponderance of the
evidence that it was damaged by a $250,000 loss in value of the property upon its
marketing and sale without the required Lease Amendment having been executed.174
No doubt, the burden was on First Hartford to demonstrate damages as an
element of this specific breach-of-contract claim. “Under Delaware law, plaintiffs
must prove their damages with a reasonable degree of precision and cannot recover
damages that are ‘merely speculative or conjectural.’”175 But Delaware does not
“require certainty in the award of damages where a wrong has been proven and
injury established.”176 Indeed, “[t]he quantum of proof required to establish the
amount of damage is not as great as that required to establish the fact of damage.”177
173 See Pl.’s Post-Trial Br., at 30 (citing TX-62 and estimating lost rent at “roughly $17,000.00”). 174 See TX-60; TX-49; TX-22; TX-23. See Great Hill Equity Partners IV, LP v. SIG Growth Equity Fund I, LLLP, 2020 WL 948513, at *20 (“[S]o long as a plaintiff provides a reasonable method to calculate damages, the risk that such cannot be determined with mathematical certitude falls on the wrongdoer, not the wronged.”). 175 Kronenberg v. Katz, 872 A.2d 568, 609 (Del. Ch. 2004) (quoting Laskowski v. Wallis, 205 A.2d 825, 826 (Del. 1964) (quoting Henne v. Balick, 146 A.2d 394, 396 (Del. 1958)); In re Mobilactive Media, LLC, 2013 WL 297950, at *24 (Del. Ch. Jan. 25, 2013) (“[W]hen acting as the fact finder, th[e] Court may not set damages based on mere ‘speculation or conjecture’ where a plaintiff fails adequately to prove damages.”) (quoting Medek v. Medek, 2009 WL 2005365, at *12 n.78 (Del. Ch. July 1, 2009)). 176 Del. Express Shuttle, Inc. v. Older, 2002 WL 31458243, at *15 (Del. Ch. Oct. 23, 2002) (quoting Red Sail Easter Ltd. Partners, L.P. v. Radio City Music Hall Prods., Inc., 1992 WL 251380, at *7 (Del. Ch. Sept. 29, 1992)). 177 Total Care Physicians, P.A. v. O’Hara, 2003 WL 21733023, at *3 (Del. Super. Ct. July 10, 2003).
- 38 - Responsible estimates of damages that lack mathematical certainty are permissible
so long as the fact finder had a basis to make such a responsible estimate.178
Instructive here, in the context of contractual damages, our Supreme Court
has explained that “when a contract is breached, expectation damages can be
established as long as the plaintiff can prove the fact of damages with reasonable
certainty. The amount of damages can be an estimate.”179
Here, the Court has weighed the credible evidence First Hartford adduced
regarding the difference in the final sale price and the effect the lack of the Lease
Amendment had thereon finding that First Hartford has provided a substantial “basis
to make such a responsible estimate” of that damage.180 And the reasonable estimate
of that damage is a $250,000 loss in value. 181 Wild Fork’s complaints of too great
a level of uncertainty for any damages to be awarded on this issue are unavailing.182
178 Beard Research, Inc. v. Kates, 8 A.3d 573, 613 (Del. Ch. 2010), aff’d sub nom. ASDI, Inc. v. Beard Research, Inc., 11 A.3d 749 (Del. 2010). 179 Siga Techs., Inc. v. PharmaAthene, Inc., 132 A.3d 1108, 1111 (Del. 2015). 180 Beard Research, 8 A.3d at 613. 181 See Trial Tr. Day 2, 187-96 (D.I. 87); TX-60; TX-49; TX-22; TX-23. 182 See Great Hill Equity Partners IV, LP v. SIG Growth Equity Fund I, LLLP, 2020 WL 948513, at *20 (“Delaware courts place the burden of uncertainty where it belongs; so long as a plaintiff provides a reasonable method to calculate damages, the risk that such cannot be determined with mathematical certitude falls on the wrongdoer, not the wronged.”) (citing In re Mobilactive Media, LLC, 2013 WL 297950, at *24).
- 39 - VI. VERDICT AND JUDGMENT
Consistent with the foregoing findings and conclusions, the Court enters the
following verdict:
• As to First Hartford’s Counts I, II, III, IV, and V (breach of the MDC, breach of the Lease, quantum meruit, unjust enrichment, and CASPA), the Court finds in favor of Wild Fork and against First Hartford. First Hartford shall recover nothing on those counts.
• As to First Hartford’s Count VI—concerning the requested rent adjustment, the Court finds in favor of First Hartford and against Wild Fork. Under Article 7 of the MDC and the Lease, the proper initial annual base rent for the Horsham Property is $143,550.00, calculated as 7.5% of $1,914,000.00 (110% of the original estimated project cost). Wild Fork was obligated to execute a Lease amendment reflecting this rent figure, effective as of March 2022, and to pay to First Hartford the difference between the rent actually paid and the rent that should have been paid at $143,550.00 per year from March 2022 through the property’s sale in October 2023.183 The Court also finds a loss of $250,000 reflecting the price reduction upon the property’s sale to have been proven by a preponderance of the evidence. These specific damages carry with them any applicable pre- and post-judgment interest as provided by Delaware law.
• As to Wild Fork’s counterclaim alleging breach of First Hartford’s indemnification obligations under the MDC and Horsham Lease, the Court finds in favor of Wild Fork and against First Hartford. First Hartford is obligated to reimburse Wild Fork the $288,866.00 paid to PBI in satisfaction of the Change Order work and to indemnify Wild Fork for its reasonable attorney’s fees and costs incurred in connection with the PBI mechanic’s lien and related litigation, in an amount to be determined upon application if the parties cannot agree.
• As to Wild Fork’s counterclaim alleging breach of the MDC’s Profit- Sharing provision under Texas law, the Court finds in favor of Wild Fork and against First Hartford. First Hartford is obligated to pay 183 See n.173, supra. - 40 - Wild Fork $891,381.50 in withheld profit-sharing proceeds relating to the Texas properties, together with Wild Fork’s reasonable attorney’s fees incurred in enforcing the Profit-Sharing provision, pursuant to Texas Civil Practice and Remedies Code § 38.001, in an amount to be determined upon application if the parties cannot agree, as well as applicable pre- and post-judgment interest as provided by law.
The parties are directed to confer and submit a proposed form of final
judgment that reflects the specific monetary amounts due under this Decision—
including the rent differential, diminution in the sale price of the Horsham Property,
indemnity amounts, profit-sharing amounts, attorney’s fees, costs, and interest—and
that accounts for any appropriate setoff between First Hartford’s and Wild Fork’s
respective monetary obligations. The proposed final judgment shall be prepared and
submitted no later than January 9, 2026.
IT IS SO ORDERED.
/s/ Paul R. Wallace _______________________ Paul R. Wallace, Judge Original to Prothonotary
cc: All counsel via File & Serve
- 41 -
Related
Cite This Page — Counsel Stack
First Hartford Realty Corporation v. Food Ventures North America, Inc., Counsel Stack Legal Research, https://law.counselstack.com/opinion/first-hartford-realty-corporation-v-food-ventures-north-america-inc-delsuperct-2025.