FIRST DIVISION PHIPPS, C. J., ELLINGTON, P. J., and BRANCH, J.
NOTICE: Motions for reconsideration must be physically received in our clerk’s office within ten days of the date of decision to be deemed timely filed. http://www.gaappeals.us/rules/
March 14, 2014
In the Court of Appeals of Georgia A13A1679. CHAMPION WINDOWS OF CHATTANOOGA, LLC v. EDWARDS.
B RANCH, Judge.
JoAnne Edwards contracted with Champion Windows of Chattanooga, LLC
(“Champion” or “Champion-Chattanooga”), for the construction of a deck and
screened porch at her residence in Ringgold. After Champion had partially constructed
the deck and the porch, Edwards refused to allow Champion to complete the project.
Champion then filed the current breach of contract action against Edwards in Catoosa
County Superior Court. Edwards filed an answer and counterclaims, in which she
sought rescission of the contract and damages for negligent construction.1 Following
1 Edwards also asserted claims for alleged violations of Georgia’s Fair Business Practices Act (OCGA § 10-1-390, et seq.) and a violation of the “peddler” ordinances of Catoosa County. The trial court did not award judgment to Edwards on these claims. a bench trial, the court entered judgment in favor of Edwards, finding that she was
entitled to rescind the contract based on Champion’s fraud and that she was entitled
to damages resulting from Champion’s defective workmanship on the portion of the
project that it had constructed. Champion now appeals from that order, asserting that
the trial court’s judgment is unsupported by the evidence. We agree. Accordingly, we
reverse the order of the trial court and remand the case for entry of judgment in favor
of Champion on its breach of contract claim and for a determination of damages.
On an appeal from an entry of judgment following a bench trial, we apply a de
novo standard of review to any questions of law decided by the trial court, but will
defer to any factual findings made by that court if there is any evidence to sustain
them. Lifestyle Home Rentals v. Rahman, 290 Ga. App. 585 (660 SE2d 409) (2008).
“However, if the trial court makes a finding of fact which is unsupported by the
record, [that finding] cannot be upheld” and any judgment based upon such a finding
must be reversed. (Citation and punctuation omitted.) Wilen v. Murray, 292 Ga. App.
30, 31 (663 SE2d 403) (2008).
The record shows that Champion-Chattanooga was incorporated in 1998 and
that it is a local subsidiary or division of a national corporation based in Cincinnati,
Ohio, that does business under the trade name Champion Window. This parent
2 corporation, in turn, owns three Ohio-based factories, which manufacture the
components used in the screened porches, decks, and patio rooms sold and built by
Champion Window and its subsidiaries. Champion Window owns 75% of Champion-
Chattanooga and the Chattanooga division obtains all of the products it sells from
Champion Window or its wholly-owned subsidiaries. Additionally, all of Champion-
Chattanooga’s employees, including its sales representatives and its managers who
construct the patio rooms, decks, and screened porches, travel to Ohio for training at
the Champion Window corporate campus. It is the understanding of these employees
that although their immediate supervisors are located in Chattanooga, they work for
Champion Window (the parent corporation).
In April 2006, after seeing Champion Window’s advertisement in a magazine,
Edwards called the telephone number listed in the ad to inquire about the construction
of a screened porch at her residence. According to Edwards’s testimony, she
understood that she was calling a business in Chattanooga, Tennessee, and she
believed she was calling the local office of a national corporation (Champion
Window), that had been in business since 1953. During the phone call, Edwards made
an appointment to meet with a Champion representative at her home the following
day.
3 On April 25, 2006, Donald McKenna, a factory sales representative for
Champion Window who worked out of the Chattanooga division, visited Edwards in
her home and provided her with information regarding Champion Window’s products
and services. McKenna told Edwards what he referred to as “the Champion story,”
and provided her with a brochure about Champion Window and its products.2
McKenna also discussed with Edwards the type of deck, porch, or patio room she was
interested in and showed her samples of the building materials manufactured by
Champion Window. After Edwards decided that she wanted a deck and screened
porch, McKenna priced the project for her. The parties then negotiated over the price,
and after McKenna offered her a 15 percent discount, Edwards agreed to contract with
Champion for the project. The agreed upon contract price was $29,991, with Edwards
providing a down payment of $9,000 3 with the balance to be due when construction
was complete.
2 The brochure appears to have been produced by the parent corporation for use by all of its subsidiaries. It bears the corporate logo of Champion Window, advertises the company as having been in business since 1953, and lists the website of Champion Window (www.championwindow.com). 3 Edwards paid this deposit via check, made payable to “Champion Window.”
4 McKenna wrote out the contract using a preprinted form bearing the corporate
logo of Champion Window and a Chattanooga address. McKenna filled in blanks and
checked boxes on the form specifying the dimensions of the deck and porch, the
material to be used, and, where relevant, the color of those materials. He also drew a
“layout sketch” of the project in a designated space on the form, which included the
dimensions of the proposed construction and its position relative to Edwards’s house.
Printed on the form, in a separate box immediately next to the contract price is a
notice captioned, “BUYER’S RIGHT TO CANCEL.” The notice states:
BUYER MAY CANCEL THIS CONTRACT BY DELIVERING WRITTEN NOTICE TO THE SELLER AT ANY TIME PRIOR TO MIDNIGHT OF THE THIRD BUSINESS DAY AFTER THE DATE OF THIS TRANSACTION. BUYER MAY USE THIS CONTRACT AS THAT NOTICE BY WRITING “I HEREBY CANCEL” AT THE BOTTOM AND ADDING BUYER’S NAME AND ADDRESS. THE NOTICE MUST BE DELIVERED TO THE SELLER AT THE ADDRESS SHOWN ABOVE.
Additionally, immediately above the contract’s signature lines is a paragraph which
contains the following sentence: “Since this contract calls for made to order goods, it
is not subject to cancellation except as stated above.”
5 Edwards signed the contract and she testified that, before she did so, she read
the entire document. She also explained that before she signed, she confirmed with
McKenna that Champion had been in business since 1953, “because I wanted to go
with a large company, because I thought they would be more reputable.” McKenna
also signed the contract, on the line designated “Champion Representative.”
Construction on the deck and porch began sometime in June 2006. On
approximately June 27, 2006, when the project was about fifty percent complete,
Edwards’s ex-husband, Greg Edwards, called John McGill, a Division Manager for
Champion Window who oversees the Chattanooga subsidiary, and informed McGill
that he had problems with the price of the project and he wanted the work stopped.
McGill and McKenna met with Greg and JoAanne Edwards at Edwards’s residence
on June 28, 2006 in an attempt to resolve any problems with the project, and
according to McGill, Greg Edwards told them that the project “was too much money
. . . and that he was putting a stop work order on it.”
Greg Edwards testified that he contacted McGill because he had concerns with
both the cost of the project and the quality of the construction. He requested that
Champion provide him with an itemized cost list and, when it provided that list at the
June 28 meeting, it showed what he believed to be an exorbitant cost for a screen
6 door, and he became even more concerned about the cost. He further explained, “I
knew that it [the project] was a $10,000-to-$14,000 job, and [Champion’s] charging
a woman $29,000 for it.” Mr. Edwards also testified that his concerns over
construction problems grew when McGill was shown those concerns and responded
by indicating that Champion would fix any problems on the “punch list” at the end of
construction. In Mr. Edwards’s opinion, the concerns he was raising were far more
serious than those that could be addressed as part of a punch list.
Following the meeting with McGill and McKenna , Greg and JoAnne Edwards
sent a letter to McGill in which they stated: “This letter is to confirm our
conversations of June 27 and 28. All work on [the] screen porch is ordered stopped
immediately. Under no circumstances will Champion W indow[ ] be paid for any work
done after June 27.” On June 29, 2006, Champion’s attorney sent a letter to Edwards
demanding that the company be allowed to complete the contract. In response,
Edwards returned the letter on which she and/or her ex-husband had written, “It is not
my intent to allow Champion back on this property . . . contact Robbie Stultz
[Edwards’s attorney] with all further communications.” 4 Champion then sent another
letter asking to be allowed to complete the contract, but it never received a response.
4 This note was signed by both Greg and JoAnne Edwards.
7 After Edwards’s continued refusal to honor the contract, Champion filed the
current action on July 7, 2006. Trial was held on November 14, 2007.5 Five years and
three months later, on February 11, 2013, the trial court entered an order, drafted by
Edwards’s lawyer and finding that Edwards was entitled both to rescind the contract
and to recover damages for Champion’s negligence in performing work pursuant to
that contract.6 This appeal followed.
1. The trial court found that Edwards was entitled to rescind the contract based
on Champion’s “knowingly . . . false representations as to its work product, its history
as a corporation, and its affiliation with Champion [Window].” On appeal, Champion
contends that the trial court’s findings are unsupported by the evidence and,
accordingly, the court’s conclusion that Edwards was entitled to rescission constitutes
legal error. We agree.
5 Although both the transcript and the trial court’s order refer to the November 14 proceeding as a “hearing,” it is clear that what transpired was a bench trial. 6 Notably, although the court found that Edwards was entitled to rescission, its order did not require Champion to return the $9,000 down payment it had received from Edwards or otherwise award judgment to Edwards in that amount. Nor did the order require Edwards to return to Champion its materials which the company had left on Edwards’s property for the purpose of completing the screened porch and deck and which Edwards had retained, even after purporting to rescind the contract. Rather, the only relief afforded by the order was a judgment of $1,500 in favor of Edwards and against Champion, as damages for Edwards’s negligent construction claim.
8 To justify rescission of a contract for fraud in the inducement, the party seeking
rescission must prove that the party with whom it contracted made a knowingly false
representation; that it did so with the intent of inducing the first party to act in reliance
on the deliberate misrepresentation; and that the first party justifiably relied on the
misrepresentation, to that party’s detriment. See Turner Outdoor Advertising v.
Fidelity Eastern Financial, 185 Ga. App. 815, 816 (366 SE2d 201) (1988). “When
evidence as to any one of these elements is lacking,” then the rescission claim must
fail. (Footnote omitted.) Young v. Oak Leaf Builders, 277 Ga. App. 274, 278 (3) (626
SE2d 240) (2006). Here, we find that Edwards failed to present evidence showing
either that Champion made any deliberate and knowing misrepresentation to her or
that she detrimentally relied on any such misrepresentation.
The trial court’s finding that Champion knowingly made a false representation
as to “its history as a corporation and its affiliation with Champion [Window]” is
apparently based on Edwards’s contention that Champion W indows of Chattanooga,
LLC, the company with whom she contracted and which did not exist until 1998,
misrepresented itself as Champion Window, a company that had been in business
since 1953. The evidence, however, shows that Champion-Chattanooga is a subsidiary
or division of Champion Window. The parent corporation has 75% ownership of, and
9 therefore controls, Champion-Chattanooga. Additionally, Champion-Chattanooga has
no website independent of Champion Window; if a person wants to access
information on the internet about the Chattanooga division of Champion Window,
they must go through the corporate website of the parent company. All of the
employees working out of the Chattanooga division are trained by Champion Window
at the parent company’s corporate campus, and the employees view themselves as
working for the parent corporation. Most importantly, all of the products sold by the
Chattanooga division are obtained from Champion Window, and both the labor and
the materials on projects sold, installed, or constructed by Champion-Chattanooga are
backed by a fifteen-year warranty from Champion Window. Given this evidence, the
trial court erred in finding that any statements or representations to Ms. Edwards that
she was contracting for the goods and services of Champion Window could be
construed as false.
Nor does the evidence support the trial court’s finding that Champion
knowingly made a false representation “as to its work product.” As best we can tell
from the record, this finding resulted from Ms. Edwards’s assertion that, despite
advertising its products as being manufactured by Champion Window, the screen
doors on her porch were manufactured by a third-party, Falcon Door and Window
10 Company. 7 The actual sales materials allegedly relied on by Edwards in this regard
make the following statements: “Each [patio] room is built to match the design of your
home”; patio rooms and porch enclosures are “[d]esigned, manufactured, constructed,
and guaranteed by Champion”; “Champion patio rooms are manufactured in our own
factory”; and “Champion designs, manufactures, installs and guarantees your patio
room.”
The evidence presented at trial showed that the walls, roof, windows, and
screens used in the screened porch being constructed for Edwards were all
manufactured at one of three facilities owned by Champion Window, and the doors
were manufactured to Champion Window’s specifications. In light of this evidence,
we fail to see how the statements in the advertising material can be viewed as false.
The advertisement stated that Champion manufactured the actual parts of the room
itself; it says nothing about the doors. More importantly, assuming that the door could
be considered a component of the room, Edwards failed to show how any
misrepresentation regarding the door’s manufacturer was material – i.e., that she
would have received different or better doors if they had actually been manufactured
7 When questioned about this fact at trial, McKenna explained that Falcon manufactured the doors under contract with Champion Window, to Champion Window’s specifications.
11 by Champion, as opposed to being manufactured for Champion.8 See Greenwald v.
Odom, 314 Ga. App. 46, 55 (2) (723 SE2d 305) (2012) (“[a] fact is material if its
existence or nonexistence is a matter to which a reasonable man would attach
importance in determining his choice or action in the transaction in question”)
(citations and punctuation omitted).
Finally, regardless of Edwards’s proof regarding any arguably false statements
made by Champion, her rescission claim would still fail. This is so because she did
not present any evidence showing that she relied on these alleged misrepresentations
to her detriment. See Turner Outdoor Advertising, 185 Ga. App. at 816-817 (reversing
judgment in favor of defendant, which had prevailed on its counterclaim for
rescission, where defendant had failed to show it relied on the alleged
misrepresentations of the opposing party or that it had suffered damages as a result of
any such reliance). Here, we have carefully scrutinized all of Edwards’s testimony,
and she never stated that she would not have entered the contract had she known either
that she was contracting with a local division of Champion Window, rather than the
8 In this regard, we note that Edwards’s only complaint regarding the door had nothing to do with its quality. Rather, once Edwards asked for and received an itemized price list of the components of the project, she thought she was being charged too much for the doors and too much for the overall project.
12 parent company itself, or that the screen doors to be installed on the project were
manufactured for Champion, rather than by Champion. Accordingly, she failed to
show that she relied on any misrepresentations of Champion when she executed the
contract. See Young, 277 Ga. App. at 279 (3) (affirming a grant of summary judgment
against parties seeking rescission of a contract and noting that the allegedly defrauded
parties had presented no evidence showing how the alleged misrepresentation had
influenced their decision to proceed with the contract); Greenwald, 314 Ga. App. at
55-56 (2).
Moreover, assuming that Edwards’s testimony could be construed as showing
reliance, she failed to show how she was damaged by this reliance. See Robertson v.
Panlos, 208 Ga. 116, 119 (65 SE2d 400) (1951) (“[a]n essential element of an action
for rescission of a contract by reason of fraud is injury to the complaining party”).
Specifically, the evidence showed that Edwards received products that were
manufactured by Champion Window and that were constructed or installed by an
employee who had been trained by Champion Window, at the parent company’s
corporate facilities. Edwards also received a fifteen-year warranty from Champion
Window (the parent company) on all the labor and materials that went into her deck
and screened porch. Accordingly, Edwards failed to show how any product or benefit
13 she received would have been different had she contracted directly with Champion
Window, as opposed to Champion-Chattanooga. For this additional reason, therefore,
the trial court erred in finding that Edwards was entitled to rescind the contract. See
Tyson v. McPhail Properties, 223 Ga. App. 683, 687 (5) (478 SE2d 467) (1996)
(holding that a party could not prevail on its affirmative defense of rescission where
it offered no evidence as to how it was damaged by the alleged misrepresentations of
the other party).
2. The trial court found in favor of Edwards on her claim for negligent
construction and awarded her $1,500 in damages on this claim, based on the testimony
of Edwards’s expert witness that it would cost that amount to have the negligently
constructed project torn down and removed from Edwards’s property. Because the
trial court’s findings with respect to the negligent construction claim are unsupported
by either the evidence or the law, we also reverse this part of the trial court’s order.
We first note that as a matter of law, Edwards could not recover on both her
claim for rescission and her claim for negligent construction, because her claim for
negligent construction was based upon a contractual duty. See Fields Bros. Gen.
Contractors v. Ruecksties, 288 Ga. App. 674, 676-677 (1) (655 SE2d 282) (2007)
(“there is implied in every contract for work or services a duty to perform it skillfully,
14 carefully, diligently, and in a workmanlike manner”) (footnote omitted). And
rescission represents “a remedy in which neither party is held liable in damages for
breach of the contract,” because the contract is considered void. (Citations omitted.)
Martin v. Rollins, Inc., 238 Ga. 119, 120 (1) (231 SE2d 751) (1977). Accordingly, if
the contract was void, Edwards could not recover damages for its breach. Given that
we have found that Edwards failed to prove her claim for rescission, however, we
address the merits of her negligent construction claim.
In support of this claim, Edwards introduced the testimony of Vincent Morris,
who was qualified as an expert on the subject of deck construction. Morris testified
that he inspected the deck approximately two months after Champion had ceased work
on the project and found what he believed were six or seven “major violations” of the
“Georgia Building Code.” These alleged violations included a lack of footings in the
post holes; problems with the deck framing; problems with the length of the spans; the
installation of a single band of wood, as opposed to a double band, on the deck
perimeter; the lack of flashing between the deck and the house; and defects in the
construction of the stairs. On cross examination, however, Morris admitted that most,
if not all, of the problems he found could be corrected. He also acknowledged that the
project did not look finished to him, as there was still “quite a bit” to be done. Morris
15 further stated that in his experience as a contractor, he would expect a customer to tell
him if they saw problems with or were dissatisfied with a project, so that he could
correct any deficiencies. And he admitted that if a building inspector pointed out code
violations, a contractor would have no choice but to fix the project at its own expense,
so that it complied with the applicable building code.
When questioned about the alleged problems with the construction, Rick
Tragesser, the Champion Patio Room Manager who performed that construction,
stated that there were a number of corrections that would need to be made before the
project was considered completed. Champion was never given the opportunity to
complete the project, however, and therefore it could not remedy the admitted
deficiencies. Tragesser also testified that the project would not be considered complete
until approved by the building inspector, and if the building inspector found any code
violations, Champion would correct them. Similarly, McKenna testified that if
Champion was made aware of problems with its construction or if the customer was
dissatisfied with Champion’s work, the company would remedy the problems. McGill
echoed this sentiment, noting that Champion provided a 15-year warranty on both
materials and labor.
Based on this evidence, the trial court found that Champion was negligent in
constructing the project because “it violated applicable building codes” and its work
16 was “not performed in a workmanlike manner.” This finding, however, ignores the
fact that Edwards failed to prove her claim that Champion’s work violated applicable
building codes – i.e., that the company was negligent per se. Although Edwards’s
expert testified that Champion’s work violated the “Georgia Building Code” in several
ways, Edwards did not introduce any state, county, city or other building code into
evidence. Moreover, the expert did not identify any specific code sections (either by
name or number) as having been violated. Rather, he simply testified as to the various
defects in the project that he claimed did not meet “code requirements”. Given
Edwards’s failure to introduce either a copy of the applicable building code or identify
with specificity the sections of that code that Champion’s construction violated, she
also failed to prove her claim of negligence per se. See Norman v. Jones Lang Lasalle
Americas, 277 Ga. App. 621, 629 (2) (b) (627 SE2d 382) (2006) (affirming grant of
summary judgment in favor of defendant on plaintiff’s claims of negligence per se,
where plaintiff failed to offer in to evidence a copy of the applicable building code or
specify which sections of the code the defendant had violated); Spooner v. City of
Camilla, 256 Ga. App. 179, 184 (2) (b) (568 SE2d 109) (2002) (plaintiffs could not
prove their claim of negligence per se where they failed to identify any specific
statute, rule, or regulation allegedly violated by the defendants; the testimony of
17 plaintiffs’ expert that he knew such rule existed because he had read “various rules
and regulations” was hearsay and therefore lacked probative value).
Additionally, as a matter of law “[a] party to a contract can not cause a breach
or delay in compliance by the other, and then set up the breach or delay so caused as
freeing him from the contract.” Ray M. Wright v. Stinchcomb, 259 Ga. App. 212, 214
(576 S.E.2d 566) (2002) (citation and punctuation omitted). See also Georgia 20
Properties LLC v. Tanner, 255 Ga. App. 6, 10 (2) (564 SE2d 459) (2002) (“[a] party
cannot avoid the obligations of a contract by frustrating the performance of a
condition precedent”) (footnote omitted). Here, the evidence showed that all of the
alleged defects could have been remedied, a fact that even Edwards’s expert conceded.
Edwards, however, refused to allow Champion to complete the contract and therefore
deprived it of the opportunity to cure any alleged defects in its work. In other words,
Edwards’s contractual breach resulted in Champion’s alleged breach of its contractual
obligation to provide a product free of defective workmanship. Having caused this
alleged breach, Edwards could not thereafter seek to recover for it. See Allied
Enterprises v. Brooks, 93 Ga. App. 832, 834 (3) (93 SE2d 392) (1956) (“[w]here a
defendant prevents the performance of a stipulation of a contract undertaken by the
plaintiff, he is estopped from setting up in his own behalf any injury which may have
18 resulted from the nonperformance of such condition”) (citation and punctuation
omitted).
For the reasons set forth above, we reverse the order of the trial court granting
judgment in favor of Edwards on her claims for rescission and negligent construction.
Additionally, given that Edwards’s only defense to Champion’s breach of contract
claim was rescission, and given that she was not entitled to rescind the contract, we
further find that the trial court erred in failing to find in favor of Champion on its
breach of contract claim.9 Accordingly, we remand the case for entry of judgment in
favor of Champion and for a trial on the issue of damages.10
9 We do not address Edwards’s claim that Champion Window (the parent company) should have been named as a party to this action, either in lieu of or in addition to Champion-Chattanooga. “Issues and objections not raised in the trial court and ruled on by the trial court are deemed waived and cannot be raised for the first time on appeal.” (Footnote omitted.) West v. State, 300 Ga. App. 583, 585 (2) (685 SE2d 486) (2009). Thus, because Edwards did not raise this issue in the court below, she has waived this potential defense. HWA Properties v. Community & Southern Bank, 322 Ga. App. 877, 881 (1) (a) (746 SE2d 609) (2013) (in a suit to recover on a note and guaranty, defendants’ failure to raise any defense related to plaintiff’s status as a holder or nonholder in possession of the note and guaranty under the Commercial Code resulted in a waiver of that defense). 10 In this regard, we note that Champion is seeking to recover the balance of the contract price. However, the contract does not contain a liquidated damages provision, and the general measure of damages in a case such as this is the net profit to which the contractor would have been entitled had full performance of the contract been permitted. That figure is reached by
19 Judgment reversed and case remanded with direction. Phipps, C. J., and
Ellington, P. J., concur.
subtracting from the contract price the amount which full performance would have cost the contractor. If performance by either party had begun prior to the breach, adjustments must be made to ensure that the contractor receives the full amount of the profit, but no more. First, there must be added to the profit figure the amount of the contractor’s net loss up to the point of the breach. That figure is reached by subtracting from the expenses incurred by reason of the contractor’s performance the salvage or resale value of the material left on hand. The sum of those figures (the profit which would have been realized from full performance plus net loss incurred by performance to the date of breach) may in no event exceed the contract price. Second, there must be deducted from the recovery those amounts received by the contractor from the owner as prepayment or progress payment.
Williams v. Kerns, 153 Ga. App. 259, 266-267 (1) (265 SE2d 605) (1979). See also Dill v. Chastain, 234 Ga. App. 770, 771 (507 SE2d 872) (1998).