NOTICE 2026 IL App (5th) 241159-U NOTICE Decision filed 02/13/26. The This order was filed under text of this decision may be NO. 5-24-1159 Supreme Court Rule 23 and is changed or corrected prior to the filing of a Petition for not precedent except in the
Rehearing or the disposition of IN THE limited circumstances allowed the same. under Rule 23(e)(1). APPELLATE COURT OF ILLINOIS
FIFTH DISTRICT ______________________________________________________________________________
BOEHM ELECTRICAL CONTRACTORS, LLC, ) Appeal from the ) Circuit Court of Plaintiff-Appellant, ) Champaign County. ) v. ) No. 18-CH-61 ) EDWARD ROSE DEVELOPMENT COMPANY, LLC, ) Honorable ) Jason M. Bohm, Defendant-Appellee. ) Judge, presiding. ______________________________________________________________________________
JUSTICE SHOLAR delivered the judgment of the court. Justices Moore and McHaney concurred in the judgment. ∗
ORDER
¶1 Held: The trial court did not err by granting defendant’s motion for summary judgment. The trial court did not abuse its discretion by awarding attorney fees to defendant. Further, the trial court did not err by denying plaintiff’s motion to reconsider.
¶2 Plaintiff, Boehm Electrical Contractors, LLC (Boehm), appeals the Champaign County
circuit court’s order granting summary judgment in favor of defendant, Edward Rose Development
Company, LLC (Edward Rose), and the trial court’s award of attorney fees to defendant. Boehm
appeals, arguing there were genuine issues as to material facts, and therefore the court erred by
granting defendant’s motion for summary judgment. Boehm further argues the court abused its
* Justice Moore fully participated in the decision prior to his retirement. See Cirro Wrecking Co. v. Roppolo, 153 Ill. 2d (1992). 1 discretion in awarding attorney fees to Rose. For the reasons that follow, we affirm the judgment
of the circuit court.
¶3 I. BACKGROUND
¶4 In 2015, Rose oversaw the construction of several apartment buildings in Champaign. In
April 2015, Rose first contracted with Boehm to provide underground electrical services, electrical
wiring, and electrical fixtures for three buildings in construction project. Those buildings were
designated as Buildings 13, 16, and 17 (electrical contract). In October 2015, Rose contracted with
Boehm to install cable and telecommunications wiring for the same three buildings (cable
contract). The contracts contained the following paragraphs:
“5. Contractor shall commence work promptly when notified and shall work continuously until work is completed. *** 13. If, in Builder’s opinion, Contractor fails to perform substantially in accordance with this contract, or is responsible for substantial delays and fails within 48 hours of written notice to satisfy all unsatisfactory matters, Builder may terminate this contract for all buildings, or for any specific building(s), included in this contract. Builder may avail himself of any legal remedies available to secure satisfaction of this contract. If Contractor fails to perform in accordance with the terms of this contract, Contractor shall pay all costs, including, without limitation, attorney fees, administrative expenses and court costs incurred by Builder in enforcing the terms of this contract.”
¶5 The terms of the electrical contract called for Boehm to be paid approximately $390,000,
50% to be paid upon completion of the “rough in” work and 50% to be paid upon completion of
the “finishing” work. The terms of the cable contract called for Boehm to be paid a total of $31,008,
45% to be paid upon completion of the “rough in” work and 55% to be paid upon completion of
the “finishing” work.
¶6 On October 6, 2017, Rose sent Boehm a letter (48-hour notice). That letter referenced the
“ELECTRICAL CONTRACT, DATED 4/6/15” and the “CABLE TV AND TELEPHONE
WIRING CONTRACT, DATED 10/22/15.” The body of the letter read as follows:
2 “This letter will serve as your ‘48 Hour Written Notice” in accordance with paragraph #13 of the above captioned contracts. You are responsible for substantial delays.
We have given you schedules for both Buildings #16 & 17, requesting you meet them. You have failed to do so and continue to fall further behind. You are now required to have Building #17 finish plumbing completed in the first three corridors by October 30, 2017 and the second three corridors by November 24, 2017, along with final inspections.
We are hereby requiring you to honor paragraph #5 of your contracts, man the job properly, commence work promptly when notified and work continuously until the work is completed. If you fail to perform, we will terminate the contracts and hire others to complete the work, charging the cost thereof to your account.”
¶7 On December 22, 2017, Rose sent a letter to Boehm terminating the contracts. That letter
referenced the same contracts and stated the following, in pertinent part:
“The purpose of this letter correspondence is to terminate the above captioned contracts.
On October 6, 2017, we sent you a completion date of November 24, 2017 for Building #17, including final inspections. As of today, December 22, 2017, the building is still not complete. You have not properly managed or manned this job and we cannot continue to wait for you to complete the work remaining on Building #16.[ ]
Once work is complete at Building #17, you will need to submit an invoice to the Jobsite Superintendent to receive payment. We will hire others to complete the remaining work on Building #16.[ ]” (Bold in original.)
On January 23, 2018, Boehm appeared on the job and was denied entry to the jobsite.
¶8 Boehm filed mechanic’s liens for each contract and against the property. On March 7, 2018,
Boehm filed a complaint requesting foreclosure on both mechanic’s liens. The complaint also
contained two counts for breach of contract, one for each contract. On May 11, 2018, Edward Rose
filed an answer, affirmative defenses, and a counterclaim alleging Boehm had breached the
contracts by failing (1) to provide adequate labor and materials, (2) to work continuously, (3) to
3 meet job completion and project schedules, and (4) to provide sworn statements and lien waivers
as provided by the contracts.
¶9 Boehm filed a motion for summary judgment on March 16, 2022. It was supported by an
affidavit signed by Patrick A. Boehm. In addition to claiming the monies owed, it stated:
“8. That Edward Rose *** refused to allow Boehm *** to complete the work on the job and ejected Boehm *** from the project, preventing Boehm from doing any further work. *** 12. That all labor and materials that my company provided were of excellent quality and improved the property and further allowed Edward Rose *** to complete the development project.”
Documentation attached to the Boehm affidavit included copies of the contracts, paid invoices,
unpaid invoices, and the mechanic’s liens.
¶ 10 On April 5, 2022, Edward Rose filed a response to Boehm’s motion for summary judgment.
Attached was a counteraffidavit signed by Jim Vincent (Rose affidavit), a construction manager
for Edward Rose. The Rose affidavit alleged, in part, that:
“9. Boehm failed to provide adequate labor and materials to meet job completion schedules and caused significant delays to the Project. *** 11. Boehm’s performance failures were raised during monthly construction meetings, including during the time period of June 1, 2017 through February 1, 2018.”
The Rose affidavit also asserted that Edward Rose properly terminated the contracts after
providing Boehm with written notice, and that it had either paid or tendered payment to Boehm
for all amounts due based upon the work Boehm had completed on the project. Attached were
several exhibits, including copies of the weekly progress schedules, documents from the monthly
construction meetings, the October 6, 2017, 48-hour notice, and the December 22, 2017,
termination letter.
4 ¶ 11 On October 23, 2023, Edward Rose filed its own motion for summary judgment, arguing
that it was entitled to summary judgment against Boehm’s claims. Edward Rose contended that it
had complied with the contracts in question, the contracts were properly terminated, and that it had
paid or tendered all monies owed to Boehm. Edward Rose also argued that it was entitled to
summary judgment on its counterclaims, arguing that Boehm breached the contracts by failing to
provide adequate materials and labor, by failing to meet job completion schedules, and by
wrongfully filing liens against the property.
¶ 12 Two days later, on October 25, 2023, Boehm filed a reply in support of its own motion for
summary judgment. Boehm argued it had provided undisputed facts establishing its right to
recover unpaid costs for the value of services rendered and asked that the circuit court grant its
motion for summary judgment.
¶ 13 On November 27, 2023, Boehm filed a response to Edward Rose’s motion for summary
judgment, in which it argued “there are substantial questions of fact that must be addressed before
judgment can be entered for either party” and that Edward Rose was not entitled to judgment as a
matter of law. Attached to Boehm’s pleading was another affidavit from Patrick Boehm, dated
November 22, 2023. This affidavit asserted that Boehm had performed all the work on the property
“in a timely and workmanlike manner” and that Boehm “was not informed that its work was
delayed or behind schedule.” In the affidavit, Boehm also asserted that the 48-hour notice was
deficient since the letter also provided new work dates more than 48 hours beyond the October 6,
2017, date of the letter. Boehm also claimed that the 48-hour notice was insufficient because the
body of the letter referenced “plumbing” work, and that Boehm had not contracted with Edward
Rose to complete any plumbing work, only electrical work. Attached were numerous exhibits,
5 including Boehm’s first affidavit, that were previously filed as a part of Boehm’s motion for
summary judgment.
¶ 14 On December 11, 2023, Edward Rose filed a reply to Boehm’s response to its motion for
summary judgment, asserting that Boehm had failed to dispute the legal and factual grounds set
forth in its motion. Relying on Illinois Supreme Court Rule 191 (eff. Jan. 4, 2013), Edward Rose
argued that Boehm failed to substantively respond to its motion by (1) failing to indicate that it
was based on Boehm’s personal knowledge, (2) failing to attach documents other than those
previously submitted in support of Boehm’s motion for summary judgment, and (3) failing to “set
forth with particularity facts upon which the claim, counterclaim, or defense is based,” but instead
relying on “conclusions” instead of “facts admissible in evidence.” Edward Rose further argued
that (1) Boehm failed to dispute that it failed to satisfy contractual conditions required to receive
payment from Edward Rose, (2) Edward Rose properly terminated the contracts, (3) Edward Rose
paid or tendered payment for all completed work, and (4) Edward Rose was entitled to summary
judgment on its counterclaim because it is undisputed that Boehm breached the contracts.
¶ 15 On April 30, 2024, the trial court issued a written order denying Boehm’s motion for
summary judgment and granting Edward Rose’s motion for summary judgment. The court found
Boehm’s motion and supporting documentation lacking in substance, noting that the only support
for Boehm’s motion for summary judgment was “self-serving affidavits of Patrick Boehm.”
Accordingly, the court found the Boehm affidavits to be “insufficient to raise a genuine issue of
material fact and *** nothing more than *** bald claims that it did the work.” The court further
found that Boehm had breached the contracts by failing to complete its work in a timely fashion
and failed to cure that breach when given the opportunity to do so. The court also found that Boehm
breached the contract by failing to provide Edward Rose with the contractually required lien
6 waivers but instead chose to file the mechanic’s liens. The court found that Edward Rose “rightly
terminated the remaining contracts with Boehm Electrical.” Accordingly, the court found Boehm
did not have valid mechanic’s liens. Because the replacement contractor hired by Edward Rose
finished the work for less money than the contractual amount that would have been due to Boehm
under the contracts, the court declined to award damages to Edward Rose. Noting, however, that
the contracts allowed Edward Rose to recover attorney fees and court costs, the court gave Edward
Rose time to submit a petition for attorney fees and costs.
¶ 16 Edward Rose submitted a petition requesting $55,932.50 in attorney fees, representing
110.25 hours of work from several attorneys with an average hourly rate of $502.43 an hour. The
petition was supported by an affidavit from Jad Sheikali, Edward Rose’s lead attorney. Also
attached to the petition were several invoices issued from May 17, 2018, through January 17, 2024.
Edward Rose also asked the court to order Boehm to relinquish the mechanic’s liens. Boehm filed
a response to Edward Rose’s petition for attorney fees, arguing that they were overinflated and
unreasonable, and that many of the entries were too vague to warrant payment.
¶ 17 Following a hearing on July 3, 2024, the court entered a written order on July 9, 2024,
disallowing $10,291 in fees incurred before but not accounted for in the Rose affidavit. The order
awarded the $1,465 in fees mentioned in the Rose affidavit and $43,636.25 in fees incurred after
the Rose affidavit for a total award of $45,101.25 in attorney fees.
¶ 18 On August 8, 2024, Boehm filed a motion to reconsider asking the trial court to reverse its
decision granting Edward Rose’s motion for summary judgment and the size of the award of the
attorney fees. Citing the parties’ affidavits, Boehm argued there were genuine issues of material
fact and that the court erred, as a matter of law, in granting summary judgment in favor of Edward
Rose. Specifically, Boehm argued that although the Rose affidavit claimed that Boehm was
7 responsible for delays because it did not provide adequate labor and materials, and that Edward
Rose provided Boehm with a proper 48-hour notice, Boehm’s affidavit stated that the work was
timely completed in compliance with the contract and project schedules and in coordination with
other trades. Boehm also noted its affidavit contested whether the 48-hour notice was proper notice
since “the letter only complained that Boehm had fallen behind on ‘finish plumbing.’ ” According
to Boehm, these are genuine issues regarding material facts, and therefore summary judgment was
improper. Boehm also argued that by granting Edward Rose’s motion for summary judgment, the
court had weighed the credibility of the affidavits.
¶ 19 Edward Rose filed a response on September 13, 2024. Initially, Edward Rose argued that
Boehm did not dispute, in the parties’ summary judgment briefings, either of Edward Rose’s
allegations that Boehm failed to provide lien waivers or that Edward Rose terminated the contracts
upon at least 48 hours’ notice. Edward Rose also argued that Boehm’s affidavit failed to comply
with Illinois Supreme Court Rule 191 in that it contained conclusions without any documentary
evidence or factual support, while the Rose affidavit included hundreds of pages of documentation
supporting its representations, and that Boehm did not dispute the authenticity of the provided
documentation.
¶ 20 On September 27, 2024, Boehm filed a response, noting that Rule 191 did not require
supporting documentation unless the affiant has relied upon documents to support his contentions.
Boehm also reiterated its position that the competing affidavits created genuine issues of material
fact. Boehm further argued that the documentation filed in support of the Rose affidavit was
inadmissible hearsay due to a lack of foundation and therefore did not comply with Rule 191’s
requirement that documents relied upon by an affiant shall be sworn or certified copies of those
documents. Finally, Boehm also reiterated its argument that the 48-hour notice was defective in
8 that it referred to “finish plumbing” instead of the electrical work Boehm was contracted to
complete.
¶ 21 At the conclusion of the October 8, 2024, hearing on Boehm’s motion to reconsider, the
trial court noted that Boehm’s motion to reconsider improperly raised arguments not previously
submitted to the court. The court ruled:
“Contrary to the argument of Boehm Electrical, it doesn’t require me to make any credibility findings. I didn’t make any credibility findings. It is undisputed [Boehm] got notices that they were behind. It’s undisputed that [Boehm was] given more time than the contract allows. As I said in the written order that doesn’t undermine the notice, and there’s just no basis in my mind to find a genuine issue of material fact because one typographical error in the notice that says plumbing as opposed to electrical.”
The trial court denied Boehm’s motion to reconsider. On October 24, 2024, Boehm filed a timely
notice of appeal.
¶ 22 II. ANALYSIS
¶ 23 On appeal, Boehm alleges the trial court erred (1) by granting Edward Rose’s motion for
summary judgment, (2) by awarding attorney fees to Edward Rose, and (3) by denying its motion
to reconsider. Edward Rose contends the court properly found that Boehm failed to establish a
genuine issue of material fact and therefore properly granted summary judgment in its favor.
Edward Rose further maintains that its fees were reasonable and the award was proper, and that
the trial court properly denied Boehm’s motion to reconsider.
¶ 24 We first consider whether the trial court’s April 30, 2024, order properly granted summary
judgment in favor of Edward Rose. Boehm argues the court entered summary judgment despite
the record containing genuine issues of material fact that required the court to make a credibility
determination. Specifically, Boehm argues the parties’ competing affidavits raised the following
genuine issues of fact: (1) whether Boehm caused significant delays on the project, (2) whether
9 Edward Rose provided proper notice of its intent to terminate the contracts, and (3) whether
Edward Rose properly terminated the contracts.
¶ 25 “Our review of the circuit court’s grant of summary judgment is de novo.” State Farm
Insurance Co. v. American Service Insurance Co., 332 Ill. App. 3d 31, 36 (2002). “De novo
consideration means we perform the same analysis that a trial judge would perform.” Flores v.
Westmont Engineering Co., 2021 IL App (1st) 190379, ¶ 23.
¶ 26 “The purpose of summary judgment is not to try a question of fact, but simply to determine
whether a genuine issue of triable fact exists.” Sameer v. Butt, 343 Ill. App. 3d 78, 85 (2003). To
determine whether a genuine issue of material fact exists, “a court must construe the pleadings,
depositions, admissions and affidavits strictly against the movant and liberally in favor of the
opponent.” Id. “In situations where both parties file cross-motions for summary judgment, ‘they
agree that no material issue of fact exists and that only a question of law is involved.’ [Citation.]
Thus, ‘ “the court is invited to decide the issues presented as a question of law.” ’ [Citations.]”
State Farm Insurance Co., 332 Ill. App. 3d at 36. “However, ‘the mere filing of cross-motions for
summary judgment does not require that the court grant the requested relief to one of the parties
where genuine issues of fact exist precluding summary judgment in favor of either party.’ ” Id.
¶ 27 Motions for summary judgment can be filed with or without supporting affidavits. 735
ILCS 5/2-1005(b) (West 2022). If a supporting affidavit is utilized, the opposite party “may prior
to or at the time of the hearing on the motion file counteraffidavits.” Id. § 2-1005(c). The affidavits
must be in compliance as “provided by rule.” Id. § 2-1005(e). The form and the content of the
affidavits are provided in Illinois Supreme Court Rule 191. Id. § 2-1005(d); Ill. S. Ct. R. 191(a)
(eff. Jan. 4, 2013). Rule 191(a) provides, in pertinent part, that affidavits
“shall be made on the personal knowledge of the affiants; shall set forth with particularity the facts upon which the claim, counterclaim, or defense is based; shall
10 have attached thereto sworn or certified copies of all documents upon which the affiant relies; shall not consist of conclusions but of facts admissible in evidence; and shall affirmatively show that the affiant, if sworn as a witness, can testify competently thereto. If all of the facts to be shown are not within the personal knowledge of one person, two or more affidavits shall be used.” Ill. S. Ct. R. 191(a) (eff. Jan. 4, 2013).
As noted above, both parties filed affidavits and supporting documentation in support of their
respective positions.
¶ 28 Boehm’s position is that its affidavits raise facts that are in direct conflict with the Rose
affidavit, and these conflicts create a genuine issue of material fact. For example, Boehm notes
that while the Rose affidavit states that Boehm failed to provide adequate labor and materials
causing significant delays to the project, the Boehm affidavits state that Boehm completed all work
in a timely and workmanlike manner. As another example, Boehm points to the differences
between the parties’ affidavits: the Rose affidavit states that Boehm’s performance failures were
raised at monthly construction meetings as opposed to the Boehm affidavit which states that
Boehm was not informed that its work was behind schedule. Finally, Boehm contends that there
is a genuine issue as to whether the 48-hour notice provided Boehm was proper. The basis of this
argument is that language in the body of the letter itself refers to “plumbing” work and not to the
“electrical” work that Boehm was contracted to complete. According to Boehm, these conflicts
indicate genuine issues of material fact that preclude the entry of summary judgment in favor of
Edward Rose. We disagree.
¶ 29 In ruling on the cross-motions for summary judgment, the trial court noted the “paucity”
of Boehm’s briefs in this matter and characterized Boehm’s filings as “invitations for the Court to
fill in the blanks and do the legal work for Boehm Electrical.” The court concluded that “[t]he
Boehm affidavits are insufficient to raise a genuine issue of material fact and do nothing more that
make bald claims that it did the work.” Citing Farm Credit Bank of St. Louis v. Isringhausen, 210
11 Ill. App. 3d 724, 727 (1991), the court concluded that it “ ‘should ignore’ such personal
conclusions, opinions and self-serving statements.” We agree with the trial court’s assessment.
¶ 30 We acknowledge Boehm’s argument that more recent caselaw has noted that “ ‘the term
“self[-]serving” must not be used to denigrate perfectly admissible evidence through which a party
tries to present its side of the story at summary judgment.’ ” Garton v. Pfeifer, 2019 IL App (1st)
180872, ¶ 41 (quoting Hill v. Tangherlini, 724 F.3d 965, 967 (7th Cir. 2013)). At the same time,
we also note that Boehm cited Farm Credit Bank in the trial court in its “reply in support of motion
for summary judgment” when it asked the court to ignore “the self-serving statements, personal
conclusions, and opinions contained in Defendant’s Response in Opposition to Plaintiff’s Motion
for Summary [Judgment].” Boehm should hardly be heard to complain about the court using its
own arguments against it. Furthermore, considering the trial court’s order as a whole, it is apparent
that the trial court was concerned with the complete lack of substance found in Boehm’s filings
against Edward Rose’s motion for summary judgment, and again, we agree with the trial court’s
assessment.
¶ 31 While Boehm argues that the competing affidavits demonstrate genuine issues of material
fact, we disagree. For example, even disregarding the “self-serving” nature of Boehm’s assertion
that it completed the work in a timely manner, the problem is that Boehm’s assertion is merely a
conclusion unsupported by the record or documents attached to either affidavit. To the extent that
Boehm wants its assertion to be considered a “fact,” Boehm’s assertion is, at best, an attempt to
state a “conclusion of fact.” A conclusion of fact is “[a] factual deduction drawn from observed or
proven facts without resort to rules of law; an evidentiary inference.” (Emphasis added.) Black’s
Law Dictionary (12th ed. 2024). By contrast, the Rose affidavit stated that Boehm had fallen
behind schedule and was causing delays to the project, an assertion that was supported by business
12 records attached to the affidavit. These records include weekly progress schedules indicating the
“rough electrical” and “rough TV and phone” was behind schedule, and notes of monthly
construction meetings stating the same. The Rose affidavit correctly stated “conclusions of fact”
supported by other “observed or proven facts” contained in the supporting attachments.
¶ 32 An affidavit filed in support of a motion for summary judgment, or in opposition thereto,
“shall set forth with particularity the facts upon which the claim, counterclaim or defense is based”
and “shall not consist of conclusions but of facts admissible in evidence.” (Emphasis added.) Ill.
S. Ct. R. 191(a) (eff. Jan. 4, 2013). Boehm’s affidavits and documents neither set forth facts with
particularity nor consisted of anything other than conclusions. By contrast, the Rose affidavit and
its supporting documentation set forth the facts with particularity and supported its conclusions
with provable facts. Specifically, Edward Rose established that Boehm was behind schedule and
that the project was being delayed. We further note that paragraph 13 of the contracts in question
allow Edward Rose to terminate the contracts, after proper notice, if Edward Rose was of the
opinion that Boehm “fail[ed] to perform substantially in accordance with this contract, or [was]
responsible for substantial delays.” Based upon the record before this court, there is no genuine
issue as to a material fact as to Edward Rose’s opinion on this subject matter.
¶ 33 As noted, Boehm also argues that there is a genuine issue of material fact with regard to
whether Edward Rose provided Boehm with proper notice of its intent to terminate the contracts.
In support of its argument, Boehm argues that the 48-hour notice did not inform Boehm of the
“unsatisfactory matters” that needed to be satisfied. Boehm’s argument is based solely upon the
fact that the 48-hour notice informed Boehm that it was “required to have Building #17 finish
plumbing completed in the first three corridors by October 30, 2017 and the second three corridors
by November 24, 2017, along with final inspections.” (Emphasis added.) Boehm argues that it was
13 not hired to complete any plumbing on the project, and therefore a material fact exists as to whether
the 48-hour notice was adequate notice for its termination.
¶ 34 We disagree. Again, contrary to the mandate of Rule 191, Boehm’s second affidavit simply
states that Boehm “performed all work in compliance with contract and project schedules and in
coordination with other mechanical trades” and that Boehm “was not informed that its work was
delayed or behind schedule.” As before, Boehm’s statements are mere conclusions made in the
absence of supporting facts. Boehm offered no documentation that it was uncertain as to the terms
of the notice, or that it questioned Edward Rose with regard to any perceived confusion with the
notice. Further, we note that the letter itself references, at the outset and in all caps, the contracts
between the parties including the dates that were both signed. Simply stated, despite Boehm’s
assertion to the contrary, no genuine issue of material fact exists as to the subject matter of the 48-
hour notice, notwithstanding the use of word “plumbing” instead of “electrical.”
¶ 35 In the absence of supporting documentation or other facts admissible in evidence, as
required by Rule 191, Boehm’s affidavits consist of mere conclusions without supporting
evidence. The Rose affidavit and its supporting documentation provided uncontradicted facts
supporting the conclusion that (1) Boehm fell behind on its work and caused substantial delays to
the project, (2) Edward Rose provided Boehm with proper notice of its unsatisfactory performance
under the contracts, and (3) Edward Rose properly terminated the contracts. Contrary to Boehm’s
assertion, the circuit court’s ruling did not require the court to make a credibility determination.
Boehm had the opportunity to rebut Edward Rose’s claims with supporting evidence but failed to
do so. Accordingly, we agree with the court’s conclusion that “[t]he Boehm affidavits are
insufficient to raise a genuine issue of material fact and do nothing more than make bald claims
14 that it did the work.” For these reasons, we affirm the court’s decision to grant summary judgment
in favor of Edward Rose.
¶ 36 We next consider Boehm’s request that we reverse the circuit court’s order awarding
attorney fees of $45,101.25 to Edward Rose, or in the alternative, that we remand for further
proceedings. Boehm argues that Edward Rose failed to meet its burden of proving that its fees
were reasonable. Specifically, Boehm argues that a number of the “time detail” entries are
impermissibly vague under the standard set forth in Kaiser v. MEPC American Properties, Inc.,
164 Ill. App. 3d 978, 983 (1987), and that the invoices fail to identify the hourly rate charged by
each attorney, instead only providing an average hourly rate for all of the invoiced hours.
Consequently, Boehm contends that Edward Rose failed to provide any evidence regarding the
hourly rate charged by each attorney; the skill or standing of four of the seven attorneys who
worked on the file; “or the reasonableness of having seven professionals work on a simple
contract/mechanics lien case and the obvious overlap of work that results from having multiple
attorneys work on a single matter.”
¶ 37 “Generally, a party is responsible for his own attorney fees.” J.B. Esker & Sons, Inc. v. Cle-
Pa’s Partnership, 325 Ill. App. 3d 276, 281 (2001) (citing Abdul-Karim v. First Federal Savings
& Loan Ass’n of Champaign, 101 Ill. 2d 400, 412 (1984)). “An exception exists when the contract
provides for an award of attorney fees.” Id. (citing Mirar Development Inc. v. Kroner, 308 Ill. App.
3d 483, 488 (1999)). “[O]nly those fees which are reasonable will be allowed [citations], the
determination of which is left to the sound discretion of the trial court.” Kaiser, 164 Ill. App. 3d at
983. The party seeking the fees must present evidence sufficient for the court to determine the
reasonableness of the fees. Id. “The determination of reasonableness is a matter for the trial court’s
15 discretion.” J.B. Esker & Sons, Inc., 325 Ill. App. 3d at 283 (citing Mercado v. Calumet Federal
Savings & Loan Ass’n, 196 Ill. App. 3d 483, 493 (1990)).
¶ 38 “[T]he petition for fees must specify the services performed, by whom they were
performed, the time expended thereon and the hourly rate charged therefor.” Kaiser, 164 Ill. App.
3d at 984. “Because of the importance of these factors, it is incumbent upon the petitioner to
present detailed records maintained during the course of litigation containing facts and
computations upon which the charges are predicated.” Id. In determining the reasonableness of the
requested fees, the trial court should consider other various factors, including: (1) the skill and
standing of the attorney, (2) the nature of the case, (3) the novelty of the issues involved, (4) the
significance of the case, (5) the degree of responsibility required, (6) the customary charges for
comparable services, (7) the benefit to the client, and (8) the reasonable connection between the
fees sought and the amount involved in the litigation. J.B. Esker & Sons, Inc., 325 Ill. App. 3d at
283 (citing Mercado, 196 Ill. App. 3d at 493). “A trial court’s decision whether to award attorney
fees is a matter within its discretion and will not be disturbed absent an abuse of that discretion.”
(Internal quotation marks omitted.) McNiff v. Mazda Motor of America, Inc., 384 Ill. App. 3d 401,
404 (2008).
¶ 39 As noted above, a fee-shifting provision exists in the contracts here. Paragraph 13 of the
contracts provide that Edward Rose is entitled to recover “all costs, including, without limitation,
attorney fees, administrative expenses and court costs” based on Boehm’s breach of the contracts.
Edward Rose sought attorney fees of $55,392.50 for work completed during the pendency of the
case. Edward Rose supported its claim for fees with an affidavit from its lead attorney, Jad
Sheikali. Sheikali’s affidavit was in turn supported by invoices, and each invoice was likewise
supported by a “time detail” sheet that gave the date of the work, the name of the attorney
16 completing the legal work, the amount of time expended, and a brief description of the work
involved.
¶ 40 Regarding Boehm’s argument that Edward Rose failed to provide any evidence regarding
four of the seven attorneys who worked on the case, we note that those four attorneys all worked
on the case prior to the April 5, 2022, Rose affidavit. The Rose affidavit mentioned that the
company had paid attorney fees in excess of $1,465. In its petition for attorney fees, Edward Rose
requested payment of $11,755 in attorney fees for all legal work completed prior to the Rose
affidavit. The additional fees of $10,291 were disallowed by the trial court, obviating the need for
this court to consider Edward Rose’s failure to detail the skill and the standing of the four attorneys
who worked on the case prior to the Rose affidavit. The trial court did not abuse its discretion by
awarding Edward Rose the $1,465 in attorney fees incurred prior to April 5, 2022.
¶ 41 Three attorneys worked on the Edward Rose file after April 5, 2022. For this work, Edward
Rose requested payment of $43,636.25 in attorney fees. The Sheikali affidavit stated that all three
of these attorneys were partners in the Honigman LLP law firm, explaining to some extent the skill
and the standing of the attorneys employed. Insofar as the hourly rate for each attorney involved
during this time frame is concerned, Boehm correctly asserts that Edward Rose failed to specify
an hourly rate for each attorney. We acknowledge that it would have been easier for this court if
Sheikali had specified the hourly rate for each of the attorneys involved in the case after April 5,
2022. We note, however, that the hourly rate for each attorney can be readily ascertained by
looking at the “time detail” documents and applying basic math.
¶ 42 Regarding other factors listed in J.B. Esker & Sons, Inc., Boehm argues that the evidence
provided below supports a finding that the attorney fees claimed were unreasonable. Boehm
specifically argues that this case was “an uncomplicated contract dispute with a mechanics lien
17 claim,” and that Edward Rose “failed to identify any facet of this case which made it more complex
or difficult to litigate.” We note that the Sheikali affidavit explained the work completed on the
case as invoiced from April 13, 2022, through January 17, 2024, as follows:
“(i) drafting a response to Boehm’s motion for summary judgment; (ii) conducting legal research in support of a response to Boehm’s motion for summary judgment; (iii) reviewing and compiling hundreds of documents submitted in support of a response to Boehm’s motion for summary judgment; (iv) preparing a detailed affidavit in support of a response to Boehm’s motion for summary judgment; (v) drafting a response to Boehm’s motion to dismiss Edward Rose’s affirmative defenses; (vi) drafting Edward Rose’s cross-motion for summary judgment; (vii) drafting a reply in support of Edward Rose’s cross-motion for summary judgment; (viii) analyzing Boehm’s reply in support of it[s] motion for summary judgment; (ix) conferring with Boehm’s counsel regarding then-pending motions and potential resolution of the litigation; and (x) conferences between Edward Rose and its outside counsel at Honigman LLP regarding then-pending motions, legal strategy, and potential resolution of the litigation.”
As noted above, Sheikali’s affidavit was supported by invoices and “time detail” documents.
¶ 43 Boehm also insists that several of the entries on the “time detail” documents are
impermissibly vague and therefore fail to support its claim for fees for those times. We note that
of the 14.5 hours’ worth of time entries that Boehm claims are vague, 3 hours reflect time that
Honigman LLP billed Edward Rose for work done prior to the Rose affidavit. As noted above, the
trial court denied the vast majority of Edward Rose’s request for attorney fees during that part of
the litigation.
¶ 44 In support of its argument that some of the time entries are impermissibly vague, Boehm
relies on the Kaiser court’s statement that “to justify a fee, more must be presented than a mere
compilation of hours multiplied by a fixed hourly rate or bills issued to the client [citation], since
this type of data, without more, does not provide the court with sufficient information” as to the
reasonableness of the fees. Kaiser, 164 Ill. App. 3d at 984. Part of the problem with Boehm’s
reliance on Kaiser is the standard of review. In Kaiser, the defendant was appealing the trial court’s
18 denial of its request for attorney fees. Id. at 983. We note that the Kaiser court found that the trial
court did not abuse its discretion denying the defendant’s request, noting that many of the time
entries contained inadequate descriptions, such as “file review,” “status,” “telephone calls” (some
identifying the person called, others not), “conferences” (again, some identifying the conference
participants, others not), etc. Id. at 986. By contrast, in this case, the trial court necessarily found
that the time entries submitted by Edward Rose in support of its request for attorney fees were
adequate. Our review of the time entries as a whole supports the conclusion that the trial court did
not abuse its discretion in granting the fees requested, notwithstanding that a handful of the entries
lack the detail contained in other entries.
¶ 45 Next, Boehm maintains that the attorney fees were unreasonable when measured against
the benefits resulting to Edward Rose as a result of the litigation. Boehm argues that the benefits
to Edward Rose were limited in that the trial court declined to award Edward Rose expectation
damages since its costs in having another electrician finish the work was less than what it would
have paid under the contract and that Edward Rose did not demonstrate additional costs due to any
delay. Boehm concludes that, “Even though the trial court entered judgment in [Edward Rose]’s
favor, the benefits produced by its attorneys was limited because there was no affirmative recovery
on the most significant issue of its counterclaim.”
¶ 46 We disagree with Boehm’s characterization regarding the benefits Edward Rose received
from its attorneys. As noted by the trial court in its order granting Edward Rose’s motion for
summary judgment, “Worse, Boehm Electrical could have been paid in full for its work had it
simply provided the contractually obligated lien waivers for the work. Instead it initiated this
lawsuit.” We note that Boehm filed mechanic’s liens against the property. It is clear that this was
a multi-million dollar project involving several apartment buildings. It is also clear that Boehm
19 violated the contracts at issue and improperly filed mechanic’s liens against the property. While
the trial court may not have awarded expectation damages to Edward Rose, it granted Edward
Rose the very thing it was requesting from Boehm at the outset: that its property be free and clear
of mechanic’s liens. For the foregoing reasons, we cannot conclude that the trial court abused its
discretion in granting Edward Rose attorney fees in the amount of $45,101.25.
¶ 47 Finally, Boehm contends that the trial court erred in denying its motion to reconsider its
decision to grant summary judgment in favor of Edward Rose and granting Edward Rose’s petition
for attorney fees. Boehm’s motion to reconsider and its supporting memorandum echoed its
arguments that the competing affidavits in this matter created genuine issues of material fact, and
that the trial court “misapplied existing law by deciding genuine issues of material fact on summary
judgment and making credibility determinations.”
¶ 48 The purpose of a motion to reconsider is to alert the court to newly discovered evidence,
changes in the law, or errors in the court’s application of previously existing law. Nissan Motor
Acceptance Corp. v. Abbas Holding I, Inc., 2012 IL App (1st) 111296, ¶ 16. Generally, a trial
court’s decision to grant or deny a motion for reconsideration lies within its discretion and will not
be reversed absent an abuse of that discretion. General Motors Acceptance Corp. v. Stoval, 374
Ill. App. 3d 1064, 1078 (2007). However, where the motion was based solely on the trial court’s
application or purported application of existing law, rather than on new facts or legal theories not
presented at trial, a court of review will apply a de novo standard of review. Nissan Motor
Acceptance Corp., 2012 IL App (1st) 111296, ¶ 16.
¶ 49 As discussed above, the trial court did not misapply the law by making a credibility
determination. Boehm tries to support its argument to the contrary by noting that the trial court’s
written order granting Edward Rose’s motion for summary judgment cited to the Rose affidavit 15
20 times. A review of the court order shows that the court was citing to the affidavit and facts found
in its supporting documents. As noted, Boehm did not provide any evidence to dispute these facts
other than its own conclusory statements, and this was not enough to create genuine issues of
material facts. Under a de novo review, we find that the trial court did not err in denying Boehm’s
motion to reconsider.
¶ 50 Boehm also argues, in its reply brief filed with this court, that Exhibits D (weekly progress
schedules) and E (monthly construction meeting documents) attached to the Rose affidavit violate
Rule 191 in that the documents are not sworn or certified copies of the business records and
therefore “lack foundation and are inadmissible hearsay.” We note that the first time Boehm
complained about Exhibits D and E in the trial court were in its response to Rose’s memorandum
in opposition to Boehm’s motion to reconsider. If Boehm wanted the trial court to consider this
argument, it should have raised it earlier in the proceedings. Instead, Boehm waited not only until
after it lost Edward Rose’s motion for summary judgment or even in its motion to reconsider but
waited until it filed a reply to Edward Rose’s memorandum in opposition to Boehm’s motion to
reconsider. This was the first time Boehm advanced this new legal argument. In ruling on Boehm’s
motion to reconsider, the trial court found it “interesting that *** Boehm Electrical now makes
arguments that they didn’t make the first time.”
¶ 51 A motion for reconsideration “is not the place to raise a new legal theory or factual
argument.” Liceaga v. Baez, 2019 IL App (1st) 181170, ¶ 25. “As a result, legal theories and
factual arguments not previously made are subject to waiver.” Id. Since Boehm was then
advancing a new legal theory that would have prevented the court from granting Edward Rose’s
motion for summary judgment, we review this argument under an abuse of discretion standard.
Nissan Motor Acceptance Corp., 2012 IL App (1st) 111296, ¶ 16. We note that the Rose affidavit
21 states that the affiant, Jim Vincent, “could competently testify to the facts stated herein based upon
my own personal knowledge and the business records of Edward Rose.” The Rose affidavit further
asserted that Exhibits D and E were “true and accurate” copies of the weekly progress schedules
and the monthly construction meetings, respectively. Under these circumstances, we will not find
that the trial court abused its discretion by denying Boehm’s motion to reconsider based upon an
argument that it did not advance in its opposition to Edward Rose’s motion for summary judgment
or even in its written motion for reconsideration.
¶ 52 For the foregoing reasons, we conclude that the trial court did not err by granting Edward
Rose’s motion for summary judgment or in its granting of attorney fees to Edward Rose. Further,
the trial court did not err by denying the motion to reconsider.
¶ 53 III. CONCLUSION
¶ 54 For these reasons, the judgment of the Champaign County circuit court is affirmed.
¶ 55 Affirmed.