48 CFR § 252.219-7011

48 CFR · Federal Acquisition Regulations System

§ 252.219-7011 — Notification to delay performance.

TitleTitle 48: Federal Acquisition Regulations System PartPart 252: Solicitation Provisions and Contract Clauses

SourceeCFR (current through Apr 2, 2026)

This text of 48 C.F.R. § 252.219-7011 (Notification to delay performance.) is published on Counsel Stack Legal Research, covering United States primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook

48 C.F.R. § 252.219-7011 (2026).

Text

252.219-7011 Notification to delay performance.
As prescribed in 219.811-3 (3), use the following clause:

Notification To Delay Performance (JUN 1998)

The Contractor shall not begin performance under this purchase order until 2 working days have passed from the date of its receipt. Unless the Contractor receives notification from the Small Business Administration that it is ineligible for this 8(a) award, or otherwise receives instructions from the Contracting Officer, performance under this purchase order may begin on the third working day following receipt of the purchase order. If a determination of ineligibility is issued within the 2-day period, the purchase order shall be considered canceled.

(End of clause)

[63 FR 33588, June 19, 1998]

Free access — add to your briefcase to read the full text and ask questions with AI

252.219-7011 Notification to delay performance.

As prescribed in 219.811-3 (3), use the following clause:

Notification To Delay Performance (JUN 1998)
The Contractor shall not begin performance under this purchase order until 2 working days have passed from the date of its receipt. Unless the Contractor receives notification from the Small Business Administration that it is ineligible for this 8(a) award, or otherwise receives instructions from the Contracting Officer, performance under this purchase order may begin on the third working day following receipt of the purchase order. If a determination of ineligibility is issued within the 2-day period, the purchase order shall be considered canceled.

(End of clause) [63 FR 33588, June 19, 1998]