Texas Statutes
§ 315.095 — SUSPENSION OF WORK.
Texas § 315.095
JurisdictionTexas
Code TNTransportation Code
This text of Texas § 315.095 (SUSPENSION OF WORK.) is published on Counsel Stack Legal Research, covering Texas primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.
Bluebook
Tex. Transportation Code Code Ann. § 315.095 (2026).
Text
Sec. 315.095. SUSPENSION OF WORK. When suit is brought under Section 315.092 , the municipality or the contractor may suspend performance of work until a final judgment is rendered in the case and all appellate remedies are exhausted.
Free access — add to your briefcase to read the full text and ask questions with AI
Legislative History
Acts 1995, 74th Leg., ch. 165, Sec. 1, eff. Sept. 1, 1995.
Nearby Sections
15
§ 315.001
DEFINITIONS.§ 315.002
APPLICABILITY.§ 315.022
CONTENTS OF PETITION.§ 315.023
PLANS AND SPECIFICATIONS.§ 315.024
OWNERSHIP AND CONTROL.§ 315.025
USE OF AVAILABLE MONEY.§ 315.041
ADVERTISEMENT FOR BID.§ 315.042
FILING OF BID.§ 315.043
AMENDMENT OF BID PROHIBITED.§ 315.045
CONTRACTS.§ 315.061
AUTHORITY TO ASSESS COSTS.§ 315.062
METHOD OF ASSESSMENT.§ 315.063
ADJUSTMENT OF EQUITIES.Cite This Page — Counsel Stack
Bluebook (online)
Texas § 315.095, Counsel Stack Legal Research, https://law.counselstack.com/statute/tx/TN/315.095.