Texas § 315.094 AFFIDAVIT.

Texas Statutes

§ 315.094 — AFFIDAVIT.

Texas § 315.094

Code TNTransportation Code

This text of Texas § 315.094 (AFFIDAVIT.) is published on Counsel Stack Legal Research, covering Texas primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook

Tex. Transportation Code Code Ann. § 315.094 (2026).

Text

Sec. 315.094. AFFIDAVIT.

(a)In a suit brought under Section 315.092 , an affidavit must be attached to the plaintiff's petition stating:

(1)that the matters alleged in the petition are true, except for matters alleged on information and belief; and

(2)that the suit is brought in good faith and not to injure or delay the municipality, the contractor, or an owner of abutting property.

(b)If the plaintiff does not attach the affidavit required by this section, the court shall dismiss the suit on a defendant's motion and the plaintiff is barred to the same extent as if suit had not been brought.

Free access — add to your briefcase to read the full text and ask questions with AI

Sec. 315.094. AFFIDAVIT. (a) In a suit brought under Section 315.092 , an affidavit must be attached to the plaintiff's petition stating:
(1) that the matters alleged in the petition are true, except for matters alleged on information and belief; and
(2) that the suit is brought in good faith and not to injure or delay the municipality, the contractor, or an owner of abutting property.
(b) If the plaintiff does not attach the affidavit required by this section, the court shall dismiss the suit on a defendant's motion and the plaintiff is barred to the same extent as if suit had not been brought.