Arizona § 41-2617 Contracts for procurement of construction; delay; recovery of damages by contractor

Arizona Statutes

§ 41-2617 — Contracts for procurement of construction; delay; recovery of damages by contractor

Arizona § 41-2617

Title 41Arizona Revised Statutes

Ch. 23ARIZONA PROCUREMENT CODE

Art. 9Legal and Contractual Remedies

This text of Arizona § 41-2617 (Contracts for procurement of construction; delay; recovery of damages by contractor) is published on Counsel Stack Legal Research, covering Arizona primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook

Ariz. Rev. Stat. Ann. § 41-2617 (2026).

Text

A contract for the procurement of construction shall include a provision which provides for negotiations between the state governmental unit and the contractor for the recovery of damages related to expenses incurred by the contractor for a delay for which the state governmental unit is responsible, which is unreasonable under the circumstances and which was not within the contemplation of the parties to the contract.  This section shall not be construed to void any provision in the contract which requires notice of delays, provides for arbitration or other procedure for settlement or provides for liquidated damages.

Free access — add to your briefcase to read the full text and ask questions with AI

A contract for the procurement of construction shall include a provision which provides for negotiations between the state governmental unit and the contractor for the recovery of damages related to expenses incurred by the contractor for a delay for which the state governmental unit is responsible, which is unreasonable under the circumstances and which was not within the contemplation of the parties to the contract. This section shall not be construed to void any provision in the contract which requires notice of delays, provides for arbitration or other procedure for settlement or provides for liquidated damages.