WPI Decisionkey v. Volvo Truck Parts CV-97-467-JD 02/23/99 UNITED STATES DISTRICT COURT FOR THE DISTRICT OF NEW HAMPSHIRE
WPI Decisionkey, Inc.
v. Civil No. 97-467-JD
Volvo Truck Parts Corp.
O R D E R
The plaintiff, WPI DecisionKey, Inc. ("WPI"), brings this
action against the defendant, Volvo Truck Parts Corporation
("Volvo"), asserting claims for breach of contract, breach of
covenant of good faith, and unjust enrichment. On December 23,
1997, Volvo filed its answer in which it asserted counterclaims
of breach of contract, breach of covenant of good faith, and
unjust enrichment. Before the court is Volvo's motion for
summary judgment on all claims (document no. 13).
Background
In late 1994 or early 1995, Volvo decided to develop a
"global software solution" known as IMPACT that would assist
mechanics servicing its trucks. The IMPACT project consisted of
a number of sub-projects that each addressed different components
of the final product. One component was the development of a
Service Information Database ("SID") which stored information
about Volvo trucks. This was to be developed by a Volvo affiliate, Volvo Data. A second component was the development of
a "method" authoring tool and a "diagnostic" authoring tool. The
method authoring tool was to enable technical writers to write
repair procedures using information stored in SID, while the
diagnostic authoring tool was to enable the technical writers to
write diagnostic procedures using information stored in SID.
From late 1994 through November 1995, Volvo and WPI
discussed the possibility of WPI providing the method and
diagnostic tools to Volvo. This culminated in a November 1995
WPI proposal to develop the tools, which Volvo accepted.
WPI was to customize its standard software product, IDEA, by
integrating IDEA with data structures and databases specific to
Volvo. WPI representatives traveled to Sweden to meet with Volvo
representatives and identify Volvo's reguirements for the method
and diagnostic tools. Although no formal agreement was executed,
Volvo and WPI jointly developed specifications for the customized
IDEA project and WPI began customizing IDEA in March 1996.
The parties entered a formal agreement in June 1996,
controlling the transaction. The agreement provided a schedule
pursuant to which WPI was to deliver various stages of the final
product. Volvo in turn had to supply necessary information
regarding SID, among other things, to WPI so that WPI could
design the tools appropriately. The contract provided that if
2 the final product was not delivered and accepted by Volvo by
January 7, 1997, Volvo could terminate the contract and seek a
refund of its expenditures. There were clauses establishing
payment schedules and requiring any modification of the
specifications to be in writing and accepted by the parties.
At the time the agreement was signed both parties were
already experiencing difficulties. At WPI development proceeded
more slowly than expected. Moreover, WPI experienced changes in
management and personnel. In assuming responsibility for the
Volvo project, the new WPI personnel began to realize the extent
of WPI's commitments and re-evaluate its ability to meet them
within budget and on time. Volvo was also flagging. The
development of SID and the provision of information necessary for
WPI to meet its obligations had fallen behind schedule.
The parties therefore included in the June 1996 agreement an
addendum that modified the schedule in the body of the contract
by adding one month to each of the original dates. Moreover, the
addendum modified the work that WPI was to perform. Rather than
developing a system that integrated with SID, WPI was to develop
a stand alone system.
Difficulties in meeting obligations persisted. In response
to a September 27, 1996, letter from WPI seeking to modify the
schedule and establish a release date for certain phases in
3 November and December, 1996, Volvo asserted that WPI was in
material breach. Throughout October the parties negotiated,
culminating in an apparent agreement in late October or early
November on a new schedule that identified various "deliverables"
and the dates on which they were to be delivered. WPI sent Volvo
a letter identifying the project schedule and deliverables, and
Volvo responded by providing its schedule and deliverables,
stating that they hoped it did not differ from WPI's but that
discussions would follow. The new schedule provided that the
final product was to be delivered by May 1, 1997. Internal
memoranda of WPI indicate that WPI identified incongruities
between its expectations and Volvo's.
The parties proceeded to perform under the altered time
frames. However, in a January 30, 1997, letter, WPI indicated to
Volvo that there was additional work to be done beyond the
original scope of the agreement and that this would take
additional time and money. Volvo responded that there was
nothing new beyond the original scope of the project. After
reviewing its records, WPI found past documents that included
those features WPI had thought were new and constituted
additional work. In a February 7, 1997, letter, WPI wrote Volvo
acknowledging the fact that the contested features were included
in earlier specifications. However, WPI asserted that in
4 November the parties had restarted the project and had come to a
similar level of understanding regarding the work to be done,
which did not include the contested features.
On February 26, 1997, WPI sent a letter to Volvo proposing a
solution that would address the contested features, stating that
"numerous additional items would not make the May deliverable"
and that there was "too much work to do and [WPI'] list of
enhancements seems to grow by the week." La Liberte Aff. Ex. 42.
"Should Volvo wish to accelerate the schedule for these items, we
would need to add contract programmers to the project and would
propose charging Volvo our cost for these additional resources."
Id. On March 27, 1997, Volvo asserted that WPI was in material
breach of the contract and terminated the agreement.
On September 18, 1997, WPI filed this action asserting
breach of contract, breach of covenant of good faith, and unjust
enrichment. Volvo answered and similarly asserted counterclaims
of breach of contract, breach of covenant of good faith and
unjust enrichment. In this motion Volvo seeks summary judgment
on WPI's claims because WPI allegedly repudiated the contract.
Volvo also seeks summary judgment on its claims asserting that it
is entitled to reimbursement of all money paid by Volvo to WPI
pursuant to the contract, as well as to attorney fees.
5 Discussion
The role of summary judgment is "to pierce the boilerplate
of the pleadings and assay the parties' proof in order to
determine whether trial is actually reguired." Snow v.
Harnischfeger Corp., 12 F.3d 1154, 1157 (1st Cir. 1993) (guoting
Wynne v. Tufts Univ. Sch. of Med., 976 F.2d 791, 794 (1st Cir.
1992)). The court may only grant a motion for summary judgment
where the "pleadings, depositions, answers to interrogatories,
and admissions on file, together with the affidavits, if any,
show that there is no genuine issue as to any material fact and
that the moving party is entitled to a judgment as a matter of
law." Fed. R. Civ. P. 56(c). The party seeking summary judgment
bears the initial burden of establishing the lack of a genuine
issue of material fact. See Celotex Corp. v. Catrett, 477 U.S.
317, 323 (1986); Quintero de Quintero v. Aponte-Rogue, 974 F.2d
226, 227-28 (1st Cir. 1992). The court must view the entire
record in the light most favorable to the nonmovant, "'indulging
all reasonable inferences in that party's favor.'" Mesnick v.
General Elec. Co., 950 F.2d 816, 822 (1st Cir. 1991) (guoting
Griqqs-Rvan v. Smith, 904 F.2d 112, 115 (1st Cir. 1990)) .
However, once the defendant has submitted a properly supported
motion for summary judgment, the plaintiff "may not rest upon
mere allegation or denials of his [its] pleading, but must set
6 forth specific facts showing that there is a genuine issue for
trial." Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 256
(1986) (citing Fed. R. Civ. P. 56(e)).
As a preliminary issue, WPI asserts that Volvo is barred
from asserting anticipatory repudiation in support of summary
judgment because it is an affirmative defense and Volvo failed to
assert it in its answer. See Fed. R. Civ. P. 8(c). Volvo
contests the characterization of anticipatory repudiation as an
affirmative defense. It also asserts that its answer
sufficiently raised the defense and that in any event WPI had
notice of it and suffered no prejudice given Volvo's answer and
counterclaims.
"Generally speaking, failure to plead an affirmative defense
results in a waiver of the defense and the exclusion of all
evidence relevant to it." Conjugal Partnership Comprised of
Joseph Jones and Venetta Jones v. Conjugal Partnership Comprised
of Arthur Pineda and Joni Pineda, 22 F.3d 391, 400 (1st Cir.
1994). This rule is intended to ensure that the opposing party
has "notice of the defense and a chance to develop evidence and
offer arguments to controvert the defense." Wolf v. Reliance
Standard Life Ins. Co., 71 F.3d 444, 449 (1st Cir. 1995). Given
the purpose behind the 'raise or waive rule,' the First Circuit
has held that "'[w]hen there is no prejudice and when fairness
7 dictates, the strictures of [the raise or waive] rule may be
relaxed.'" Jones v. Pineda, 22 F.3d 391, 400 (quoting Jakobsen v.
Massachusetts Port Authority, 520 F.2d 810, 813 (1st Cir. 1975)).
As specifically pertinent to this case, where there is no
prejudice, courts have allowed parties to raise affirmative
defenses for the first time in post-answer motions. See Sanders
v. Department of the Army, 981 F.2d 990, 991 (8th Cir. 1992)
(affirmative defense raised in motion to dismiss allowed and
formality of amended complaint unnecessary); Grant v. Preferred
Research, Inc., 885 F.2d 795, 797 (11th Cir. 1989) (no prejudice
where plaintiff received notice of affirmative defense in summary
judgment motion); Rivera v. Anaya, 726 F.2d 564, 566 (9th Cir.
1984); Devito v. Pension Plan of Local 819 I.B.T. Pension Fund,
975 F. Supp. 258, 263 (S.D.N.Y. 1997) ("numerous courts have held
that '[a]bsent prejudice to the plaintiff, a defendant may raise
an affirmative defense [such as statute of limitations] in a
motion for summary judgment for the first time.'") (quotations
and citations omitted) (citing cases) .
The court assumes for the purposes of this discussion that
anticipatory repudiation is an affirmative defense under Federal
Rule of Civil Procedure 8 (c). WPI has not asserted that it would
be prejudiced by Volvo's late assertion of anticipatory
repudiation. Nor under the circumstances of this case would prejudice seem likely. In its anticipatory repudiation defense,
Volvo alleges that WPI clearly and unequivocally stated it would
not deliver the specified software on time. Similarly, in its
counterclaim Volvo asserted WPI had breached its agreement by
attempting to change the specifications of the software and
failing to comply with delivery dates.1 Given the congruent
allegations underlying Volvo's counterclaim and its anticipatory
repudiation defense, the element of surprise in this case is
minimal. WPI had fair notice of Volvo's general assertions and
an opportunity to conduct discovery on them. This is evidenced
by WPI's well documented opposition to Volvo's motion for summary
judgment. In light this, and of WPI's failure to allege
prejudice, fairness dictates that Volvo be allowed to raise the
defense at this time.
Specifically, in its answer, Volvo counterclaims that "WPI breached the contract by, inter alia, failing to deliver any of the software phases on time, attempting to change the specifications of the software, and completely failing to deliver several of the software phases." Volvo Answer at 11. Volvo further states that it "has been excused from performance by reasons of WPI's acts or conduct." Id. Volvo asserts as its tenth defense "[b]y its acts and conduct, the plaintiff has waived any rights it may have against the defendant . . . ." Volvo Answer at 9. I. Anticipatory Repudiation
Volvo asserts that it was entitled to terminate the contract
because WPI committed an anticipatory repudiation. Volvo bases
its defense of anticipatory repudiation on two letters sent by
Bradford Wild, the president of WPI, to Volvo on February 7,
1997, and February 26, 1997, as well as internal WPI memoranda.
Volvo asserts that in WPI's February correspondence Wild clearly
and unequivocally stated that WPI would not honor its obligations
under the contract. WPI asserts that a genuine issue of material
fact exists as to whether the parties modified their agreement,
replacing the specifications initially included in the June
agreement with other specifications and altering delivery dates.
WPI also asserts that the statements at issue were not
sufficiently unequivocal, definite statements of repudiation, but
were instead offers to compromise.
New Hampshire law provides that in certain circumstances a
party aggrieved by another party's repudiation of a contract not
yet fully performed may resort to any remedy for breach. See New
Hampshire Rev. Stat. Ann. ("RSA") § 382-A:2-6102. The official
comment to section 610 provides that "anticipatory repudiation
centers upon an overt communication of intention or an action
2Neither party disputes the applicability of New Hampshire's version of the UCC, and given their mutual reliance on it, both have implicitly acknowledged it controls the instant case.
10 which renders performance impossible or demonstrates a clear
determination not to continue with performance." RSA § 382-A:2-
610 comment 1. "[A] statement of intention not to perform except
on conditions which go beyond the contract" is a repudiation.
Id., comment 2. To constitute anticipatory repudiation, courts
have required statements to be clear, positive, and unequivocal.3
See Wallace Real Estate Inv. Inc. v. Groves, 881 P.2d 1010, 1019
(Wash. 1994) (en banc); Flat & Sons Co. v. Schupf, 649 N.E.2d
990, 993 (111. A p p . C t . 1995). Whether a party has indeed
anticipatorily repudiated a contract is a question of fact. See
Grace v. Insurance Co. of North America, 944 P.2d 460, 467
(Alaska 1997) (reversing and remanding summary judgment order
"for a factual determination whether INA in fact anticipatorily
repudiated its contractual obligations"); Alaska Pacific Trading
Co. v. Eaaon Forest Products Inc., 933 P.2d 417, 522 (Wash. C t .
App. 1997) ("[T]he question of anticipatory repudiation is one of
fact. . . . This issue, too, may only be decided on summary
judgment if, taking all evidence in the light most favorable to
3Although the New Hampshire Supreme Court has not had the opportunity to address the statutory provisions for anticipatory repudiation, in section 610 New Hampshire has followed the Uniform Commercial Code's provisions regarding anticipatory repudiation of contracts. See RSA § 382-A:2-610 ("RSA"). The court therefore finds other states' treatment of their analogous versions of the UCC provision regarding anticipatory repudiation to be persuasive.
11 the non-moving party, reasonable minds can reach only one
conclusion."); Flat & Sons Co. v. Schupf, 649 N.E.2d 990, 993
(111. App. C t . 1995) ("Whether an anticipatory repudiation
occurred is a question of fact . . . ."); Jones v. Solomon, 428
S.E.2d 637, 639 (Ga. C t . App. 1993) ("It is a question for the
trier of fact as to whether any action of one party is sufficient
to constitute a repudiation of the contract and amount to an
anticipatory breach.").
The correspondence in which Volvo asserts WPI repudiated its
agreement employs language such as " [m]y current position is
. . . ," " [w]e must get together and discuss this topic in more
detail and " [w] e believe this work can be accomplished
but is beyond the scope of the current project." Tule Aff., Ex.
40 at 1, 3. WPI requests Volvo's "guidance as to replanning or
setting of priorities on additional work items." Id. at 3.
Wild's letter of February 26, 1997, speaks in terms of a
proposal. See Tule Aff. Ex. 42 ("I am prepared to offer a
proposal . . . .") .4 On the other hand. Wild states that certain
specifications would:
require additional YEARS - not months. The current
4Because there must have been an overt communication by WPI to Volvo establishing WPI's intention not to perform, Volvo's reliance on WPI's internal memorandum in this case is unwarranted.
12 DecisionKey/Volvo contractors and personnel cannot deliver these additional works items . . . .
Tule Aff., Ex. 42. He also stated that WPI's current position
was that it "could not commit to include [certain features] in
the current schedule." Tule Aff. Ex. 40 at 1.
The language employed, such as use of the term proposal,
implies a desire to negotiate. In contrast, WPI's statement that
it would take years to develop certain features might in some
circumstances strongly suggest repudiation. However, the facts
of this case undermine their significance in the summary judgment
context because the terms that the parties were operating under
are unclear on this record.
WPI and Volvo entered a formal agreement in June 1996, that
established specifications and delivery dates and governed the
parties' mutual obligations. After a conflict in which Volvo
asserted WPI was in material breach, WPI and Volvo appeared to
reach a compromise agreement. In an October 30, 1996, letter to
Volvo, WPI set out a new "scope of work and schedule of
deliverables for the remainder of the project through May 1,
1997." La Liberte Aff. Ex. W. Volvo responded sending WPI a
list of its expectations on deliverables and dates:
13 We have discussed the proposed delivery plan and made our notes and interpretations of what we expect in each delivery. Please take a look at Volvo's expectations. I hope that they do not differ from what is planned from WPI. We can discuss them in detail next Monday.
Id. Ex. X. Although internal WPI memoranda indicate that WPI was
aware of certain discrepancies, the discussions that followed are
not in the record and the parties then proceeded to operate under
the apparently modified agreement. Indeed, in Volvo's final
termination letter of March 27, 1997, Volvo referred to their
agreement setting specifications and delivery dates "as modified
in May and October 1996." La Liberte Aff. Ex. HH.
Courts have concluded that whether parties have modified a
contract is a guestion of fact. Zemco Mfg. Co. v. Pecoraro, 703
N.E.2d 1064, 1071 (Ind. App. C t . 1998) ("Questions regarding the
modification of a contract are ones of fact, and are to be
determined by the trier of fact upon the evidence of the case.");
Kiwanis Club v. de Kalafe, __ So.2d __ , 1998 WL 712705, *2 (Fla.
Dis. C t . App. 1998) ("Whether a written contract has been
modified by subseguent oral agreement or by course of dealing is
a guestion of fact for the jury."); ALCA Const. Co., Inc. v.
Waterburv Housing Auth., 713 A.2d 886, 890 (Conn. App. C t . 1997)
("'Whether the parties to a contract intended to modify the
contract is a guestion of fact.'") (guoting Newman & Partners v.
CFC Constr. Ltd., 674 A.2d 1313 (1996)); Mavville v. Peerless
14 Ins. C o ., 141 N.H. 317, 320 (1996); Park Square Auto Station v.
American Locomotive Co., 79 N.H. 497 (1920). On the record
before the court, reasonable people could find that the parties
modified the original June 1996 agreement on or about October or
November 1996. On this record it is unclear what the terms of
the modified agreement, if modified, are.
The court concludes that genuine issues of material fact
exist as to whether the parties modified the original agreement,
thereby altering the specifications and delivery dates, and as to
whether WPI anticipatorily breached its agreement with Volvo.
The court therefore denies Volvo's motions for summary judgment
on WPI's claims.
The court finds Volvo's reliance on Government of Republic
of China v. Compass Communication, 473 F. Supp. 1306 (D.C. 1979)
unpersuasive. Among other things, the court in Compass
specifically stated that the defendant had failed "to produce
evidence of a writing signed by plaintiff extending the time for
performance." Id. at 130 9. Here there is evidence that the
parties may have modified the contract.
II. Reimbursement
Volvo asserts that it has a contractual right to
reimbursement of funds paid to WPI. Volvo bases the assertion
15 upon section 3.2 of the original June 1996 agreement, titled
"Completion Date." La Liberte Aff. Ex. K at 4. Specifically,
Volvo relies upon the following language:
If the System has not been deemed accepted by Customer in accordance with Section 4 by January 7th, 1997, Customer, at its sole option and at any time prior to the System being accepted, may demand return of all payments made to Developer . . . .
Id. This was modified once in addendum D of the original
agreement, extending the date by one month and altering the
deliverable. See id. Addendum D. As discussed above, a genuine
issue of material fact exists as to whether the parties modified
the contract, extending delivery dates and the scope of work. A
reasonable inference is that such a modification might also
change the agreed upon completion date and affect this clause as
well. As such, Volvo's motion for summary judgment on this
ground is denied as well.
Conclusion
In light of the above discussion, Volvo's motion for summary
judgment is denied, as is its reguest for a hearing on the
summary judgment motion (document no. 13).
Based on what the court has learned of this case to date, it
is the opinion of the court that the parties would be well
advised to engage in some form of alternative dispute resolution
16 prior to trial. Therefore, the court directs counsel to explore
the matter and file a status report with the court by March 12,
1999.
SO ORDERED.
Joseph A. DiClerico, Jr. District Judge
February 23, 1999
cc: Thomas J. Donovan, Esquire John C. LaLiberte, Esquire