Tommy Hilfiger v. N. Conway Outlets CV-99-147-B 2/14/00
UNITED STATE DISTRICT COURT FOR THE DISTRICT OF NEW HAMPSHIRE
Tommy Hilfiger Retail. Inc,
v. Civil No. 99-C-147-B Opinion No. 2000 DNH 03S North Conway Outlets LLC
MEMORANDUM AND ORDER
Tommy Hilfiger Retail, Inc. ("Hilfiger") entered into a
long-term commercial lease with North Conway Outlets ("NCO") , a
developer that planned to build a retail outlet shopping center
in North Conway, New Hampshire. NCO failed to complete
construction of the shopping center by the deadline specified in
the lease. The issue presented by this declaratory judgment
action is whether NCO is entitled to invoke a clause in the lease
excusing any delay in completing construction caused by
"governmental restrictions."
I. BACKGROUND On January 16, 1997, after a period of negotiation, Hilfiger
and NCO entered into a seven year commercial lease for retail
- 2 - space in a shopping center NCO planned to build in North Conway,
New Hampshire. See Aff. of Steven R. Gursky, Esq. I 2
[hereinafter Gursky Aff.]; Aff. of Jordan D. Warshaw 5 2
[hereinafter Warshaw Aff.]. Under Section 6.2 of the lease, NCO
agreed that
construction of the demised premises to the extent required of [NCO] shall be substantially completed by not later than twelve (12) months following October 1, 1997 unless [NCO's] failure so to complete is caused by governmental restrictions, strikes, walkouts, shortages of material or labor, act of God, enemy actions, civil commotion, fire or casualty, or any other causes beyond the reasonable control of [NC01, in which event the aforesaid date shall be extended for such period as [NCO] is so prevented from completing such construction. If such substantial completion has not been achieved by the aforesaid date, as extended as aforesaid, [Hilfiger] and [NCO] shall have the right to terminate this lease by giving written notice of such termination to the other within thirty (30) days thereafter.
Gursky Aff. Ex. A § 6.2 (emphasis added).
On March 20, 1997, the Conway Planning Board ("Planning
Board") granted final site plan approval for NCO's project.
See Warshaw Aff. SI 4. Mountain Valley Mall Associates ("MVMA") ,
a shopping mall located across the street from NCO's proposed
- 3 - development, appealed the Planning Board's grant of final
approval to both the Conway Zoning Board of Adjustment ("ZBA")
and the New Hampshire Superior Court. See id. 5 5 3, 5, 6. The
ZBA refused to hear the matter and MVMA appealed the ZBA's
decision to superior court. See id. I I S , 6. The Superior
Court affirmed both the Planning Board's grant of final site plan
approval and the ZBA's refusal to consider MVMA's appeal. See
id. I 7.1 MVMA then appealed both decisions. The New Hampshire
Supreme Court affirmed both decisions on February 3, 2000. See
id. 5 8.
NCO did not begin construction of the planned shopping
center by the October 1, 1998 substantial completion date
specified in the lease. Shortly after the deadline expired,
Hilfiger notified NCO that it had breached the lease and that
1 The Superior Court dismissed MVMA's ZBA appeal because MVMA's "planning board claims [had] already been adjudicated and [its] ZBA appeal was not preserved through proper exhaustion of administrative remedies." Mountain Valley Mall Assocs. v. Municipality of Conway and Conway Zoning Bd. of Adjustment, N o . 97-E-125, slip op. at 6 (N.H. Super. C t ., Carroll County Feb. 11, 1998) .
- 4 - Hilfiger was exercising its right to terminate. See id. Ex. C.
NCO responded by claiming that it could not build the shopping
center because MVMA had appealed the land use approvals NCO
needed to begin construction. See id. Ex. D. NCO argued,
therefore, that the time for completing construction was extended
because its inability to build was due to a cause beyond its
reasonable control. See id. It has since also argued that its
inability to meet the substantial completion deadline must be
excused because its inability to build was the result of
governmental restrictions. Hilfiger commenced this declaratory
judgment action to resolve the dispute. It now seeks summary
judgment.
II. STANDARD OF REVIEW
Summary judgment is appropriate if the record, viewed in the
light most favorable to the non-moving party, shows that no
genuine issues of material fact exist and that the moving party
is entitled to judgment as a matter of law. See Fed R. Civ. P.
- 5 - 56(c); Commercial Union Ins. Co. v. Walbrook Ins. Co., 7 F.3d
1047, 1050 (1st Cir. 1993). A material fact is one "that might
affect the outcome of the suit under the governing law."
Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 248 (1986). A
genuine factual issue exists if "the evidence is such that a
reasonable jury could return a verdict for the nonmoving party."
Id.
Summary judgment is appropriate to resolve a question of
contract interpretation "only if the meaning of the language is
clear," in light of the surrounding circumstances and the
undisputed evidence of the parties' intent. See Rodriquez-Abreu
v. Chase Manhattan Bank, N.A., 986 F.2d 580, 586 (1st Cir. 1993)
(noting that there must be "no genuine issue as to the inferences
which might reasonably be drawn from the language"). A dispute
over the proper interpretation of the pertinent contract
provision does not necessarily give rise to a "genuine issue."
See Boston Five Cents Sav. Bank v. Secretary of Dep't of Hous.
and Urban Dev., 768 F.2d 5, 8 (1st Cir. 1985) . If the words of
- 6 - the contract are so clear that "reasonable people could not
differ over their meaning," the contract language is unambiguous
and the court decides the issue of proper interpretation. Id.;
see also United States Liab. Ins. Co. v. Selman, 70 F.3d 684, 687
(1st Cir. 1995). To prevail under these circumstances, the
moving party must demonstrate that its interpretation of the
unambiguous language is correct. See Allen v. Adage, Inc., 967
F .2d 695, 701 n. 5 (1st Cir. 1992).
- 7 - In contrast, summary judgment generally is inappropriate if
the meaning of contract language is ambiguous and the extrinsic
evidence bearing on the meaning of the ambiguous language is
contested. See id. at 698 n. 3. In such circumstances, summary
judgment is appropriate only if the extrinsic evidence of the
parties' "intended meaning is so one-sided that no reasonable
person could decide to the contrary." Bank v. International Bus.
Machs. Corp., 145 F.3d 420, 424 (1st Cir. 1998) (internal
quotation marks and citations omitted); Allen, 967 F.2d at 698
(same).
Applying the summary judgment standard in the context of the
present case, Hilfiger will not be entitled to judgment if the
contract language plausibly could be construed to excuse NCO's
non-performance and the extrinsic evidence bearing on the issue
would permit this construction.
Ill. DISCUSSION
Hilfiger presents two arguments to support its summary judgment motion. First, it challenges NCO's assertion that
MVMA's appeals prevented it from completing construction by the
- 9 - date specified in the lease. Second, it argues that the pendency
of an appeal challenging a necessary land use approval cannot
excuse NCO's nonperformance. I address each contention in turn.
A. Did MVMA's Appeals Preclude NCO From Building?
Hilfiger cites the fact that NCO obtained a building permit
from the Town of Conway to support its argument that MVMA's
challenges to the site plan approval did not prevent NCO from
commencing construction. I reject this argument because it is
inconsistent with New Hampshire law.
Once the superior court granted certiorari and accepted
MVMA's appeal of the final site plan approval, the approval was
automatically stayed by operation of New Hampshire law.2 See
N.H. Rev. Stat. Ann. § 677:15 ("the allowance of the order shall
stay proceedings upon the decision appealed from"). Moreover,
MVMA's timely appeal of the superior court's ruling upholding the
2 Unlike an appeal of an adverse planning board decision, an appeal challenging an adverse ruling by a ZBA does not automatically stay the ZBA's decision. See N.H. Rev. Stat. Ann. § 677:9. Accordingly, I focus my analysis on the effect of MVMA's appeal of the final site plan approval.
- 10 - approval stayed the entry of final judgment while the appeal was
pending. See Super. C t . R. 74 (1999); Rollins v. Rollins, 122
N.H. 6 , 9 (1982) ("Superior Court Rule 74 provides that a decree does not go to final judgment if a timely appeal is taken to this
court"). No evidence has been presented to suggest that NCO
obtained relief from this automatic stay. Accordingly, New
Hampshire law prevented NCO from acting on the final site plan
approval while the appeal was pending. The building permit on
which Hilfiger relies, therefore, was not lawfully issued and it
could not entitle NCO to commence construction while the appeal
of the site plan approval was pending.
B. Can Section 6.2 Reasonably Be Interpreted to Excuse NCO?
Because I conclude that New Hampshire law prevented NCO from
beginning construction by the substantial completion date
specified in the lease, I must address the second question
presented by Hilfiger's motion for summary judgment: whether
Section 6.2 of the parties' lease can reasonably be interpreted
to excuse NCO's delay in performance due to the suspension of the
- 11 - grant of site plan approval. To resolve this question, I first
consider the relevant New Hampshire precedents governing contract
interpretation. I then apply these precedents to the language of
Section 6.2.
1. Rules of Contract Interpretation
A lease is a type of contract and should be interpreted
according to the standard rules of contract interpretation. See
Hampton Beach Casino, Inc. v. Town of Hampton, 140 N.H. 785, 788,
674 A.2d 979, 981 (1996); Echo Consulting Servs., Inc. v. North
Conway Bank, 140 N.H. 566, 569, 669 A.2d 227, 230 (1995). As
with any contract, the proper interpretation of a lease
ultimately presents a question of law for the court to decide.
The court's objective must be to give the contract the
interpretation which best reflects its reasonable meaning and the
parties' intention when they executed the contract. See
Alexander v. Blackstone Realty Assocs., 141 N.H. 366, 368-69, 684
A.2d 60, 62 (1996); Gamble v. University Svs. of New Hampshire,
136 N.H. 9, 13, 610 A.2d 357, 360 (1992); Woodstock Soapstone Co.
- 12 - v. Carleton, 133 N.H. 809, 815, 585 A.3d 312, 315 (1991);
Restaurant Operators, Inc. v. Jennev, 128 N.H. 708, 710, 519 A.2d
256, 258 (1986). The first step in this process is determining
whether the disputed lease term is ambiguous. The court resolves
this threshold issue as a matter of law. See Bank, 145 F.3d at
424; Echo Consulting Servs., 140 N.H. at 569, 669 A.2d at 230.
- 13 - Contract language is ambiguous if "parties to the contract
reasonably disagree as to the meaning of that language."
Woodstock Soapstone Co., 133 N.H. at 815, 585 A.2d at 315
(citations omitted); see also Bank, 145 F.3d at 424. Ambiguity
does not exist simply because the parties, "each favoring an
interpretation contrary to the other's," dispute the proper
meaning of contract language. Bank, 145 F.3d at 424 (internal
quotation marks and citation omitted). "If only one inter
pretation is reasonable, the contract is deemed unambiguous."
URI Cogeneration Partners, L.P. v. Board of Governors For Higher
Educ., 915 F. Supp. 1267, 1281 (D.R.I. 1996) (citing W.P. Assocs.
v. Forcier, 637 A.2d 353, 356 (R.I. 1994)).
If the contract is unambiguous, then "the intent of the
parties to a lease is to be determined from the plain meaning of
the language used." Echo Consulting Servs., 140 N.H. at 569, 669
A.2d at 230; see also Anderson v. Century Prods. Co., 943 F.
Supp. 137, 152 (D.N.H. 1996). In gleaning the parties' intent
from the plain meaning of the lease language, the entire lease
- 14 - must be examined and its terms must be given "the standard
meaning as understood by reasonable people." Echo Consulting
- 15 - Servs., Inc., 140 N.H. at 569, 669 A.2d at 230. In addition, it
is necessary to "consider the situation of the parties at the
time of their agreement and the object that was intended
thereby." Hampton Beach Casino, Inc., 140 N.H. at 789, 674 A.2d
at 981 (citing Appeal of Dell, 140 N.H. 484, 488, 668 A.2d 1024,
1029 (1995)); Butler v. Walker Power, Inc., 137 N.H. 432, 435,
629 A.2d 91, 93 (1993) .
In contrast, if a contract is deemed ambiguous, then
surrounding circumstances and extrinsic evidence are considered
to determine the parties' intent. See Rodriquez-Abreu, 986 F.2d
at 586; Anderson, 943 F. Supp. at 152.
2. Interpreting Section 6.2 According to the __________ Rules of Contract Interpretation
Hilfiger argues that the automatic stay of the final site
plan approval required by New Hampshire law does not excuse NCO's
nonperformance because it is neither a governmental restriction
nor a cause beyond reasonable control.
According to Hilfiger, the term "governmental restrictions"
refers to governmental action that is both unforeseeable and
- 16 - temporary in duration. It asserts that this term is intended to
- 17 - include only something like a "a temporary construction
moratorium to prevent excessive electrical use during a heat
wave, or . . . some analogous action of a temporary and
unforeseeable nature." PI.'s Mem. of Law in Supp. of Its Mot.
for Summ. J. at 6 (doc. no. 14). A suspension of a final site
plan approval resulting from an abutter's challenge to the
approval is not a governmental restriction, so Hilfiger argues,
because such a challenge is foreseeable, given that abutters have
standing to appeal Planning Board decisions.
Assuming without deciding that Hilfiger has proffered a
plausible construction of the term "governmental restrictions" it
interpretation is by no means the only plausible construction. A
commonly accepted dictionary definition of "restriction" is
"something that restricts; a restrictive condition or regulation;
limitation." Random House Unabridged Dictionary 1642 (2d ed.
1993). To "restrict" means "to confine or keep within limits, as
of space, action, choice, intensity, or quantity." Id. A
governmental restriction, therefore, reasonably can be understood
- 18 - as any limitation on action, or restrictive condition, imposed by
the government that prevents NCO from completing construction.
- 19 - The context in which the term is used in the lease gives no hint
that the parties intended a more restrictive interpretation.
Hilfiger argues, however, that the only reasonable way to
construe the governmental restrictions term is to limit it to
unforeseeable governmental restrictions. To support its
position, Hilfiger cites the District of Rhode Island's decision
in URI Cogeneration Partners, L.P. v. Board of Governors., 915 F.
Supp. 1267 (D.R.I. 1996) .
In URI Cogeneration Partners, L.P.,3 the plaintiff, UCP,
planned to build and operate a power plant on the property of its
customer, the defendant, the University of Rhode Island ("URI").
Even before the parties executed their agreement, they were aware
that UCP might need to obtain zoning approval for the project in
order to obtain necessary financing. Although the URI did not
believe that it was subject to the zoning jurisdiction of the
community in which its campus was located, the parties' agreement
gave UCP the discretion to decide whether it would pursue zoning
3 For purposes of this discussion, I present a simplified version of the facts.
- 20 - approval. See URI Cogeneration Partners, L.P., 915 F. Supp. at
- 21 - 1273-74. An exhibit to the agreement, which was incorporated
therein, stated that UCP needed to obtain zoning approval as a
prerequisite to obtaining financing. See id. at 1277. UCP opted
to seek zoning approval, but the local board "tarried over the
matter for the next two years." Id. Due to this delay, UCP
failed to achieve certain milestones by the dates established in
the parties' agreement. As a result, URI terminated the
agreement. See id. at 1278.
UCP argued that its delay in performance was excused by a
"catchall" provision in the agreement's force maieure clause.
See id. at 1276, 1286 ("'causes beyond the reasonble control of
and without the fault or negligence of the party claiming Force
Majeure.'"). The court rejected this argument. In doing so, it
noted that a "catchall" provision in a force majeure clause is
limited to "things of the same kind of nature as the particular
matter [sic] mentioned." Id. at 1287 (quoting Kel Kim Corp., 519
N.E. 2d at 296-97). Since the clause at issue did not
specifically list the failure to obtain governmental approvals as
- 22 - an excusable condition and all of the specific conditions listed
in the clause were unforeseeable, the court reasoned that the
- 23 - catchall clause should similarly be limited to unforeseeable
events. See id. Accordingly, the court reasoned that UCP could
not invoke the catchall clause because the denial of zoning
approval was foreseeable when the parties entered into the
agreement. See id.
Because the force maieure clause did not expressly allocate
the risk of a failure to obtain the zoning approval, the court
fell back on the common law rule of risk allocation. "Under the
common law, 'if governmental approval is required for a party's
performance, the party may be taken to assume the risk that
approval will be denied if there is no provision excusing the
party in that event.'" Id. at 1287(quoting 2 E. Allan Farnsworth,
Farnsworth on Contracts § 9.6 (1990)). Accordingly, the court
concluded that UCP, which voluntarily assumed the obligation of
securing zoning approval, bore the risk that such approval would
be denied. As a result, its delay in performing its obligations
under the contract was not excused. See id. at 1288.
Although relevant and instructive, URI Cogeneration
- 24 - Partners, L.P. is distinguishable and therefore does not dictate
the result in this case. Here, "governmental restrictions" is
- 25 - specifically listed "among the parade of horribles triggering"
Section 6.2's application. See id. at 1287. Further, in the
absence of contract language or extrinsic evidence suggesting
that a more limited meaning was intended, a stay of a necessary
approval that automatically goes into effect by operation of law
when an appeal is taken is a limitation on NCO's ability to build
that reasonably can be viewed as a governmental restriction. As
a result, the lease arguably allocates the risk of delay due to
an automatic stay of a necessary approval to Hilfiger rather than
NCO. Under these circumstances, the common law rule allocating
the risk of a failure to obtain a necessary approval to the party
seeking the approval is irrelevant.4
IV. CONCLUSION
Because NCO has not filed a cross-motion for summary
4 Because I conclude that NCO's inability to complete construction by the deadline specified in the lease plausibly could be understood as a governmental restriction excusing its failure to meet the substantial completion deadline, I need not also consider whether it could also qualify as a cause beyond NCO's reasonable control.
- 26 - judgment. I reserve judgment on the precise meaning of the
- 27 - language in Section 6.2 of the lease. For the foregoing reasons,
however, I deny Hilfiger's motion for summary judgment (doc. no.
14) .
SO ORDERED.
Paul Barbadoro Chief Judge February , 2000
cc: Stephen Grill, Esq. John LaLiberte, Esq.
- 28 -