8 IN THE UNITED STATES DISTRICT COURT 9 FOR THE WESTERN DISTRICT OF WASHINGTON AT SEATTLE 10
12 PUGET SOUNDKEEPER ALLIANCE, Case No. C12-1201RSM 13 Plaintiff, 14 ORDER GRANTING MOTION TO 15 v. ENFORCE CONSENT DECREE 16 SEATTLE IRON & METALS CORP., 17 Defendant. 18
19 20 This matter comes before the Court on Plaintiff Puget Soundkeeper Alliance 21 (“Soundkeeper”)’s Motion to Enforce Consent Decree, Dkt. #89. 22 In this case, Soundkeeper alleged that Seattle Iron & Metals Corporation, (“SIMC”) 23 24 violated various provisions of Clean Water Act (“CWA”) permits that authorized stormwater 25 and industrial wastewater discharges from SIMC’s facilities in Seattle’s Georgetown 26 neighborhood used for vehicle and scrap metal recycling and storage. Dkt. #38. Relevant to 27 28 this Motion, Soundkeeper alleged that SIMC’s scrap handling activities emit dust and harmful 29 particles into the air that contaminate the neighborhood and Duwamish River in violation of the 30 CWA and Resource Conservation and Recovery Act (“RCRA”). Id. at 55, 104-108, and 134. ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 1 1 The parties settled the case via a Consent Decree, which the Court entered on March 3, 2 2019. Dkts. #82 and #84. SIMC agreed to install wind fencing to contain dust emissions by 3 mid-2019. Dkt. #84 at 6. Additional technical analysis revealed that “replacing one set of wind 4 5 fences with an enclosure for the trommel equipment to control dust closer to its source,” would 6 be more effective. Dkt. #86 at 2. The parties therefore filed a proposed Amended Consent 7 Decree with the Court on September 10, 2020, replacing the dust fence requirement with a 8 9 requirement to enclose the trommel equipment, amending the installation schedule, and 10 requiring additional penalty payments, including stipulated daily penalties if the new deadline 11 for the trommel enclosure was not met. Id. at 2, Dkt. #86-2 at 5. The terms and conditions of 12 13 the original Consent Decree were to remain in full force and effect except as specifically 14 amended. Relevant to the instant Motion, the Amended Decree stated: 15 Within 21 weeks of the City of Seattle’s issuance of the 16 building permit for the trommel enclosure, SIMC shall install 17 the permitted trommel enclosure. In the event that SIMC fails to install the trommel enclosure within 21 weeks of permit 18 issuance, SIMC shall pay stipulated penalties of $1,000 per day 19 until the trommel enclosure is installed.
20 Dkt. #88 at 5. Earlier, the Amended Decree states that SIMC completed “design drawings and 21 City of Seattle permit applications for wind fences and a trommel enclosure that meet the 22 23 requirements of this section and are approved by Dr. Ranajit Sahu, the parties’ joint consultant.” 24 Id. at 4. The Court entered the Amended Decree on October 30, 2020. Dkt. #88. 25 The original Consent Decree contained a force majeure clause allowing delays “outside 26 27 the reasonable control of SIMC,” including those caused by the actions or inactions of third 28 parties. See Dkt. #84 at 11–12. “In such event, the time for performance of the task will be 29 extended for a reasonable period of time following the force majeure event.” Id. at 12. 30 ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 2 1 Paragraph 11 provides that a prevailing party should be awarded its costs, including attorneys’ 2 fees, in any proceedings to enforce the Consent Decree. Id. at 12. 3 The City of Seattle approved SIMC’s trommel enclosure construction permit on March 4 5 26, 2021, and while SIMC anticipated the permit would issue in April, the City did not issue the 6 permit until July 22, 2021. Dkt. #90 (“Kinn Decl.”), ¶¶ 5-6, Ex. A. The deadline for SIMC to 7 install the trommel enclosure was therefore December 16, 2021. 8 9 There were delays. Although the trommel’s metal structure was built, the mesh material 10 that actually performs the dust containment was not immediately installed. The parties agree 11 that this was not finished until March 3, 2022, 77 days after the deadline. Dkt. #91 at 4; Dkt. 12 13 #94 at 7. SIMC has refused to pay the $1,000 per day penalty. 14 Soundkeeper now moves the Court to find SIMC in civil contempt of the Amended 15 Consent Decree and for the Court to order SIMC to pay stipulated penalties, interest, and 16 17 Soundkeeper’s attorneys’ fees and costs in bringing this motion. 18 Clean Water Act consent decrees are judgments which may be enforced by judicial 19 sanctions in a civil contempt proceeding. Las Vegas v. Clark Cty., 755 F.2d 697, 701 (9th Cir. 20 21 1984); Nw. Envtl. Def. Ctr. v. H&H Welding, No. 3:13-cv-00653-AC, 2015 U.S. Dist. LEXIS 22 162182, at *43 (D. Or. Oct. 13, 2015); see also Nehmer v. U.S. Dept. of Veterans Affairs, 494 23 F.3d 846, 860 (9th Cir. 2007) (“It is well established that the district court has the inherent 24 25 authority to enforce compliance with a consent decree that it has entered in an order, to hold 26 parties in contempt for violating the terms therein.”). To justify civil contempt, the moving 27 party must prove by clear and convincing evidence that the nonmoving party violated a court 28 29 order. Ahearn ex rel. N.L.R.B. v. Int’l Longshore & Warehouse Union, Locals 21 & 4, 721 F.3d 30 1122, 1129 (9th Cir. 2013). ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 3 1 “Substantial compliance” may provide a defense to an action for civil contempt. Gen. 2 Signal Corp. v. Donallco, Inc., 787 F.2d 1376, 1380 (9th Cir. 1986). However, the defense does 3 not exist where there is a “failure to take all reasonable steps within the party’s power to 4 5 comply.” Reno Air Racing Ass’n, Inc. v. McCord, 452 F.3d 1126, 1130 (9th Cir. 2006). To 6 determine whether a party substantially complied with a consent decree, the Court must take a 7 “holistic view of all the available information,” to see if the level of compliance “overall was 8 9 substantial, notwithstanding some minimal level of noncompliance.” Labor/Cmty. Strategy Ctr. 10 v. L.A. Cty. Metro. Transp. Auth., 564 F.3d 1115, 1122 (9th Cir. 2009); Puget Soundkeeper 11 Alliance v. Rainier Petroleum Corp., W.D. Wash. No. C14-0829JLR, 2017 U.S. Dist. LEXIS 12 13 208663 (Dec. 19, 2017). 14 Soundkeeper argues that the delay was due to SIMC’s lack of diligence: 15 SIMC waited until September 2021 before preparing to select 16 the type of mesh material necessary for completing the 17 trommel enclosure – over a year after completing design drawings and submitting the necessary City of Seattle permit 18 application. Kinn Decl. ¶ 10. Knowing full well that the 19 Consent Decree required installation within 21 of weeks of permit issuance, SIMC waited to select and order that 20 necessary material until the installation deadline was imminent. 21 Id. ¶ 21. SIMC’s attempts to blame third parties for its own delay should not be well-taken. 22
23 Dkt.#89 at 3. Soundkeeper also attempts to cut off a “substantial compliance” argument: 24 Soundkeeper anticipates that SIMC may argue that it believes 25 it has substantially complied with the trommel enclosure installation deadline because it had largely erected the 26 enclosure’s frame by that date. The Court should not be 27 convinced. The entire purpose of installing the trommel enclosure is to enclose the trommel, thereby containing dust 28 emissions generated by the processing that occurs within its 29 giant rotating drum. Dkt. 88 at 5.
Free access — add to your briefcase to read the full text and ask questions with AI
8 IN THE UNITED STATES DISTRICT COURT 9 FOR THE WESTERN DISTRICT OF WASHINGTON AT SEATTLE 10
12 PUGET SOUNDKEEPER ALLIANCE, Case No. C12-1201RSM 13 Plaintiff, 14 ORDER GRANTING MOTION TO 15 v. ENFORCE CONSENT DECREE 16 SEATTLE IRON & METALS CORP., 17 Defendant. 18
19 20 This matter comes before the Court on Plaintiff Puget Soundkeeper Alliance 21 (“Soundkeeper”)’s Motion to Enforce Consent Decree, Dkt. #89. 22 In this case, Soundkeeper alleged that Seattle Iron & Metals Corporation, (“SIMC”) 23 24 violated various provisions of Clean Water Act (“CWA”) permits that authorized stormwater 25 and industrial wastewater discharges from SIMC’s facilities in Seattle’s Georgetown 26 neighborhood used for vehicle and scrap metal recycling and storage. Dkt. #38. Relevant to 27 28 this Motion, Soundkeeper alleged that SIMC’s scrap handling activities emit dust and harmful 29 particles into the air that contaminate the neighborhood and Duwamish River in violation of the 30 CWA and Resource Conservation and Recovery Act (“RCRA”). Id. at 55, 104-108, and 134. ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 1 1 The parties settled the case via a Consent Decree, which the Court entered on March 3, 2 2019. Dkts. #82 and #84. SIMC agreed to install wind fencing to contain dust emissions by 3 mid-2019. Dkt. #84 at 6. Additional technical analysis revealed that “replacing one set of wind 4 5 fences with an enclosure for the trommel equipment to control dust closer to its source,” would 6 be more effective. Dkt. #86 at 2. The parties therefore filed a proposed Amended Consent 7 Decree with the Court on September 10, 2020, replacing the dust fence requirement with a 8 9 requirement to enclose the trommel equipment, amending the installation schedule, and 10 requiring additional penalty payments, including stipulated daily penalties if the new deadline 11 for the trommel enclosure was not met. Id. at 2, Dkt. #86-2 at 5. The terms and conditions of 12 13 the original Consent Decree were to remain in full force and effect except as specifically 14 amended. Relevant to the instant Motion, the Amended Decree stated: 15 Within 21 weeks of the City of Seattle’s issuance of the 16 building permit for the trommel enclosure, SIMC shall install 17 the permitted trommel enclosure. In the event that SIMC fails to install the trommel enclosure within 21 weeks of permit 18 issuance, SIMC shall pay stipulated penalties of $1,000 per day 19 until the trommel enclosure is installed.
20 Dkt. #88 at 5. Earlier, the Amended Decree states that SIMC completed “design drawings and 21 City of Seattle permit applications for wind fences and a trommel enclosure that meet the 22 23 requirements of this section and are approved by Dr. Ranajit Sahu, the parties’ joint consultant.” 24 Id. at 4. The Court entered the Amended Decree on October 30, 2020. Dkt. #88. 25 The original Consent Decree contained a force majeure clause allowing delays “outside 26 27 the reasonable control of SIMC,” including those caused by the actions or inactions of third 28 parties. See Dkt. #84 at 11–12. “In such event, the time for performance of the task will be 29 extended for a reasonable period of time following the force majeure event.” Id. at 12. 30 ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 2 1 Paragraph 11 provides that a prevailing party should be awarded its costs, including attorneys’ 2 fees, in any proceedings to enforce the Consent Decree. Id. at 12. 3 The City of Seattle approved SIMC’s trommel enclosure construction permit on March 4 5 26, 2021, and while SIMC anticipated the permit would issue in April, the City did not issue the 6 permit until July 22, 2021. Dkt. #90 (“Kinn Decl.”), ¶¶ 5-6, Ex. A. The deadline for SIMC to 7 install the trommel enclosure was therefore December 16, 2021. 8 9 There were delays. Although the trommel’s metal structure was built, the mesh material 10 that actually performs the dust containment was not immediately installed. The parties agree 11 that this was not finished until March 3, 2022, 77 days after the deadline. Dkt. #91 at 4; Dkt. 12 13 #94 at 7. SIMC has refused to pay the $1,000 per day penalty. 14 Soundkeeper now moves the Court to find SIMC in civil contempt of the Amended 15 Consent Decree and for the Court to order SIMC to pay stipulated penalties, interest, and 16 17 Soundkeeper’s attorneys’ fees and costs in bringing this motion. 18 Clean Water Act consent decrees are judgments which may be enforced by judicial 19 sanctions in a civil contempt proceeding. Las Vegas v. Clark Cty., 755 F.2d 697, 701 (9th Cir. 20 21 1984); Nw. Envtl. Def. Ctr. v. H&H Welding, No. 3:13-cv-00653-AC, 2015 U.S. Dist. LEXIS 22 162182, at *43 (D. Or. Oct. 13, 2015); see also Nehmer v. U.S. Dept. of Veterans Affairs, 494 23 F.3d 846, 860 (9th Cir. 2007) (“It is well established that the district court has the inherent 24 25 authority to enforce compliance with a consent decree that it has entered in an order, to hold 26 parties in contempt for violating the terms therein.”). To justify civil contempt, the moving 27 party must prove by clear and convincing evidence that the nonmoving party violated a court 28 29 order. Ahearn ex rel. N.L.R.B. v. Int’l Longshore & Warehouse Union, Locals 21 & 4, 721 F.3d 30 1122, 1129 (9th Cir. 2013). ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 3 1 “Substantial compliance” may provide a defense to an action for civil contempt. Gen. 2 Signal Corp. v. Donallco, Inc., 787 F.2d 1376, 1380 (9th Cir. 1986). However, the defense does 3 not exist where there is a “failure to take all reasonable steps within the party’s power to 4 5 comply.” Reno Air Racing Ass’n, Inc. v. McCord, 452 F.3d 1126, 1130 (9th Cir. 2006). To 6 determine whether a party substantially complied with a consent decree, the Court must take a 7 “holistic view of all the available information,” to see if the level of compliance “overall was 8 9 substantial, notwithstanding some minimal level of noncompliance.” Labor/Cmty. Strategy Ctr. 10 v. L.A. Cty. Metro. Transp. Auth., 564 F.3d 1115, 1122 (9th Cir. 2009); Puget Soundkeeper 11 Alliance v. Rainier Petroleum Corp., W.D. Wash. No. C14-0829JLR, 2017 U.S. Dist. LEXIS 12 13 208663 (Dec. 19, 2017). 14 Soundkeeper argues that the delay was due to SIMC’s lack of diligence: 15 SIMC waited until September 2021 before preparing to select 16 the type of mesh material necessary for completing the 17 trommel enclosure – over a year after completing design drawings and submitting the necessary City of Seattle permit 18 application. Kinn Decl. ¶ 10. Knowing full well that the 19 Consent Decree required installation within 21 of weeks of permit issuance, SIMC waited to select and order that 20 necessary material until the installation deadline was imminent. 21 Id. ¶ 21. SIMC’s attempts to blame third parties for its own delay should not be well-taken. 22
23 Dkt.#89 at 3. Soundkeeper also attempts to cut off a “substantial compliance” argument: 24 Soundkeeper anticipates that SIMC may argue that it believes 25 it has substantially complied with the trommel enclosure installation deadline because it had largely erected the 26 enclosure’s frame by that date. The Court should not be 27 convinced. The entire purpose of installing the trommel enclosure is to enclose the trommel, thereby containing dust 28 emissions generated by the processing that occurs within its 29 giant rotating drum. Dkt. 88 at 5. Erection of the enclosure’s frame without installing the mesh material that actually 30 performs the dust containment does no more than create a structure that fails in its raison d’être. ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 4 1 Id. at 10. 2 3 In Response, SIMC argues that it completed the trommel enclosure “as contemplated 4 under the express language of the Amended Consent Decree” within the 21-week deadline, and 5 that it completed the installation of the trommel enclosure’s cladding—which was not subject to 6 7 the 21-week deadline or any other contractual deadline—within an objectively reasonable 8 amount of time. Dkt. #91 at 1–2. SIMC does not cite the force majeure clause. 9 The Court has reviewed the record and the briefing of the parties and finds that SIMC 10 11 did not achieve substantial compliance within the deadline. SIMC makes much hay out of the 12 Amended Decree language “permitted trommel enclosure,” as if it was only required to install 13 exactly what was in the City of Seattle permit, a metal frame; the Court instead reads this as 14 15 requiring the installation of the trommel enclosure as contemplated earlier in the Amended 16 Consent Decree, and that it be permitted. Substantial compliance in this case meant erection of 17 a functioning trommel enclosure, the meaning of that word being clear to the Court and well 18 19 known to the parties. The metal frame constructed before the deadline supported the trommel 20 enclosure, it was not itself the trommel enclosure. While SIMC points to certain of its actions 21 that demonstrate diligence (and cooperation with Soundkeeper), other prior actions and 22 23 inactions reflect a lack of diligence, like the delay in selecting the mesh material. Given all of 24 the above, the Court finds by clear and convincing evidence that SIMC violated the Amended 25 Consent Decree and that the relief requested by Soundkeeper is appropriate. The Court declines 26 27 to award interest as a sanction as such is outside the penalties contemplated by the Amended 28 Decree. 29 Soundkeeper’s request to take discovery on this issue is moot. 30 ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 5 1 Having reviewed the relevant briefing and the remainder of the record, the Court hereby 2 FINDS and ORDERS that: 3 1) Not later than thirty (30) days from the date of this Order, SIMC shall pay $77,000 in 4 5 stipulated penalties to Just Health Action, for environmental benefit projects in the 6 Duwamish River and central Puget Sound watersheds, as described in Attachment B of 7 the 2020 Consent Decree, Dkt. #88 at 29. Payment shall be made by check to the 8 9 address provided in Attachment B. Payment shall include the following reference in a 10 cover letter or on the check: “Stipulated Penalties and Sanctions, PSA v. Seattle Iron & 11 Metals Corp; For the benefit of the Duwamish Valley Clean Air Program.” SIMC shall 12 13 notify the Court and Soundkeeper once it has made the payment. 14 2) The Court declines to award interest as a sanction. 15 3) The Court further orders that SIMC will pay $2,000 per day in coercive sanctions should 16 17 it fail to timely comply with this Order. 18 4) Soundkeeper is a prevailing party in this proceeding. SIMC shall pay for Soundkeeper’s 19 costs, including reasonable attorneys’ fees, incurred in enforcing the Consent Decree. 20 21 Soundkeeper is directed to file an accounting of these costs within two weeks of this 22 Order. The Court will review this accounting and issue a subsequent order. No 23 response is needed from SIMC unless requested by the Court. 24 25 DATED this 3rd day of February, 2023. 26 A 27 28 RICARDO S. MARTINEZ 29 UNITED STATES DISTRICT JUDGE
ORDER GRANTING MOTION TO ENFORCE CONSENT DECREE – 6