Michael Harmonay Corp. v. Board of Education of the City School District of New Rochelle

Appellate Division of the Supreme Court of New York

Michael Harmonay Corp. v. Board of Education of the City School District of New Rochelle

18 A.D.2d 934, 1963 N.Y. App. Div. LEXIS 4373

CourtAppellate Division of the Supreme Court of the State of New York

DecidedFebruary 18, 1963

StatusPublished

This text of 18 A.D.2d 934 (Michael Harmonay Corp. v. Board of Education of the City School District of New Rochelle) is published on Counsel Stack Legal Research, covering Appellate Division of the Supreme Court of the State of New York primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook

Michael Harmonay Corp. v. Board of Education of the City School District of New Rochelle, 18 A.D.2d 934, 1963 N.Y. App. Div. LEXIS 4373 (N.Y. Ct. App. 1963).

Pincite

Opinion

In an action by the prime contractor for the heating and ventilating work on a school construction job, against defendant, the Board of Education of the City School District of New Rochelle, for damages resulting from delays caused by said board, in which the board served a third-party complaint against the general contractor and its surety, the board, as third-party plaintiff, appeals from an raider of the Supreme Court, Westchester County, dated March 13, 1962, which, on motion of the third-party defendants, stayed the third-party action until arbitration has been had in accordance with the school construction contract between the board and the general contractor. Order affirmed, with $10 costs and disbursements (see Matter of Board of Educ. City School Dist. of New Rochelle v. Bernard Associates No. 3, 11 A D 2d 1038). Beldock, P. J., Kleinfeld, Christ, Hillj and Hopkins, JJ., concur.

Free access — add to your briefcase to read the full text and ask questions with AI

In an action by the prime contractor for the heating and ventilating work on a school construction job, against defendant, the Board of Education of the City School District of New Rochelle, for damages resulting from delays caused by said board, in which the board served a third-party complaint against the general contractor and its surety, the board, as third-party plaintiff, appeals from an raider of the Supreme Court, Westchester County, dated March 13, 1962, which, on motion of the third-party defendants, stayed the third-party action until arbitration has been had in accordance with the school construction contract between the board and the general contractor. Order affirmed, with $10 costs and disbursements (see Matter of Board of Educ. City School Dist. of New Rochelle v. Bernard Associates No. 3, 11 A D 2d 1038). Beldock, P. J., Kleinfeld, Christ, Hillj and Hopkins, JJ., concur.

Cite This Page — Counsel Stack

Bluebook (online)

18 A.D.2d 934, 1963 N.Y. App. Div. LEXIS 4373, Counsel Stack Legal Research, https://law.counselstack.com/opinion/michael-harmonay-corp-v-board-of-education-of-the-city-school-district-of-nyappdiv-1963.