McWilliams Construction, Inc. v. Village of Spring Park

Supreme Court of Minnesota

McWilliams Construction, Inc. v. Village of Spring Park

200 N.W.2d 401, 294 Minn. 509, 1972 Minn. LEXIS 1447

CourtSupreme Court of Minnesota

DecidedAugust 4, 1972

DocketNo. 43295

StatusPublished

This text of 200 N.W.2d 401 (McWilliams Construction, Inc. v. Village of Spring Park) is published on Counsel Stack Legal Research, covering Supreme Court of Minnesota primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook

McWilliams Construction, Inc. v. Village of Spring Park, 200 N.W.2d 401, 294 Minn. 509, 1972 Minn. LEXIS 1447 (Mich. 1972).

Pincite

Opinion

Per Curiam.

Plaintiff, McWilliams Construction, Inc., seeks review of a post-trial decision of the trial court denying its motion to amend its complaint and ordering entry of a money judgment against plaintiff in favor of defendant Johnson Brothers Highway and Heavy Constructors, Inc., pursuant to a special verdict of a jury. In ordering the judgment, the trial court refused to order judgment for plaintiff on its claim against defendant Johnson Brothers for an additional construction expense which was based upon an alleged breach of an oral agreement concerning the time schedule of the respective parties in constructing sewer and water mains in the village of Spring Park.¹ During trial, the court [510]*510reserved decision as to the issue of liability on this claim even'though the jury was permitted to find on special-interrogatories that defendant Johnson Brothers delayed its performance in the excavation and installation of sewer mains, thus delaying plaintiff’s installation of water mains, and that such delay resulted in additional expense to plaintiff of $4,500.

Reading the procedural record in the light most favorable to plaintiff, it is our conclusion that plaintiff is attempting to appeal from an order directing the entry of judgment following special findings by a jury, which order, because it is not final, is not appealable. of right. Cucchiarella v. Kolodzieg, 283 Minn. 515, 166 N. W. 2d 100 (1969). Accordingly, defendant Johnson Brothers’ motion to dismiss plaintiff’s appeal, which had been filed before oral argument and upon which we reserved decision, is granted.

. Although we do not regard the issue of defendant Johnson Brothers’ liability to plaintiff as one justifying discretionary review, we have, in view of the submission of written and oral argument, nevertheless considered the merits of the appeal. We are persuaded that the trial court properly denied recovery by plaintiff for the reason, expressed in the court’s supplementary memorandum, that no valid legal theory upon which recovery could be based exists. It is also our conclusion after reading the transcript of the testimony that plaintiff’s claim as to an "¡agreement made by defendant Johnson Brothers concerning its schedule for completing the excavation and installation of the sewer mains was not established by the evidence.

Affirmed.

Free access — add to your briefcase to read the full text and ask questions with AI

Per Curiam.

Plaintiff, McWilliams Construction, Inc., seeks review of a post-trial decision of the trial court denying its motion to amend its complaint and ordering entry of a money judgment against plaintiff in favor of defendant Johnson Brothers Highway and Heavy Constructors, Inc., pursuant to a special verdict of a jury. In ordering the judgment, the trial court refused to order judgment for plaintiff on its claim against defendant Johnson Brothers for an additional construction expense which was based upon an alleged breach of an oral agreement concerning the time schedule of the respective parties in constructing sewer and water mains in the village of Spring Park.¹ During trial, the court [510]*510reserved decision as to the issue of liability on this claim even'though the jury was permitted to find on special-interrogatories that defendant Johnson Brothers delayed its performance in the excavation and installation of sewer mains, thus delaying plaintiff’s installation of water mains, and that such delay resulted in additional expense to plaintiff of $4,500.

Reading the procedural record in the light most favorable to plaintiff, it is our conclusion that plaintiff is attempting to appeal from an order directing the entry of judgment following special findings by a jury, which order, because it is not final, is not appealable. of right. Cucchiarella v. Kolodzieg, 283 Minn. 515, 166 N. W. 2d 100 (1969). Accordingly, defendant Johnson Brothers’ motion to dismiss plaintiff’s appeal, which had been filed before oral argument and upon which we reserved decision, is granted.

. Although we do not regard the issue of defendant Johnson Brothers’ liability to plaintiff as one justifying discretionary review, we have, in view of the submission of written and oral argument, nevertheless considered the merits of the appeal. We are persuaded that the trial court properly denied recovery by plaintiff for the reason, expressed in the court’s supplementary memorandum, that no valid legal theory upon which recovery could be based exists. It is also our conclusion after reading the transcript of the testimony that plaintiff’s claim as to an "¡agreement made by defendant Johnson Brothers concerning its schedule for completing the excavation and installation of the sewer mains was not established by the evidence.

Affirmed.

Cite This Page — Counsel Stack

Bluebook (online)

200 N.W.2d 401, 294 Minn. 509, 1972 Minn. LEXIS 1447, Counsel Stack Legal Research, https://law.counselstack.com/opinion/mcwilliams-construction-inc-v-village-of-spring-park-minn-1972.

Opinion

Related

Cite This Page — Counsel Stack