This opinion will be unpublished and may not be cited except as provided by Minn. Stat. § 480A.08, subd. 3 (2014).
STATE OF MINNESOTA IN COURT OF APPEALS A14-0678
KBW Associates, Inc., Appellant,
vs.
W.L. Hall Co., Respondent.
Filed March 30, 2015 Affirmed Klaphake, Judge*
Clay County District Court File No. 14CV13180
Kip M. Kaler, Kaler Doeling, P.L.L.P., Fargo, North Dakota (for appellant)
Michael B. Lapicola, David A. Snieg, Faegre, Baker, Daniels, LLP, Minneapolis, Minnesota (for respondent)
Considered and decided by Bjorkman, Presiding Judge; Smith, Judge; and
Klaphake, Judge.
UNPUBLISHED OPINION
KLAPHAKE, Judge
Appellant general contractor KBW Associates, Inc. (KBW) challenges the district
court’s dismissal of its promissory estoppel claim against respondent subcontractor W.L.
* Retired judge of the Minnesota Court of Appeals, serving by appointment pursuant to Minn. Const. art. VI, § 10. Hall Co. (Hall). KBW argues that the district court erred by concluding that (1) KBW
did not rely to its detriment on Hall’s promise to complete the work on time and
(2) Hall’s promise need not be enforced to avoid injustice. We affirm.
DECISION
Promissory estoppel is an equitable doctrine that “impl[ies] a contract in law
where none exists in fact.” Grouse v. Grp. Health Plan, Inc., 306 N.W.2d 114, 116
(Minn. 1981). Promissory estoppel “requires proof that 1) a clear and definite promise
was made, 2) the promisor intended to induce reliance . . . [,] [3] the promisee in fact
relied to his or her detriment, and [4] the promise must be enforced to prevent injustice.”
Martens v. Minn. Mining & Mfg. Co., 616 N.W.2d 732, 746 (Minn. 2000).
In applying Minn. R. Civ. P. 52.01, “we view the record in the light most
favorable to the judgment of the district court.” Rogers v. Moore, 603 N.W.2d 650, 656
(Minn. 1999). “The decision of a district court should not be reversed merely because the
appellate court views the evidence differently.” Id. “Rather, the findings must be
manifestly contrary to the weight of the evidence or not reasonably supported by the
evidence as a whole.” Id. (quotation omitted). “Findings of fact are clearly erroneous
only if the reviewing court is left with the definite and firm conviction that a mistake has
been made.” Fletcher v. St. Paul Pioneer Press, 589 N.W.2d 96, 101 (Minn. 1999)
(quotation omitted). And “[i]f there is reasonable evidence to support the district court’s
findings, we will not disturb them.” Rogers, 603 N.W.2d at 656. This court applies a de
novo standard of review to the district court’s conclusions of law. Western Insulation
Servs. v. Central Nat’l Ins. Co., 460 N.W.2d 355, 357 (Minn. App. 1990).
2 I.
KBW received a subcontract bid from Hall which it incorporated into its general
contractor’s bid to Minnesota State Colleges and University (MNSCU). The MNSCU
project at issue involves the first phase (Phase 1) of a two-phase renovation of a residence
hall that was to be performed under the specifications promulgated by MNSCU. The
specifications required substantial completion by August 15, 2011. Hall withdrew its bid
after MNSCU awarded the general contract to KBW, stating that its bid was in error and
the bid proposal was $60,000 lower than it had intended to bid. KBW thereafter found a
replacement subcontractor to complete the project.
KBW first challenges the district court’s conclusion that KBW did not rely to its
detriment upon Hall’s performance. To support this conclusion, the district court found
that (1) the project was delayed because of KBW’s month-long search for a replacement
subcontractor, and then by the MNSCU approval process, which in turn delayed the
manufacture and delivery of the materials for the project; (2) KBW made the decision to
go with another subcontractor despite knowing that Hall could timely perform; and (3) it
was uncertain from the evidence whether Phase 1 of the project was substantially
completed by the deadline.
Delay due to KBW’s month-long search for a contractor other than Hall
The district court found that KBW’s search for a replacement subcontractor was
the reason the project was delayed. We agree. KBW was aware that it needed to find a
replacement subcontractor after Hall withdrew its bid on April 25, 2011. Despite this,
KBW rejected a bid it received four days later from Northland Glass and Glazing
3 Company (Northland), which advised KBW that it would need to accept the bid
immediately in order to meet project deadlines. KBW instead waited until May 25 to
accept Northland’s bid,1 ten days after the date the project was scheduled to commence
and exactly one month after Hall withdrew its bid. KBW knew that contracting with
Northland would require approval from MNSCU—a process KBW knew would take
additional time and add further delay to the project start date. Thus, this finding by the
district court is not clearly erroneous.
KBW could have contracted with Hall to avoid the delay
The district court also found that KBW could have contracted with Hall to avoid
delaying the process. KBW testified that it knew Hall was the exclusive supplier of
Wausau products and that Northland would not be able to complete the project on time
when it accepted Northland’s bid. KBW testified that although it discussed the
withdrawal of Hall’s bid with MNSCU, they both “agreed” to look for a replacement
subcontractor rather than pay Hall the additional $60,000. KBW stated, and MNSCU
agreed, that it believed that Hall’s conduct represented poor business ethics. KBW
testified that they both were “pretty disgusted with [Hall]” and paying the additional
$60,000 for the corrected bid amount “would be the last thing [they’d] do.” The parties
do not dispute that Hall would have performed the work if KBW agreed to pay the
additional $60,000.
1 This was Northland’s second bid. KBW rejected Northland’s first bid because it was too high. The bid KBW accepted was for a lesser amount but included materials from manufactures other than Wausau—the manufacturer named in MNSCU’s project specification.
4 KBW instead continued to look for a replacement subcontractor. There is no
evidence tending to show that KBW attempted to negotiate the increased bid price with
Hall. Indeed, when asked at trial whether KBW made an attempt to “persuade [Hall] to
work the project,” KBW testified that it only asked “why [Hall] would do this and why
[Hall] would not honor [its] bid.” KBW testified that it would not have offered Hall the
additional $60,000 in order to complete the job. The district court’s finding in this regard
is not clearly erroneous.
Failure to meet substantial completion deadline
The district court found that it was unclear from the record that KBW failed to
meet the project’s August 15 substantial completion date. The project specification
states, “Substantial completion is the stage in the progress of the Work when the Work or
Free access — add to your briefcase to read the full text and ask questions with AI
This opinion will be unpublished and may not be cited except as provided by Minn. Stat. § 480A.08, subd. 3 (2014).
STATE OF MINNESOTA IN COURT OF APPEALS A14-0678
KBW Associates, Inc., Appellant,
vs.
W.L. Hall Co., Respondent.
Filed March 30, 2015 Affirmed Klaphake, Judge*
Clay County District Court File No. 14CV13180
Kip M. Kaler, Kaler Doeling, P.L.L.P., Fargo, North Dakota (for appellant)
Michael B. Lapicola, David A. Snieg, Faegre, Baker, Daniels, LLP, Minneapolis, Minnesota (for respondent)
Considered and decided by Bjorkman, Presiding Judge; Smith, Judge; and
Klaphake, Judge.
UNPUBLISHED OPINION
KLAPHAKE, Judge
Appellant general contractor KBW Associates, Inc. (KBW) challenges the district
court’s dismissal of its promissory estoppel claim against respondent subcontractor W.L.
* Retired judge of the Minnesota Court of Appeals, serving by appointment pursuant to Minn. Const. art. VI, § 10. Hall Co. (Hall). KBW argues that the district court erred by concluding that (1) KBW
did not rely to its detriment on Hall’s promise to complete the work on time and
(2) Hall’s promise need not be enforced to avoid injustice. We affirm.
DECISION
Promissory estoppel is an equitable doctrine that “impl[ies] a contract in law
where none exists in fact.” Grouse v. Grp. Health Plan, Inc., 306 N.W.2d 114, 116
(Minn. 1981). Promissory estoppel “requires proof that 1) a clear and definite promise
was made, 2) the promisor intended to induce reliance . . . [,] [3] the promisee in fact
relied to his or her detriment, and [4] the promise must be enforced to prevent injustice.”
Martens v. Minn. Mining & Mfg. Co., 616 N.W.2d 732, 746 (Minn. 2000).
In applying Minn. R. Civ. P. 52.01, “we view the record in the light most
favorable to the judgment of the district court.” Rogers v. Moore, 603 N.W.2d 650, 656
(Minn. 1999). “The decision of a district court should not be reversed merely because the
appellate court views the evidence differently.” Id. “Rather, the findings must be
manifestly contrary to the weight of the evidence or not reasonably supported by the
evidence as a whole.” Id. (quotation omitted). “Findings of fact are clearly erroneous
only if the reviewing court is left with the definite and firm conviction that a mistake has
been made.” Fletcher v. St. Paul Pioneer Press, 589 N.W.2d 96, 101 (Minn. 1999)
(quotation omitted). And “[i]f there is reasonable evidence to support the district court’s
findings, we will not disturb them.” Rogers, 603 N.W.2d at 656. This court applies a de
novo standard of review to the district court’s conclusions of law. Western Insulation
Servs. v. Central Nat’l Ins. Co., 460 N.W.2d 355, 357 (Minn. App. 1990).
2 I.
KBW received a subcontract bid from Hall which it incorporated into its general
contractor’s bid to Minnesota State Colleges and University (MNSCU). The MNSCU
project at issue involves the first phase (Phase 1) of a two-phase renovation of a residence
hall that was to be performed under the specifications promulgated by MNSCU. The
specifications required substantial completion by August 15, 2011. Hall withdrew its bid
after MNSCU awarded the general contract to KBW, stating that its bid was in error and
the bid proposal was $60,000 lower than it had intended to bid. KBW thereafter found a
replacement subcontractor to complete the project.
KBW first challenges the district court’s conclusion that KBW did not rely to its
detriment upon Hall’s performance. To support this conclusion, the district court found
that (1) the project was delayed because of KBW’s month-long search for a replacement
subcontractor, and then by the MNSCU approval process, which in turn delayed the
manufacture and delivery of the materials for the project; (2) KBW made the decision to
go with another subcontractor despite knowing that Hall could timely perform; and (3) it
was uncertain from the evidence whether Phase 1 of the project was substantially
completed by the deadline.
Delay due to KBW’s month-long search for a contractor other than Hall
The district court found that KBW’s search for a replacement subcontractor was
the reason the project was delayed. We agree. KBW was aware that it needed to find a
replacement subcontractor after Hall withdrew its bid on April 25, 2011. Despite this,
KBW rejected a bid it received four days later from Northland Glass and Glazing
3 Company (Northland), which advised KBW that it would need to accept the bid
immediately in order to meet project deadlines. KBW instead waited until May 25 to
accept Northland’s bid,1 ten days after the date the project was scheduled to commence
and exactly one month after Hall withdrew its bid. KBW knew that contracting with
Northland would require approval from MNSCU—a process KBW knew would take
additional time and add further delay to the project start date. Thus, this finding by the
district court is not clearly erroneous.
KBW could have contracted with Hall to avoid the delay
The district court also found that KBW could have contracted with Hall to avoid
delaying the process. KBW testified that it knew Hall was the exclusive supplier of
Wausau products and that Northland would not be able to complete the project on time
when it accepted Northland’s bid. KBW testified that although it discussed the
withdrawal of Hall’s bid with MNSCU, they both “agreed” to look for a replacement
subcontractor rather than pay Hall the additional $60,000. KBW stated, and MNSCU
agreed, that it believed that Hall’s conduct represented poor business ethics. KBW
testified that they both were “pretty disgusted with [Hall]” and paying the additional
$60,000 for the corrected bid amount “would be the last thing [they’d] do.” The parties
do not dispute that Hall would have performed the work if KBW agreed to pay the
additional $60,000.
1 This was Northland’s second bid. KBW rejected Northland’s first bid because it was too high. The bid KBW accepted was for a lesser amount but included materials from manufactures other than Wausau—the manufacturer named in MNSCU’s project specification.
4 KBW instead continued to look for a replacement subcontractor. There is no
evidence tending to show that KBW attempted to negotiate the increased bid price with
Hall. Indeed, when asked at trial whether KBW made an attempt to “persuade [Hall] to
work the project,” KBW testified that it only asked “why [Hall] would do this and why
[Hall] would not honor [its] bid.” KBW testified that it would not have offered Hall the
additional $60,000 in order to complete the job. The district court’s finding in this regard
is not clearly erroneous.
Failure to meet substantial completion deadline
The district court found that it was unclear from the record that KBW failed to
meet the project’s August 15 substantial completion date. The project specification
states, “Substantial completion is the stage in the progress of the Work when the Work or
designated portion thereof is sufficiently complete in accordance with the Contract
Documents so that the Owner can occupy or utilize the Work for its intended use.” The
project specification further instructs that “[t]he Owner may occupy or use any completed
or partially completed portion of the Work at any stage . . . provided such occupancy or
use is consented to by the insurer as required[.] Such partial occupancy or use may
commence whether or not the portion is substantially complete.”
Conflicting evidence was presented on whether the project was substantially
completed by August 15, 2011.2 There was testimony that students were able to use the
bathrooms, despite the fact that the installation of the curtain walls and windows was not
2 While both parties allude to a Certificate of Substantial Completion to be issued by the Architect pursuant to § 9.8.4 of the project specification, there is nothing in the record to show that one was ever issued.
5 completed. There was also testimony that the students could use part of the lounge area
while Northland continued to work. KBW provided testimony that the students could use
the bathroom, but that they could not use the lounge and the kitchen area. However, it is
undisputed that the windows and curtain walls were not delivered until on or around
August 15—the deadline date for substantial completion. Based on this evidence, the
district court did not err by finding that the record was incomplete for purposes of
determining whether KBW substantially completed the project by August 15.3
II.
KBW challenges the district court’s conclusion that Hall’s promise did not need to
be enforced in order to prevent injustice. Whether a promise must be enforced to prevent
injustice depends on, among other things, the reasonableness of a promisee's reliance.
Faimon v. Winona State Univ., 540 N.W.2d 879, 883 (Minn. App. 1995), review denied
(Minn. Feb. 9, 1996). “The injustice factor is a question of law that the court must
decide.” Id.
The district court found that KBW “should have at least sought timely
performance by Hall before it solicited an untimely performance by Northland.” Because
it did not, the district court determined it could not “find that KBW made reasonable
efforts to avoid the consequences for which it now seeks to hold Hall liable.” KBW
argues that it mitigated its damages by looking for a different subcontractor, and by
3 Moreover, the district court noted that even if it were to agree with KBW that the project was not substantially completed on August 15, 2011, “the [c]ourt [could] make no finding as to whether that was the case because the window and curtain wall work was incomplete, or for other reasons.”
6 getting MNSCU to reimburse it for Northland’s additional costs. We are not persuaded.
KBW chose to look for a replacement contractor instead of using Hall despite knowing
that it would not be able to timely meet the project deadline. KBW did not make
reasonable attempts to work with Hall after discovering that Hall withdrew its bid. Nor
did KBW make a reasonable attempt to persuade MNSCU to pay Hall the difference.
KBW’s decision to find another subcontractor was grounded in its disagreement with
Hall’s business ethics. In fact, KBW was able to obtain reimbursement from MNSCU in
the amount of $84,481 to pay for Northland’s contract—an amount greater than the
additional $60,000 requested by Hall. KBW did not make reasonable efforts to mitigate
its damages for not meeting the time requirements of the project; thus, any reliance that
KBW had on Hall’s promise to complete the project on time was not reasonable, and the
district court did not err in so finding.
Affirmed.