Isadore Rosen & Sons, Inc. v. John A. Johnson & Sons, Inc.

Appellate Division of the Supreme Court of New York

Isadore Rosen & Sons, Inc. v. John A. Johnson & Sons, Inc.

11 A.D.2d 723, 205 N.Y.S.2d 870, 1960 N.Y. App. Div. LEXIS 9142

CourtAppellate Division of the Supreme Court of the State of New York

DecidedJune 20, 1960

StatusPublished

This text of 11 A.D.2d 723 (Isadore Rosen & Sons, Inc. v. John A. Johnson & Sons, Inc.) is published on Counsel Stack Legal Research, covering Appellate Division of the Supreme Court of the State of New York primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook

Isadore Rosen & Sons, Inc. v. John A. Johnson & Sons, Inc., 11 A.D.2d 723, 205 N.Y.S.2d 870, 1960 N.Y. App. Div. LEXIS 9142 (N.Y. Ct. App. 1960).

Pincite

Opinion

In an action by a subcontractor against the general contractor and the surety company on its bond, to recover damages allegedly sustained by reason of delays and interference during the performance of a construction contract, the defendants appeal from an order of the Supreme Court, Westchester County, entered September 1, 1959, denying their motion for partial summary judgment dismissing the second cause of action. Order affirmed, with $10 costs and disbursements. No opinion. Beldock, Acting P. J., Kleinfeld, Christ, Pette and Brennan, JJ., concur.

Free access — add to your briefcase to read the full text and ask questions with AI

In an action by a subcontractor against the general contractor and the surety company on its bond, to recover damages allegedly sustained by reason of delays and interference during the performance of a construction contract, the defendants appeal from an order of the Supreme Court, Westchester County, entered September 1, 1959, denying their motion for partial summary judgment dismissing the second cause of action. Order affirmed, with $10 costs and disbursements. No opinion. Beldock, Acting P. J., Kleinfeld, Christ, Pette and Brennan, JJ., concur.

Cite This Page — Counsel Stack

Bluebook (online)

11 A.D.2d 723, 205 N.Y.S.2d 870, 1960 N.Y. App. Div. LEXIS 9142, Counsel Stack Legal Research, https://law.counselstack.com/opinion/isadore-rosen-sons-inc-v-john-a-johnson-sons-inc-nyappdiv-1960.