COURT OF APPEALS EIGHTH DISTRICT OF TEXAS EL PASO, TEXAS
F.T. JAMES CONSTRUCTION, INC., § No. 08-20-00096-CV Appellant, § Appeal from the v. § 210th District Court HOTEL SANCHO PANZA, LLC, and § JORDAN FOSTER CONSTRUCTION, of El Paso County, Texas LLC., § (TC# 2019-DCV-0505) Appellees. §
OPINION
Appellee Hotel Sancho Panza, LLC (the Hotel) filed suit against F.T. James Construction,
Inc. (FTJC) over delays in the construction of the Courtyard Marriott Downtown/Convention
Center hotel and meeting space in downtown El Paso. FTJC answered the lawsuit, made
counterclaims against the Hotel, and initiated a third-party claim against one of its subcontractors,
Jordan Foster Construction Inc. (Jordan Foster). In turn, Jordan Foster filed a counterclaim against
FTJC, and subsequently, a third-party petition against the Hotel.
Just shy of one year after the Hotel initiated this lawsuit, FTJC moved to compel arbitration
and abate the case, pursuant to what it views as a valid and enforceable arbitration clause in the
contract between it and the Hotel. The trial court denied FTJC’s motion to compel arbitration and this interlocutory appeal followed. FTJC asks this Court to reverse the trial court’s denial of its
motion. We affirm.
I. BACKGROUND
The Project
The Hotel hired FTJC to construct a Courtyard Marriott hotel and meeting space in
downtown El Paso (the Project). The contract between the parties was entered on May 21, 2016.
Among its terms, the contract provided for substantial completion of the Project within 420 days
after commencement, and 30 days more for final completion. That timeline meant expected
completion was by August 2017. The Project, however, was not completed within the time period
called for in the contract. In the underlying suit, the parties dispute the cause of the delay. FTJC
claims the delay resulted from multiple change orders submitted by the Hotel. Countering that
argument, the Hotel claims delays resulted from “FTJC’s failure to timely order materials, failure
to properly process and approve change orders, and failure to schedule roof work.” Provisions of
the contract for the Project are relevant to this dispute.
The Contract
The agreement between the parties was titled “Cost of the Work Plus a Fee with a
Negotiated Guaranteed Maximum Price Construction Agreement between Owner and Builder.”
The architect on the Project was identified on the first page of the agreement as being Mitchell
Carlson Stone, Inc. (hereinafter referred to as MCS or the Architect). The second page of that
agreement listed eight documents that, together with the agreement itself, constituted the “Contract
Documents.” The first document listed was titled, “AIA Document A201-1997 edition of the
General Conditions of the Contract for Construction,” published by the American Institute of
Architects.
2 Several of the provisions in Document A201-1997 describe a multi-step dispute resolution
process included within the parties’ agreement. The first of these provisions defined the term
“claim” as “a demand or assertion by one of the parties seeking, as a matter of right, adjustment
or interpretation of Contract terms, payment of money, extension of time or other relief with
respect to the terms of the Contract.” Also included in the definition of the term “claim” is “other
disputes and matters in question between the Owner and Contractor arising out of or relating to
the Contract.” Claims, as that term is defined, were to be initiated by written notice to the Architect
and the other party. Also, it must have been “initiated within 21 days after occurrence of the event
giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving
rise to the Claim, whichever is later.
Claims were to be referred initially to the Architect for decision. After the Architect’s initial
decision, or thirty days after the submission of the claim to the Architect if no decision was made,
claims were then subject to mediation as a condition precedent to arbitration or the initiation of
legal or equitable proceedings. Claims not resolved by mediation were then subject to arbitration.
A demand for arbitration was to be made within a reasonable time after any claim had arisen.
Claims by the Hotel, FTJC, and Jordan Foster
On February 6, 2019, the Hotel initiated litigation by filing its original petition against
FTJC. The Hotel’s petition alleged that the Project was not completed on time due to a number of
failures by FTJC. It also alleged that the Project suffered serious concrete defects, among other
deficiencies claimed. On March 11, 2019, FTJC filed its original answer and a counterclaim
against the Hotel, along with a third-party claim for breach of contract against Jordan Foster, a
concrete subcontractor on the Project. Against the Hotel, FTJC asserted a claim of breach of
3 contract, seeking to foreclose on a mechanic’s lien in the amount of $1,900,000.1 As for the third-
party claim against Jordan Foster, FTJC also asserted a breach of contract claim against it, and
sought indemnification in the event the Hotel established there were concrete deficiencies on the
Project. With its answer to FTJC’s third-party claim, Jordan Foster, in turn, filed a counterclaim
against FTJC for breach of contract and quantum meruit. Months later, Jordan Foster filed a third-
party petition against the Hotel also seeking to foreclose on a mechanic’s lien. The Hotel answered
Jordan Foster’s claim and filed its own counterclaim against Jordan Foster, alleging the
subcontractor’s lien claim against the Hotel was improper. Responding to the initial discovery
requested by FTJC, Jordan Foster served 53,390 pages of documents on all parties to the lawsuit.
The trial court signed the original scheduling order on May 8, 2019, initially setting the case for
trial on June 5, 2020. On August 1, 2019, the Hotel served its first set of requests for admissions
to FTJC.
Jordan Foster and FTJC’s Arbitration Demands
FTJC first demanded arbitration in a letter to counsel for the Hotel, dated September 23,
2019. The letter said, “F.T. James Construction, Inc. hereby demands arbitration pursuant to the
Arbitration Clause contained in the General Conditions.” On September 25, 2019, the Hotel
conducted two depositions solely on the issue of arbitration. The first deposition was of Francisco
Licon, a project manager for third-party defendant Jordan Foster. The second deposition was of
Frank James, the owner of FTJC. During Frank James’ deposition, he testified that he did not know
whether FTJC was making a demand for arbitration; that he did not know if there was a right to
arbitration in the contract between FTJC and the Hotel; that he did not know if FTJC had a
1 FTJC’s counterclaim lists the amount of the mechanic’s lien as “no less than $1,900,000.00.” In their brief before this Court, it identifies the exact amount of $1,963,584.45.
4 preference that the dispute be resolved in the court system or in arbitration; and that he did not
know of any concern about litigating the dispute in the court system.
On November 11, 2019, Jordan Foster filed an amended motion to compel arbitration.2
The motion included a standard subcontract form agreement, entered June 10, 2016, between
Jordan Foster and FTJC. Jordan Foster’s motion to compel arbitration sought to send the entire
case to arbitration based on arbitration clauses found in the contract between it and FTJC, and in
the purported contract between FTJC and the Hotel. Jordan Foster’s motion to compel arbitration
was opposed by the Hotel, but not by FTJC. The Hotel’s opposition was based primarily upon the
fact that there was no direct agreement to arbitrate between Jordan Foster and the Hotel. On
December 20, 2019, by written order, the trial court denied Jordan Foster’s motion to compel
arbitration.
Meanwhile, on November 12, 2019, FTJC sent a letter to MCS—the Project architect—
indicating it sought to submit the dispute for resolution in accordance with the alternative dispute
resolution procedure outlined in AIA Document A201-1997. When MCS did not respond, FTJC
advanced to the next step of the process, demanding mediation with the Hotel, by letter dated
December 20, 2019. On January 7, 2020, the Hotel’s counsel sent a letter to FTJC’s counsel
indicating the letter was intended as a response to FTJC’s letter to MCS, dated November 12, 2019.
Counsel for the Hotel informed FTJC that MCS had been retained as an expert witness in the
lawsuit. Counsel stated, “[o]n October 2, 2019, I met with Keith Carlson and Grant Fisher for an
in-depth discussion of the case; and an engagement letter was fully executed as of October 29,
2019.” In closing, the letter indicated the Hotel contended that FTJC had waived any right under
2 The appellate record does not include any previous motion to compel arbitration filed by Jordan Foster or any other party.
5 the contract to have MCS “decide the validity” of any claims asserted between the parties; and
finally, to the extent certain claims were mentioned in FTJC’s letter of November 12, those claims
had already been determined by the Architect. After all parties agreed to a continuance, the trial
court reset the trial date for December 4, 2020.
On January 29, 2020, FTJC filed its own motion to compel arbitration. Attached to this
motion, FTJC included several exhibits including an affidavit of Frank James asserting the exhibits
were true and correct copies; an exhibit B, identified as copies of pages 1 and 2 of a “Cost of Work
Plus Fee With a Negotiated Guaranteed Maximum Price Construction Agreement Between Owner
and Builder dated May 21, 2016”; and an exhibit C, identified as a copy of “General Conditions
of the Contract of Construction AIA Document A201-1997.”
In response to FTJC’s motion, the Hotel argued that FTJC did not provide the trial court
with an authenticated arbitration agreement and there was no meeting of the minds on an
agreement to arbitrate between itself and FTJC. The Hotel also raised the defenses of waiver and
the impossibility of complete relief amongst the parties through arbitration. In February, while the
parties awaited a hearing on FTJC’s motion to compel arbitration, depositions on written questions
were noticed and cross-questions were propounded on a number of other subcontractors related to
the Project. On February 26, 2020, the trial court held a hearing on the motion to compel, and
signed an order denying said motion on April 1, 2020. The trial court did not enter findings of fact
or conclusions of law along with its order denying the motion.
II. ISSUES ON APPEAL
FTJC raises two issues on appeal: first, it contends the trial court erred in failing to compel
arbitration; and second, it further contends the trial court erred by concluding that at least one of
the defenses raised by the Hotel was valid. Raising three arguments in response, the Hotel first
6 contends that FTJC failed to establish the terms of the parties’ contract by offering “scant
evidence” at the hearing on its motion to compel arbitration; second, the Hotel contends that, even
if an arbitration clause was part of the parties’ contract, FTJC impliedly waived any right to
arbitrate by extensively engaging in the litigation process; and third and finally, the Hotel contends
the record establishes under these circumstances that an arbitration cannot afford complete relief
to the parties.
III. STANDARD OF REVIEW
The denial of a motion to compel arbitration is reviewed for an abuse of discretion. Henry
v. Cash Biz, LP, 551 S.W.3d 111, 115 (Tex. 2018); Perry Homes v. Cull, 258 S.W.3d 580, 598
(Tex. 2008). In doing so, we defer to the trial court on factual determinations that are supported by
the evidence but review its legal determinations de novo. Henry, 551 S.W.3d at 115. Here, the trial
court did not issue findings of fact or conclusions of law to explain its denial of the motion to
compel arbitration. We must, therefore, uphold the trial court’s decision on any appropriate legal
theory urged below. See Bonded Builders Home Warranty Ass’n of Texas v. Rockoff, 509 S.W.3d
523, 531–32 (Tex. App.—El Paso 2016, no pet.). Because the trial court would err if it denied a
motion to compel arbitration on a ground not raised by the resisting party, we may affirm the trial
court’s refusal to compel arbitration only if one of the grounds presented by the resisting party is
valid. APC Home Health Servs., Inc. v. Martinez, 600 S.W.3d 381, 389 (Tex. App.—El Paso 2019,
no pet.).
At the outset, we particularly note in their briefing of this appeal, the parties heavily dispute
whether or not FTJC proved the existence of an agreement to arbitrate based on the record evidence
presented to the trial court. FTJC contends it not only proved the existence of such agreement, but
also that it proved the parties’ dispute fell within the scope of that agreement. The Hotel responds,
7 however, that FTJC presented almost no evidence at the motion to compel hearing, and
consequently, it proved nothing of the existence of a valid arbitration agreement. Specifically, the
Hotel contends FTJC offered no documents into evidence and it called no witnesses to testify.
Instead, the Hotel contends that FTJC relies on evidence presented at a prior hearing that is not
properly part of the record of this appeal. Due to the contentious nature of these arguments over
the scope of the record, we initially assume without deciding, that FTJC offered sufficient evidence
to prove the existence of an arbitration agreement.
With this assumption in place, we move forward to otherwise consider the Hotel’s defense
to arbitration, that is, that the trial court impliedly found FTJC waived its right to arbitrate by its
litigation conduct.
IV. WAIVER
As a defense to FTJC’s motion to compel arbitration, the Hotel contends that FTJC waived
arbitration by invoking the judicial process and it was prejudiced by that conduct.
A. The law governing waiver
Whether a party has waived arbitration by litigation conduct that is detrimental to the other
party is a question of law, which we review de novo. Perry Homes, 258 S.W.3d at 598; see also
Ellman v. JC Gen. Contractors, 419 S.W.3d 516, 520 (Tex. App.—El Paso 2013, no pet.). “[A]
party waives an arbitration clause by substantially invoking the judicial process to the other party’s
detriment or prejudice.” Perry Homes, 258 S.W.3d at 589–90. Public policy favors the
enforcement of contracts, including those related to arbitration, therefore the law imposes a strong
presumption against waiver. See In re Bruce Terminix Co., 988 S.W.2d 702, 704 (Tex. 1998) (orig.
proceeding) (per curiam). The presumption, however, is rebuttable. See Perry Homes, 258 S.W.3d
at 590.
8 When the underlying facts are undisputed, waiver of an arbitration is a matter of law subject
to de novo review on appeal. G.T. Leach Builders, LLC v. Sapphire V.P., LP, 458 S.W.3d 502,
511 (Tex. 2015). The party asserting waiver bears the burden of proof. In re Bruce Terminix Co.,
988 S.W.2d at 705. “To decide whether a waiver has occurred, the court focuses on the actions of
the person who held the right; the court seldom considers the effects of those actions on the
opposing party. That analysis applies to the waiver of a contractual right, as of any other.” Morgan
v. Sundance, Inc., 142 S. Ct. 1708, 1713 (2022). Whether a party has waived its right to arbitration
depends upon the totality of the circumstances. Perry Homes, 258 S.W.3d at 591. In making this
determination, courts consider a wide variety of factors, including: (1) whether the party asserting
the right to arbitrate is the plaintiff or defendant in the lawsuit; (2) how long the party waited before
seeking arbitration; (3) the reasons for any delay in seeking to arbitrate; (4) whether and when the
movant knew of the arbitration agreement during the period of delay; (5) how much discovery and
other pretrial activity the party seeking to arbitrate conducted before seeking arbitration; (6)
whether the party seeking to arbitrate requested the court to dispose of claims on the merits; (7)
whether the party seeking to arbitrate asserted affirmative claims for relief in court; (8) the amount
of time and expense the parties have expended in litigation; (9) whether the discovery conducted
would be unavailable or useful in arbitration; and (10) when the case was to be tried. See G.T.
Leach Builders, 458 S.W.3d at 512; Perry Homes, 258 S.W.3d at 590–92.
Providing further guidance, the Supreme Court of Texas noted that “no one factor is, by
itself, dispositive.” RSL Funding, LLC v. Pippins, 499 S.W.3d 423, 430 (Tex. 2016). Even so, the
Supreme Court further explained that all of the factors are rarely presented in a single case. Perry
Homes, 258 S.W.3d at 591. Additionally, Perry Homes recognized that “[f]ederal courts have
found waiver based on a few, or even a single one.” Id. (citing, e.g., Restoration Pres. Masonry,
9 Inc. v. Grove Eur. Ltd., 325 F.3d 54, 62 (1st Cir. 2003) (finding three-year delay alone sufficient
to establish waiver); Cabinetree of Wis., Inc. v. Kraftmaid Cabinetry, Inc., 50 F.3d 388, 391 (7th
Cir. 1995) (finding removal to federal court alone sufficient to establish waiver)).
B. Application
1. Did FTJC substantially invoke the judicial process such that it waived its contractual right to arbitration?
Because some of the waiver factors are interrelated with one another, we group them into
three topics: first, those related to the procedural posture of the case; second, those related to
FTJC’s delay in demanding arbitration; and third, those related to discovery, time, and expense.
See G.T. Leach Builders, 458 S.W.3d at 512; Perry Homes, 258 S.W.3d at 590–92.
(a) Factors related to the procedural posture of the case
Factors related to the procedural posture of the case generally consider whether the party
asserting a right to arbitrate sits as a plaintiff or defendant in the lawsuit, whether affirmative
claims for relief were otherwise asserted in the trial court, and whether affirmative requests to
dispose of claims on the merits were ever asserted.
Plaintiff or Defendant
Unquestionably, the Hotel—not FTJC—initiated the lawsuit in the court below, originally
placing FTJC in the position of the defendant. This factor initially weighs against a finding of
waiver because FTJC did not—at least at the outset—choose to litigate the dispute in court. See
Perry Homes, 258 S.W.3d at 591 (citing Grumhaus v. Comerica Sec., Inc., 223 F.3d 648, 650 (7th
Cir. 2000)). To the extent we consider FTJC’s initial position as the defendant, we must also keep
in mind that it became a counterclaimant against the Hotel and a third-party plaintiff against Jordan
Foster, then a completely new party to the litigation. The Supreme Court of Texas warns about
placing undue importance on a party sitting as a plaintiff who filed suit because “Texas procedure
10 . . . contemplates that parties may file suit in order to compel arbitration.” Perry Homes, 258
S.W.3d at 592 (citing TEX. CIV. PRAC & REM. CODE ANN. § 171.021(a) (“A court shall order the
parties to arbitrate on application of a party showing: (1) an agreement to arbitrate; and (2) the
opposing party’s refusal to arbitrate.”)).
Affirmative claims for relief
Here, FTJC’s counterclaim and third-party petition are examples of it asserting affirmative
claims for relief contrary to a desire to arbitrate. By making its counterclaim, and especially by
bringing in Jordan Foster, who ultimately made its own claim against the Hotel, FTJC invoked the
jurisdiction of the court and of the judicial process. See Perry Homes, 258 S.W.3d at 592. We
determine this factor to weigh in favor of a finding of waiver.
Motions for disposition on the merits
It is undisputed that FTJC did not file any dispositive motions in this case. However, the
Hotel argues under this factor that FTJC did file pleadings asking the trial court to limit its liability,
including its third-party petition and a Motion for Leave to Designate Responsible Third Parties,
in which it listed seven people or entities it blamed for defects and delays. We take note of the
Hotel’s argument, including the fact that FTJC’s Motion for Leave to Designate Responsible Third
Parties was filed after it had claimed a right to arbitration. However, this factor asks whether FTJC
filed any dispositive motions. They have not, and so this factor weighs against a finding of waiver.
(b) Factors related to FTJC’s delay in demanding arbitration
The factors related to FTJC’s delay in demanding arbitration are how long FTJC waited
before seeking arbitration, when the case was to be tried, whether and when FTJC knew of the
arbitration agreement during the period of delay, and the reasons for any delay in seeking
11 How long FTJC waited & when the case was set for trial
The Hotel filed this case on February 6, 2019. FTJC first claimed a right to arbitration in a
letter to the Hotel dated September 23, 2019. It then waited until January 29, 2020 to file its motion
to compel arbitration. Thus, FTJC did not first claim a right to arbitration until seven-and-a-half
months after the initiation of the lawsuit, and it did not file its motion to compel arbitration until
just shy of one year after the lawsuit began.
The trial in this case was initially set on June 5, 2020. However, on a motion for
continuance filed by Jordan Foster, and the agreement of counsel, the setting was vacated by order
dated January 29, 2020, and the trial date was reset for December 4, 2020. On the same date as
that agreed order, FTJC filed its motion to compel arbitration. This means FTJC filed its motion
to compel arbitration just over ten months prior to the trial date. While ten months can hardly be
considered the “eve of trial,”3 this factor, combined with the length of delay in filing a motion to
compel arbitration, creates a rule of proportion wherein the time between the initiation of the
lawsuit and the filing of the motion to compel arbitration is compared to the time between the
motion to compel arbitration and the trial date. See id. at 596; In re Vesta Ins. Grp., Inc., 192
S.W.3d 759, 764 (Tex. 2006) (citing Com-Tech Assocs. v. Computer Assocs. Int’l, Inc., 938 F.2d
1574, 1576–77 (2d Cir. 1991) (where arbitration was waived when request did not come until 18
months after filing and 4 months before trial)). Here, we compare the almost twelve months
between the initiation of the lawsuit and FTJC’s motion to compel arbitration with the ten months
remaining until the trial date. We conclude that these two factors, when taken together, weigh
slightly in favor of a finding of waiver. See Hogg v. Lynch, Chappell & Alsup, P.C., 480 S.W.3d
3 Perry Homes, 258 S.W.3d at 584 (filing motion to compel arbitration four days before trial date was considered the “eve of trial”).
12 767, 773 (Tex. App.—El Paso 2015, no pet.) (party waited three months after beginning discovery
and less than four months before the trial setting to seek arbitration); Truly Nolen of Am., Inc. v.
Martinez, 597 S.W.3d 15, 22 (Tex. App.—El Paso 2020, pet. denied) (case had already been set
for trial after both parties made such a request before motion for arbitration was filed several
months later).
The reasons for any delay in seeking to arbitrate
FTJC claims that the reason for the delay in seeking arbitration is that it did not know about
the arbitration clause. We find this argument to be problematic for FTJC for two reasons. First, as
evidence for it not knowing about the arbitration clause, FTJC cites to the deposition of Frank
James, where he testified that he did not even know—during the deposition—if there was a right
to arbitrate between FTJC and the Hotel. The deposition, however, was taken on September 25,
2019, or two days after FTJC had first requested arbitration with the Hotel. Second, to the extent
Frank James did not know the contents of the agreement with the Hotel, that failure does not excuse
FTJC from acting inconsistently with its right to seek arbitration. We presume a party, like FTJC,
who has the opportunity to read a contract containing an arbitration agreement and signs it, knows
its contents. See EZ Pawn Corp. v. Mancias, 934 S.W.2d 87, 90 (Tex. 1996). Moreover, FTJC and
the Hotel are both sophisticated parties and there is no evidence of unequal bargaining power in
favor of the Hotel. We conclude that this factor weighs in favor of a finding of waiver.
Whether and when the party seeking arbitration knew of the agreement
As stated above, the record is clear that FTJC actually knew of the agreement by
September 23, 2019, despite Frank James’ assertions two days later that he still did not know of
the arbitration clause. At Frank James’ deposition, the opportunity was afforded—if FTJC wanted
to arbitrate—for it to state unequivocally that a valid arbitration agreement existed between the
13 parties and it was demanding arbitration. In fact, arbitration was the sole subject of the deposition,
as the deposition had been scheduled only two days after FTJC’s attorney sent a letter to the Hotel
regarding arbitration. Yet, when testifying at the deposition, FTJC’s owner said he did not know
whether a contractual right to arbitration existed in the agreement with the Hotel, nor whether he
preferred arbitration over resolution in the court system.
Additionally, even if September 23 was the first day FTJC realized an agreement to
arbitrate existed, and even if we do not interpret Frank James’ deposition as explicitly waiving
arbitration, there is no explanation for the subsequent four-month delay before filing its motion to
compel arbitration. Presumably, FTJC would argue that it was attempting to fulfill the contractual
prerequisites to arbitration, such as submitting the claim to the Architect and demanding mediation.
But it is not clear that FTJC, as the original defendant in the lawsuit, would have been required to
fulfill those obligations; after all, it was the Hotel that initially made the claims. Even if FTJC was
required to take those steps before filing a motion to compel arbitration, it could have submitted
its claim to the Architect in late September—instead of on November 12, 2019—and then it could
have moved to compel arbitration by late October, which would have been 30 days after
submission of the claim to the Architect. As a result of FTJC’s continued delays, even after it knew
of the arbitration clause, we conclude that this factor weighs in favor of a finding of waiver.
(c) Factors related to discovery, time, and expense
The factors in this category are how much discovery and other pretrial activity the party
seeking to arbitrate conducted before seeking arbitration, whether the discovery conducted would
be unavailable or useful in arbitration, and the amount of time and expense the parties have
expended in litigation.
How much discovery and other pretrial activity FTJC conducted before seeking arbitration
14 Under this factor, the Hotel states that “[t]he parties expended substantial time and expense
in litigation and discovery.” As examples, the Hotel lists FTJC’s counterclaim, its third-party
claim, its motion for leave to designate responsible third parties , and its agreement to consolidate
another party’s claims against it into this lawsuit , all of which are a part of the appellate record.
The Hotel also states that “both FTJC and the Hotel propounded written discovery.” Although the
docket summary does have a number of entries labeled “Certificate of Written Discovery,” we
cannot determine from the record who created the discovery requests, to whom they were directed,
the number of individual requests within each instrument, the substance of those requests, or
whether they were ever responded to. Even so, it is clear that FTJC actively engaged in discovery
as it included requests for disclosure to the Hotel and Jordan Foster as a part of its counterclaim
and third-party claim, respectively.
Jordan Foster served 53,390 pages of documents to counsel for all parties. Because it is
unclear whose discovery request Jordan Foster’s production was in response to, we cannot say that
FTJC was directly responsible for the production, but we do note the Hotel’s argument that Jordan
Foster would not necessarily be a part of this litigation but for FTJC’s third-party claim. FTJC
filed a motion for protective order regarding 346 Requests for Admission sent by the Hotel. The
parties agree that no oral depositions on the merits have been taken.
This factor requires us to analyze how much discovery and other pre-trial activity FTJC
actually conducted before seeking arbitration. In our view, the record does not prove extensive
discovery was conducted by FTJC. We also cannot say FTJC’s filing of an answer or even a
counterclaim against the Hotel rises to the level of substantially invoking the judicial process. See
G.T. Leach, 458 S.W.3d at 512. However, we do find that FTJC’s third-party claim against Jordan
Foster does rise to that level. By filing an entirely separate claim against an entirely new party,
15 FTJC not only invoked the trial court’s jurisdiction over Jordan Foster, but it opened the door to
Jordan Foster’s eventual direct claim against the Hotel. It also required the Hotel to review any
documents Jordan Foster produced in discovery, which turned out to be 53,390 pages of responses.
We determine that this factor weighs in favor of a finding of waiver.
Whether the discovery would be unavailable or useful in arbitration
Because none of the discovery requests and responses were made a part of the appellate
record, we are unable to determine whether any of the discovery would be unavailable or useful in
arbitration. Accordingly, this factor weighs against a finding of waiver.
Time and expense
In response to FTJC’s motion to compel arbitration, the Hotel presented the trial court with
an affidavit of Jim Scherr, an authorized representative of the Hotel, stating in relevant part that
FTJC’s litigation efforts:
subjected [the Hotel] to many thousands of dollars in legal fees including having to respond to the claims and discovery asserted by Jordan Foster. Because of the affirmative steps FTJC took in invoking the jurisdiction of the Court, Jordan Foster propounded interrogatories, requests for production and disclosures and depositions upon written questions, which [the Hotel] has incurred thousands of dollars of attorneys’ fees in responding.
FTJC argues that the Hotel presented no specific evidence of how much time it had spent on
litigation efforts or what precise expense it incurred. We disagree with FTJC that such a specific
showing is required under this element. See Truly Nolen, 597 S.W.3d at 24; Ellman, 419 S.W.3d
at 522. Considering the almost twelve months that passed between the filing of this lawsuit and
FTJC’s motion to compel arbitration, numerous motions, all of which required briefing, several
hearings, and at least some engagement in discovery, there can be little doubt that the Hotel
incurred significant expenses litigating this case. We determine that this factor weighs in favor of
a finding of waiver.
16 After considering the totality of the circumstances, we conclude that FTJC substantially
invoked the judicial process, thereby waiving its right to arbitrate. See Sedillo v. Campbell, 5
S.W.3d 824, 827 (Tex. App.—Houston [14th Dist.] 1999, no pet.) (“Actions that raise the specter
of waiver may include the applicant’s engaging in some combination of filing an answer, setting
up a counterclaim, pursuing extensive discovery, moving for a continuance and failing to timely
request arbitration.”).
2. Was the Hotel prejudiced?
In Perry Homes, the Supreme Court of Texas further instructs that substantial invocation
of the judicial process alone does not constitute waiver of a right to arbitrate unless the party
opposing arbitration proves that it suffered prejudice as a result. Perry Homes, 258 S.W.3d at 593;
but see Morgan, 142 S. Ct. at 1714 (explaining that “the usual federal rule of waiver does not
include a prejudice requirement”).
Prejudice may be shown by considerable delay, expense, or damage to the nonmovant’s
legal position. See Ellman, 419 S.W.3d at 522. Here, the Hotel has shown that FTJC’s failure to
timely demand arbitration has damaged its legal position. Seeking affirmative relief, FTJC brought
Jordan Foster into the case via a third-party claim; in turn, Jordan Foster subsequently brought a
crossclaim against the Hotel. In short, FTJC’s conduct thrust the Hotel into litigation against a
subcontractor with whom it has no contract at all, much less an agreement to arbitrate. As a result,
if the claims between FTJC and the Hotel are stayed pending arbitration, the end result causes the
Hotel to participate in arbitration with FTJC, and also engage in litigation with Jordan Foster, with
such proceedings addressing the same issues. We agree with the Hotel that this will cause
significant additional time and expense, as well as expose it to the risk of conflicting results arising
from two different forums. See BBX Operating, LLC v. Am. Fluorite, Inc., No. 09-17-00245-CV,
17 2018 WL 651276, at *8 (Tex. App.—Beaumont Feb. 1, 2018, no pet.) (memo. op.).
Additionally, we agree with the Hotel that it has been prejudiced by the time and expense
already incurred during the course of the litigation so far, including during the four months between
when FTJC absolutely knew about the arbitration clause and when it filed its motion to compel
arbitration. First, while FTJC delayed, the Hotel discussed the dispute “in-depth” with MCS—the
Project architects—and then hired them as expert witnesses. This fact made it impossible for the
parties to then execute the dispute resolution process to its full intended effect; the first step in the
process as outlined in AIA Document A201-1997 requires the dispute to be submitted to the
Architect—presumably as a neutral party—for decision. And second, the Hotel presented the trial
court with an affidavit of its authorized representative stating that the Hotel had incurred “many
thousands of dollars in legal fees including having to respond to the claims and discovery asserted
by Jordan Foster.” As we stated earlier, the party opposing arbitration is not always required to
show the specific cost of litigation in order to prove prejudice. See Perry Homes, 258 S.W.3d at
599–600.
Based on the totality of the circumstances, we conclude that—even after assuming without
deciding there was a valid arbitration clause between FTJC and the Hotel—FTJC has waived its
right to arbitrate by substantially invoking the judicial process such that this conduct prejudiced
the Hotel. See Truly Nolen, 597 S.W.3d at 26; Ellman, 419 S.W.3d at 519. Thus, we overrule
FTJC’s second issue.
As a result of this determination, we do not reach either FTJC’s issue asserting it
established the existence of an arbitration agreement, or the Hotel’s defensive argument
contending that complete relief cannot be afforded to the parties through arbitration. See TEX. R.
APP. P. 47.1.
18 V. CONCLUSION
We affirm the trial court’s order denying FTJC’s motion for arbitration.
GINA M. PALAFOX, Justice September 28, 2022
Before Rodriguez, C.J., Palafox, and Alley, JJ.