McAlvay, J.
Plaintiff in 1904 contracted in writing with the American Arithmometer Company to do the mason work in the construction of a factory in Detroit, according to plans and specifications of the architect, for the sum of $19,769. Defendant is the successor of the American Arithmometer Company, and as such responsible for any judgment plaintiff may recover. During the construction certain changes from the original plans and specifications were ordered and directed to be performed by the architect, which were made by plaintiff with the knowledge of the superintendent of construction. After certain delays caused by the owner not securing certain material, the work under plaintiff’s contract was completed, shortly before which time plaintiff was taken seriously ill. During the prosecution of the work, plaintiff, [127]*127by reason of delays and losses caused by the company, was unable to pay for some of the materials which were used in the construction of the building, and several mechanics’ liens were filed. Later foreclosure proceedings of one of these liens were begun. Plaintiff was also sued by one of his creditors in justice’s court, and the defendant company garnished, and on an appeal by plaintiff the president of the company signed his appeal bond. Under these circumstances, and while plaintiff was confined to his house by sickness, and was not present at any meetings between the attorneys for the parties and defendant’s agents, the following agreement in writing was made and executed
“An agreement made by and between the C. H. Little Company of the first part, and the American Arithmometer Company of the second part, and George W. Fisher of the third part, under date of May 19, 1905, was duly proven and introduced in evidence by the defendant and marked Exhibit G. and is as follows:
“It is hereby agreed by and between the C. H. Little Co., of the first part, the American Arithmometer Company of the second part, and George W. Fisher of the third part, as follows:
“ Whereas, there is a balance owing to the third party from the second party of $6,211.05 for materials furnished and labor performed in construction of the second party’s factory at the corner of Second and Amsterdam avenues, Detroit, Michigan; and, whereas, liens have been filed upon said factory premises by the following parties for materials and labor furnished to said Fisher for the amounts set opposite their respective names, to wit:
“Trussed Concrete Steel Co...................... $236 16
Philip Carey Mfg. Co........................... 264 95
The C. H. Little Co............................. 3,672 81
Michigan Pressed Brick Co_____________________ 677 50
Garner Bros.................................... 24 50
Larkins Brick Co..........-....._.............. 1,207 50.
Sheehan Artificial Stone Co. __.................. 308 75
Elmer Jones.......................-........... 1,524 72
E. B. Holmes & Co.........-___________________ 823 43
$8,739 32
[128]*128—and a suit at law has been commenced and is now pending on appeal in the circuit court for the county of Wayne by said Sheehan Artificial Stone Company against said Fisher for the same claim for which it has filed said lien, one Joseph Boyer, a stockholder in said American Arithmometer Company, being surety on the appeal bond; and, whereas, it is represented by the first and third parties that the liens of the following parties may be settled for the amounts set opposite their respective names, to wit:
“Trussed Concrete Steel Co...................... $100 00
Philip Carey Mfg. Co__________________________ 200 00
The C. H. Little Co_____________________________ 2,194 41
Michigan Pressed Brick Co...................... . 474 25
Larkins Brick Co________________________________ 1,107 50
Garner Bros.___________________________________ 14 70
$4,090 86
—and, whereas, it is represented by the said Fisher that good defense exists to the remaining lien claims and the said suit at law or to some part thereof:
“It is agreed by the respective parties, the agreement of each being in consideration of the agreements of the others as follows:
“Said the C. H. Little Company agrees:
“1. To protect and save harmless said American Arithmometer Company from all loss, costs, damages and expense on account of or by reason of any and all of the said lien claims hereinbefore referred to and all litigation thereon, and of the settlement of the claims whereof the settlement is hereby contemplated.
“3. To assume and carry on at its own expense the defense of said suit at law and of all of the lien claims hereinbefore mentioned until final adjudication or settlement thereof and to pay any amount necessary to effect a discharge and satisfaction of record of said suit, and of all of said claims as finally determined by adjudication or settlement in excess of the amount of $5,961.05, hereinafter provided to be paid from the fund in the second party’s hands.
‘ ‘ The second party agrees:
“1. To purchase the lien claims of the following named parties at the amounts set opposite their respective names if settlement can be effected at said amounts, paying [129]*129therefor from the said balance owing to third party hereto, to wit:
“ Trussed. Concrete Steel Co...........-....... 5100 00
Philip Carey Mfg. Co________________________ 200 00
The C. H. Little Co..........'............... 2,194 41
Garner Bros................................. 14 70
Michigan Pressed Brick Co................... 474 25
Larkins Brick Co............................ 1,107 50
54,090 86
—taking assignments of the claims settled in the name of some person selected by itself which assignments shall be held for the purposes hereinafter provided.
“2. To pay W illard E. W arner, attorney for said Fisher, the sum of $250.00 from said balance owing third party, this payment being made by direction of the first and third parties and for services performed for the third party.
“3.
Free access — add to your briefcase to read the full text and ask questions with AI
McAlvay, J.
Plaintiff in 1904 contracted in writing with the American Arithmometer Company to do the mason work in the construction of a factory in Detroit, according to plans and specifications of the architect, for the sum of $19,769. Defendant is the successor of the American Arithmometer Company, and as such responsible for any judgment plaintiff may recover. During the construction certain changes from the original plans and specifications were ordered and directed to be performed by the architect, which were made by plaintiff with the knowledge of the superintendent of construction. After certain delays caused by the owner not securing certain material, the work under plaintiff’s contract was completed, shortly before which time plaintiff was taken seriously ill. During the prosecution of the work, plaintiff, [127]*127by reason of delays and losses caused by the company, was unable to pay for some of the materials which were used in the construction of the building, and several mechanics’ liens were filed. Later foreclosure proceedings of one of these liens were begun. Plaintiff was also sued by one of his creditors in justice’s court, and the defendant company garnished, and on an appeal by plaintiff the president of the company signed his appeal bond. Under these circumstances, and while plaintiff was confined to his house by sickness, and was not present at any meetings between the attorneys for the parties and defendant’s agents, the following agreement in writing was made and executed
“An agreement made by and between the C. H. Little Company of the first part, and the American Arithmometer Company of the second part, and George W. Fisher of the third part, under date of May 19, 1905, was duly proven and introduced in evidence by the defendant and marked Exhibit G. and is as follows:
“It is hereby agreed by and between the C. H. Little Co., of the first part, the American Arithmometer Company of the second part, and George W. Fisher of the third part, as follows:
“ Whereas, there is a balance owing to the third party from the second party of $6,211.05 for materials furnished and labor performed in construction of the second party’s factory at the corner of Second and Amsterdam avenues, Detroit, Michigan; and, whereas, liens have been filed upon said factory premises by the following parties for materials and labor furnished to said Fisher for the amounts set opposite their respective names, to wit:
“Trussed Concrete Steel Co...................... $236 16
Philip Carey Mfg. Co........................... 264 95
The C. H. Little Co............................. 3,672 81
Michigan Pressed Brick Co_____________________ 677 50
Garner Bros.................................... 24 50
Larkins Brick Co..........-....._.............. 1,207 50.
Sheehan Artificial Stone Co. __.................. 308 75
Elmer Jones.......................-........... 1,524 72
E. B. Holmes & Co.........-___________________ 823 43
$8,739 32
[128]*128—and a suit at law has been commenced and is now pending on appeal in the circuit court for the county of Wayne by said Sheehan Artificial Stone Company against said Fisher for the same claim for which it has filed said lien, one Joseph Boyer, a stockholder in said American Arithmometer Company, being surety on the appeal bond; and, whereas, it is represented by the first and third parties that the liens of the following parties may be settled for the amounts set opposite their respective names, to wit:
“Trussed Concrete Steel Co...................... $100 00
Philip Carey Mfg. Co__________________________ 200 00
The C. H. Little Co_____________________________ 2,194 41
Michigan Pressed Brick Co...................... . 474 25
Larkins Brick Co________________________________ 1,107 50
Garner Bros.___________________________________ 14 70
$4,090 86
—and, whereas, it is represented by the said Fisher that good defense exists to the remaining lien claims and the said suit at law or to some part thereof:
“It is agreed by the respective parties, the agreement of each being in consideration of the agreements of the others as follows:
“Said the C. H. Little Company agrees:
“1. To protect and save harmless said American Arithmometer Company from all loss, costs, damages and expense on account of or by reason of any and all of the said lien claims hereinbefore referred to and all litigation thereon, and of the settlement of the claims whereof the settlement is hereby contemplated.
“3. To assume and carry on at its own expense the defense of said suit at law and of all of the lien claims hereinbefore mentioned until final adjudication or settlement thereof and to pay any amount necessary to effect a discharge and satisfaction of record of said suit, and of all of said claims as finally determined by adjudication or settlement in excess of the amount of $5,961.05, hereinafter provided to be paid from the fund in the second party’s hands.
‘ ‘ The second party agrees:
“1. To purchase the lien claims of the following named parties at the amounts set opposite their respective names if settlement can be effected at said amounts, paying [129]*129therefor from the said balance owing to third party hereto, to wit:
“ Trussed. Concrete Steel Co...........-....... 5100 00
Philip Carey Mfg. Co________________________ 200 00
The C. H. Little Co..........'............... 2,194 41
Garner Bros................................. 14 70
Michigan Pressed Brick Co................... 474 25
Larkins Brick Co............................ 1,107 50
54,090 86
—taking assignments of the claims settled in the name of some person selected by itself which assignments shall be held for the purposes hereinafter provided.
“2. To pay W illard E. W arner, attorney for said Fisher, the sum of $250.00 from said balance owing third party, this payment being made by direction of the first and third parties and for services performed for the third party.
“3. On the adjustment of any of the remaining lien claims on terms satisfactory to the first and third parties or upon final adjudication thereof, to pay the same from the balance of said amount owing to third party hereto but not otherwise after making the payments provided for in clauses 1 and 2 of this paragraph, taking an assignment thereof in like manner as above provided, it being understood that the suit at law and the lien suit of said Sheehan Company must be settled together.
“4. To assign to the first party a certain bond executed by the third party to the second party wherein the American Bonding Company is surety and to pay over to the first party whatever remains of said amount owing to said third party when either upon settlement or final adjudications the claim set up in said suit at law and all claims of lien and all judgments and decrees that may be rendered therein are satisfied and discharged of record.
“ Said Fisher agrees:
“1. That he will render all assistance in his power in the settlement of the claims, the settlement whereof is hereby contemplated, and in the defense of all claims not settled.
“2. That he approves and consents to the disposition of said funds in the hands of the American Arithmometer Company and all the arrangements hereby contemplated.
“It is mutually agreed that the assignments of any [130]*130claims settled shall be presented in the litigation over the unsettled claims of lien in order that they may be allowed and included in any decree that may be rendered, to the end that the parties hereto may be protected so far as possible against the unsettled claims, the expense, however, of presenting and securing the allowance of such assigned claims to be borne by the first party.
“ In witness whereof, the first and second parties have caused this instrument to be executed by the hands of their respective president, and the third party has hereunto set his hand this 19th day of May, 1905.
[Signed] “The C. H. Little Co.,
“ By O. H. Little, Prest, and Geni. Manager.
[Signed] “ American Arithmometer Company,
“By Joseph Boyer, President.
[Signed] “George W. Fisher.”
Under this agreement defendant company disbursed the sum stated according to its terms. Later plaintiff sued defendant company in assumpsit for a balance claimed to be due under his building contract, including materials and labor furnished and performed for extras in excess of the contract price, also averring that the amount stated in the agreement of May 19, 1905, as a balance owing him, was not the correct amount, but was arrived at by wrongfully deducting certain amounts on account of construction and material fraudulently represented by defendant to be defective and unfit. Upon the trial the court directed a verdict in favor of defendant, on the ground that the agreement of May 19, 1905, stated a balance as agreed upon between the parties in adjusting their accounts. No evidence was offered by defendant.
The case is before us for review upon writ of error. The material assignment of error necessary to be considered is upon the action of the court in directing a verdict. The determination of this question depends upon the construction to be given to the writing of May 19, 1905. It is contended by defendant that it was a settlement and adjustment between plaintiff and defendant of their differences arising out of the building contract, reduced to writing, signed by the parties, and is conclusive. That [131]*131there were differences between these parties, and that at the time a large amount of money was still unpaid on this contract, is not disputed. Plaintiff and his attorney both testify that they do not know what was included in the $6,311.05 stated in the writing of May 19, 1905. It also appears that there had never been any settlement or adjustment between plaintiff and defendant, unless the agreement may be so considered. Both parties had presented items for adjustment, plaintiff for extras, and defendant for deductions, and the record shows that both parties now admit that some of these items should be allowed each party. It does not appear what is included in the amount of $6,311.05, admitted by defendant to be owing plaintiff at that time; but it does appear that the sum of $300 was arbitrarily stricken out because of a claim for defective work which must be removed, which has never been done. Plaintiff, who was confined to his house by serious sickness, never took any part in these negotiations. He was represented by his attorney.
It is also urged by defendant that to allow plaintiff to dispute the amount expressed in the agreement would be a fraud upon his creditors. It is apparent that at the time plaintiff did not know the amount he was entitled to. The apparent object of this agreement was to dispose of certain liens on the properly, and a certain lawsuit without loss to defendant. The principal lienor undertook to dispose of the liens and settle the claims out of this amount of $6,311.05, belonging to plaintiff, in defendant’s hands, on condition that he take any amount that was left over, and an assignment of the surety company bond given by plaintiff to defendant as its protection, presumably when the contract was entered into. From the preambles to this contract this appears to have been a safe undertaking on the part of this lienor and justified by the results. It was carried out, and all of these claims were adjusted and settled out of this fund. Plaintiff claims he is entitled to about $1,700, the balance due under his contract. If this had been a matter of mistake by or against either one of [132]*132these parties, under the circumstances, it is clear that either one could recover from the other the amount of the true balance. If brought about by what amounted to a deception or a fraud, plaintiff ought not to be bound by it. It does not appear that any creditor was deceived by the recital that this was the balance owing plaintiff from defendant, and, if such deception of creditors could be charged as resulting therefrom, if plaintiff’s contention is true, defendant, and not he, is chargeable with it. Defendant has been in no way damaged, upon any theory of the case. On the contrary, if plaintiff is right, defendant has profited $1,700 by the transaction.
As between plaintiff and defendant, there can be no estoppel against plaintiff by reason of the recital in the agreement “whereas there is a balance owing to the third party from the second party of $6,211.05.” This recital does not constitute a settlement and adjustment between these parties.
The court was in error in instructing a verdict for defendant.
The judgment will be reversed, and a new trial ordered.
Blair, C. J., and Grant, Montgomery, and Hooker, JJ., concurred.