J-S02024-20
NON-PRECEDENTIAL DECISION - SEE SUPERIOR COURT I.O.P. 65.37
COMMONWEALTH OF PENNSYLVANIA : IN THE SUPERIOR COURT OF : PENNSYLVANIA Appellee : v. : : WILLIAM RONCASE : : Appellant : No. 797 MDA 2019
Appeal from the Judgment of Sentence Entered April 16, 2019 In the Court of Common Pleas of York County Criminal Division at No(s): CP-67-CR-0006228-2018
BEFORE: BENDER, P.J.E., KING, J., and MUSMANNO, J.
MEMORANDUM BY KING, J.: FILED FEBRUARY 20, 2020
Appellant, William Roncase, appeals from the judgment of sentence
entered in the York County Court of Common Pleas, following his bench trial
convictions for theft by deception, theft by failure to make required disposition
of funds received, and home improvement fraud.1 We affirm.
The trial court opinion accurately set forth the relevant facts and
procedural history of this case as follows:
Factual History
In early 2017, [Victim’s] ex-husband asked her to hire a contractor to renovate a property that he owned at 1512 East Market Street, York, Pennsylvania. This was to be an extensive project; the office space on the first floor of the property and the two apartments on the second floor needed to be completely gutted and redone, and the columns on the outside of the property needed to be replaced. [Victim] knew [Appellant] through a co-worker ____________________________________________
1 18 Pa.C.S.A. §§ 3922(a)(1), 3927(a); 73 P.S. § 517.8(a)(2), respectively. J-S02024-20
and had knowledge of prior contracting work that he had done. [Victim] went to the property with [Appellant] to show him what work needed to be completed and to make sure that [Appellant] would be able to do the work. Based on her prior knowledge of [Appellant’s] work and the walk through of the property, [Victim] believed that [Appellant] was experienced and would be able to complete the renovations at the East Market Street property.
On September 8, 2017, [Appellant] provided [Victim] with an estimate for the project. The estimate described some of the work that needed to be completed, the cost for materials, and the cost for labor. The estimated total was $31,500. There was also a notation from [Appellant] stating the amount that was paid as a down payment.
[Victim] paid [Appellant] $1,000 on September 8, 2017, to start. Between September 8, 2017 and January 12, 2018, [Victim] paid [Appellant] a total of $19,392. Receipts were written out for each payment. Some receipts specifically said what they were for, e.g., on September 15, 2017 [Victim] paid [Appellant] $1,900 for floors. Most of the receipts just have the date and an amount.
A receipt from January 12, 2018 shows two amounts, $150 and $142, for building permits. However, Detective Hott testified that during his investigation he checked with Spring Garden Township and there were no building permits for 1512 East Market Street. …
In September, [Appellant] told [Victim] the project would take two months. In March hardly any work had been completed. Faucets, bathroom vanities, kitchen cabinets, and toilets were purchased with money provided by [Victim]. [Appellant] allegedly returned one of the bathroom vanities because it had a chip in it. When [Victim] went back to the property the rest of the above items were missing. When she asked [Appellant] about the missing items he told her that he put the rest in his shed for “safekeeping.” [Victim] never saw the items again and they ultimately needed to be repurchased. [Appellant] pulled out old radiators from the home and sold the metal as scrap; the monies for which were never given to [Victim]. By February, [Appellant] stopped answering calls and text
-2- J-S02024-20
messages from [Victim]. In March of 2018, with little work having been completed, the property in worse shape than it was when he started, and property missing[, Victim] finally got the police involved.
Procedural History
On March 29, 2018[,] a report of Home Improvement Fraud was generated with Spring Garden Township Police. On April 13, 2018[,] Detective Hott had an initial informational meeting with [Victim]. On April 10, 2018, [Detective] Hott met [Victim] at the East Market Street property and was able to see the lack of work that had been completed by [Appellant]. [Detective] Hott directed [Victim] to send a letter to [Appellant] via certified mail stating that the work had not been done and requesting a refund; this was sent on April 25, 2018. [Victim] received no response to her letter.
On May 23, 2018, Detective Hott filed a criminal complaint against [Appellant]. Initially, [Appellant] was charged with one count of Theft by Deception, and two counts of Home Improvement Fraud. One count of Theft by Failure to Make Required Disposition of Funds Received was added at trial. [Appellant] was arrested on July 3, 2018. A pre-trial conference was held on February 20, 2019[,] during which the case was set for a nonjury trial on April 1, 2019 before the Honorable Harry M. Ness.
The nonjury trial was held as scheduled. At the conclusion of the Commonwealth’s case, [Appellant] moved for judgment of acquittal. The [c]ourt did not grant [Appellant’s] motion [to dismiss all charges but] did dismiss count two. Defense Counsel did submit a Memorandum of Law in Support of [Appellant’s] Motion for Judgment of Acquittal. The Trial Court scheduled a hearing for April 11, 2019, allowing ten days for a reserved decision.
On April 11, 2019, the trial court denied [Appellant’s] motion and he was found guilty of count one, Theft by Deception, count three Home Improvement Fraud, and count four, Theft by Failure to Make Required Disposition of Funds. On April 16, 2019, [Appellant] was sentenced in count one[,] to three years’ probation, in count three to
-3- J-S02024-20
three years’ probation, and in count four to three years’ probation; these probationary sentences are to run concurrently with each other. [Appellant] was ordered to pay restitution in the amount of $19,392 [to Victim] in equal monthly installments over the probationary period. As a condition of probation, [Appellant] is to be employed, in a business other than the home improvement business, and work at least 35 hours a week.
On May 14, 2019[,] a Notice of Appeal was filed. This [c]ourt filed a Direction to Appellant to File a Statement of [Errors] Complained of Pursuant to Pa.R.A.P. 1925(b) on May 17, 2019. The Statement of [Errors] Complained of was filed on June 7, 2019. …
(Trial Court Opinion, filed June 25, 2019, at 1-6) (internal citations and
footnotes omitted).
Appellant raises three issues for our review:
WAS THE EVIDENCE…INSUFFICIENT TO CONVICT [APPELLANT] OF THEFT BY FAILURE TO MAKE REQUIRED DISPOSITION OF FUNDS RECEIVED WHERE TAKING MONEY ON A CONSTRUCTION AGREEMENT IS NOT TAKING PROPERTY “OF ANOTHER” AND THERE WAS NO SPECIFIC AGREEMENT AS TO DISPOSITION OF ANY PARTICULAR FUNDS?
WAS THE EVIDENCE…SIMILARLY INSUFFICIENT TO SHOW THEFT BY DECEPTION WHERE [APPELLANT] DID NOT OBTAIN OR WITHHOLD ANY MONEY THROUGH FALSE STATEMENTS?
WAS THE EVIDENCE ALSO INSUFFICIENT TO ESTABLISH HOME IMPROVEMENT FRAUD WHERE THE LOOSE AGREEMENT BETWEEN [APPELLANT] AND [VICTIM] SPECIFIED NO COMPLETION DATES FOR ANY DISCRETE PORTIONS OF THE PROJECT OR FOR PROVISION OF MATERIALS?
(Appellant’s Brief at 4).
A challenge to the sufficiency of the evidence implicates the following
-4- J-S02024-20
legal principles:
The standard we apply in reviewing the sufficiency of the evidence is whether viewing all the evidence admitted at trial in the light most favorable to the verdict winner, there is sufficient evidence to enable the fact-finder to find every element of the crime beyond a reasonable doubt. In applying [the above] test, we may not weigh the evidence and substitute our judgment for the fact-finder. In addition, we note that the facts and circumstances established by the Commonwealth need not preclude every possibility of innocence. Any doubts regarding a defendant’s guilt may be resolved by the fact-finder unless the evidence is so weak and inconclusive that as a matter of law no probability of fact may be drawn from the combined circumstances. The Commonwealth may sustain its burden of proving every element of the crime beyond a reasonable doubt by means of wholly circumstantial evidence. Moreover, in applying the above test, the entire record must be evaluated and all evidence actually received must be considered. Finally, the [finder] of fact while passing upon the credibility of witnesses and the weight of the evidence produced, is free to believe all, part or none of the evidence.
Commonwealth v. Jones, 874 A.2d 108, 120-21 (Pa.Super. 2005) (quoting
Commonwealth v. Bullick, 830 A.2d 998, 1000 (Pa.Super. 2003)).
After a thorough review of the record, the briefs of the parties, the
applicable law, and the well-reasoned opinion of the Honorable Harry M. Ness,
we conclude Appellant’s issues one and two merit no relief. The trial court
opinion comprehensively discusses and properly disposes of Appellant’s first
and second questions presented. (See Trial Court Opinion at 7-17) (finding:
(1) evidence showed Victim hired Appellant as contractor to renovate
property; Victim gave Appellant down payment and 35 subsequent payments
for labor and materials; Appellant did not complete any significant work on
-5- J-S02024-20
project and did not contact Victim to explain his failure to perform work;
Appellant’s excuses at trial for his non-performance were not credible; thus,
Appellant obtained Victim’s property in form of payments, but property
interest in those payments did not transfer to Appellant; additionally, although
Appellant and Victim did not execute written contract, Appellant provided
Victim written estimate for work, Victim paid Appellant for labor and materials,
Appellant and Victim exchanged text messages regarding project, and
Appellant performed minimal work on project; thus, Appellant and Victim had
oral agreement regarding renovation project; evidence was sufficient to
sustain Appellant’s theft by failure to make required disposition of funds
received conviction; (2) evidence showed Appellant did not use money Victim
paid him for project on labor, materials, or permits; Appellant concealed his
whereabouts from Victim, often lied to Victim about his presence at premises,
and ignored her texts and phone calls; Appellant’s minimal work on property
did not justify payments he received from Victim; Victim did not see materials
Appellant claimed he bought for project; Appellant failed to procure building
permits for project; totality of circumstances established Appellant’s intent not
to perform on agreement; thus, Commonwealth presented sufficient evidence
to convict Appellant of theft by deception). The record supports the trial
court’s rationale. See Jones, supra. Therefore, as to Appellant’s first two
issues, we affirm on the basis of the trial court’s opinion.
In his third issue, Appellant argues his September 2017 agreement with
-6- J-S02024-20
Victim did not specify a completion date for the entire project or for any
particular portion of the project. Appellant asserts the agreement also failed
to specify the materials required for the project. Appellant suggests the home
improvement fraud statute requires the terms of a home improvement
agreement to be set forth in a written contract. Appellant asserts that even
if he had originally agreed to complete the project within two months, Victim
acquiesced to an extension because Victim continued to pay Appellant through
February 2018. Appellant concludes the Commonwealth produced insufficient
evidence to sustain his home improvement fraud conviction, and this Court
should reverse that conviction and vacate the judgment of sentence. We
disagree.
The Home Improvement Consumer Protection Act defines the offense of
home improvement fraud, in relevant part, as follows:
§ 517.8. Home improvement fraud
(a) Offense defined.—A person commits the offense of home improvement fraud if, with intent to defraud or injure anyone or with knowledge that he is facilitating a fraud or injury to be perpetrated by anyone, the actor:
* * *
(2) receives any advance payment for performing home improvement services or providing home improvement materials and fails to perform or provide such services or materials when specified in the contract taking into account any force majeure or unforeseen labor strike that would extend the time frame or unless extended by agreement with the owner and fails to return the payment received for such services or materials which were not provided by that date[.]
-7- J-S02024-20
73 P.S. § 517.8(a)(2).
Regarding contract interpretation, “[f]or a contract to be enforceable,
the nature and extent of the mutual obligations must be certain, and the
parties must have agreed on the material and necessary details of their
bargain.” Lackner v. Glosser, 892 A.2d 21, 30 (Pa.Super. 2006) (citing
Peck v. Delaware County Board of Prison Inspectors, 572 Pa. 249, 260,
814 A.2d 185, 191 (2002)). “In cases involving contracts wholly or partially
composed of oral communications, the precise content of which are not of
record, courts must look to surrounding circumstances and course of dealing
between the parties in order to ascertain their intent.” Boyle v. Steiman,
631 A.2d 1025, 1033 (Pa.Super. 1993), appeal denied, 538 Pa. 663, 649 A.2d
666 (1994). “[I]t is the general rule that where no time is agreed upon for
the completion of a contract, it must be completed within a reasonable time
under all the circumstances.” Francis Gerard Janson, P.C. v. Frost, 618
A.2d 1003, 1006 (Pa.Super. 1993).
Further, every commercial contract usually imposes upon each party a
duty of good faith and fair dealing in its performance and its enforcement.
Hanaway v. Parkesburg Group, L.P., 641 Pa. 367, 385-86, 168 A.3d 146,
157 (2017). A party to a contract demonstrates a lack of good faith through,
inter alia, “evasion of the spirit of the bargain, lack of diligence and slacking
off, willful rendering of imperfect performance, abuse of a power to specify
terms, and interference with or failure to cooperate in the other party’s
-8- J-S02024-20
performance.” Stamerro v. Stamerro, 889 A.2d 1251, 1259 (Pa.Super.
2005) (internal citation and quotation marks omitted).
Instantly, the record shows Appellant provided Victim a written estimate
for the renovation project in the amount of $31,500.00 for labor and materials.
On the written estimate, Appellant handwrote: “Received $1,000 to start—9-
8-17.” Victim testified she believed the work would begin on that date.
Appellant told Victim he could complete the job in two months, and Victim said
she would be happy if he finished the work by the end of December 2017.
Nevertheless, Appellant did not finish the work in December 2017.
Instead, Appellant told Victim that he needed additional time to finish the
renovations, so Victim paid Appellant for labor and materials on the project
past December 2017. By March 2018, however, the project remained
incomplete, Appellant had performed only minimal work on the property and
failed to obtain necessary building permits, and Appellant was unresponsive
to Victim’s phone calls and text messages. Additionally, multiple items were
missing from the premises, including pipes and radiators (which were in the
building prior to September 2017), and materials for which Victim had given
Appellant money to purchase for the renovation. Appellant failed to produce
receipts for the purchase of the materials and did not return any of the missing
items.
Based upon the written estimate, as well as the testimony of Victim and
Appellant, the trial court determined Appellant and Victim entered into an oral
-9- J-S02024-20
contract for labor and materials, under which Appellant would start work on
September 8, 2017, and complete the project by the end of December 2017.
The trial court, as fact-finder, was free to credit Victim’s testimony concerning
the terms specified in the oral contract. See Jones, supra. Contrary to
Appellant’s assertion, the home improvement fraud statute does not require
the homeowner to memorialize the terms of a home improvement agreement
in a written contract. See 73 P.S. § 517.8(a)(2). In fact, the statute expressly
contemplates oral home improvement agreements. See 73 P.S. §
517.8(a)(1), (4) (explaining person commits home improvement fraud if, with
intent to defraud or injure anyone or with knowledge that he is facilitating
fraud or injury to be perpetrated by anyone, actor (1) makes false or
misleading statement to induce, encourage or solicit person to enter into any
written or oral agreement for home improvement services or provision of
home improvement materials or to justify increase in previously agreed upon
price; or (4) damages person’s property with intent to induce, encourage or
solicit that person to enter into written or oral agreement for performing home
improvement services or providing home improvement materials).
Further, the fact that Victim paid Appellant beyond December 2017 does
not indicate that Victim “acquiesced” to an unlimited extension of time.
Appellant failed to finish the agreed-upon work and procure the necessary
materials and permits for the project by March 2018. Rather, Appellant
performed only perfunctory work and multiple installations were missing from
- 10 - J-S02024-20
the premises. Appellant also stopped returning Victim’s phone calls and text
messages. Under these circumstances, Appellant’s performance (or lack
thereof) on the contract was not reasonable and failed to demonstrate good
faith and fair dealing. See Hanaway, supra; Stamerro, supra; Francis,
supra. Viewed in the light most favorable to the Commonwealth as verdict
winner, the evidence was sufficient to convict Appellant of home improvement
fraud.2 See Jones, supra. Accordingly, we affirm.
Judgment of sentence affirmed.
Judge Musmanno joins this memorandum.
President Judge Emeritus Bender concurs in the result.
Judgment Entered.
Joseph D. Seletyn, Esq. Prothonotary
Date: 2/20/2020
____________________________________________
2 To the extent Appellant complains the trial court relied improperly upon a non-precedential decision of this Court when it disposed of Appellant’s sufficiency challenge concerning his home improvement fraud conviction, that claim merits no relief. See Commonwealth v. Reese, 31 A.3d 708, 727 (Pa.Super. 2011) (en banc) (stating appellate court may affirm on any basis as long as ultimate decision is correct).
- 11 - Circulated 02/07/2020 12:32 PM .,J,.
.J1
IN THE COURT OF COMMON PLEAS OF YORK COUNTY, PENNSYLVANIA "'·) CRIMINAL DIVISION J1
COMMONWEALTH OF NO. CP-67-CR-6228-2018 •·-' (J) PENNSYLVANIA �-'·
,._.q v. J;:; . r«; •• ] WILLIAM RONCASE, Appellant
OPINION IN SUPPORT OF ORDER PURSUANT TO Pa.R.A.P. 1925(a)
Appellant, William Roncase, appeals to the Superior Court of Pennsylvania
from the judgment of sentence issued by the trial court on April 16, 2019. On May
14, 2019, Appellant filed a Notice of Appeal. Appellant was directed to file a
Concise Statement of Matters Complained of on Appeal. Appellant filed a
Statement of Matters Complained on June 7, 2019. The trial court now issues this
1925(a) Opinion.
In early 2017, Maria Kanellakis' ex-husband asked her to hire a contractor to
renovate a property that he owned at 1512 East Market Street, York,
Pennsylvania.' This was to be an extensive project; the office space on the first
floor of the property and the two apartments on the second floor needed to be
1 Notes of Trial, pg. 18 )l
'.;:, completely gutted and redone, and the columns on the outside of the property
-,_:, needed to be replaced. Kanellakis knew William Roncase through a co-worker and ,.Jl
,-,_., had knowledge of prior contracting work that he had done. Kanellakis went to the C) ,. . ._-,,
,. .D property with Roncase to show him what work needed to be completed and to
\.Fl make sure that Roncase would be able to do the work. Based on her prior
"··.J knowledge of Roncase's work and the walk through of the property, Kanellakis
believed that Roncase was experienced and would be able to complete the
renovations at the East Market Street property.
On September 8, 2017, Roncase provided Kanellakis with an estimate for
the project. 2 The estimate described some of the work that needed to be completed,
the cost for materials, and the cost for labor. The estimated total was $31,500.
There was also a notation from Roncase stating the amount that was paid as a
down payment.
Kanellakis paid Roncase $1,000 on September 8, 2017, to start. Between
September 8, 2017 and January 12, 2018, Kanellakis paid Roncase a total of
$19,392. Receipts were written out for each payment. Some receipts specifically
said what they were for, e.g. on September 15, 2017 Kanellakis paid Roncase
$1,900 for floors.3 Most of the receipts just have the date and an amount.4
2 Commonwealth's Exhibit l 3 Commonwealth's Exhibit 2 4 Commonwealth's Exhibits 3, 4, 5, 6, 7, 8, 9, 10, 11
2 1... n
A receipt from January 12, 2018 shows two amounts, $150 and $142, for ,. ___) 1,fl building permits. However, Detective Hott testified that during his investigation he t-_i (:) checked with Spring Garden Township and there were no building permits for I·--'·
.o 1512 East Market Street. 5 This was really just the tip of the iceberg of Roncase's 11 ' deceitful actions.
In September, Roncase told Kanellakis the project would take two months. u)
C) In March hardly any work had been completed. Faucets, bathroom vanities, l,fl
·-,i kitchen cabinets, and toilets were purchased with money provided by Kanellakis.
Roncase allegedly returned one of the bathroom vanities because it had a chip in it.
When Kanellakis went back to the property the rest of the above items were
missing. When she asked Roncase about the missing items he told her that he put
the rest in his shed for "safekeeping". Kanellakis never saw the items again and
they ultimately needed to be repurchased.6 Roncase pulled out old radiators from
the home and sold the metal as scrap; the monies for which were never given to
Kanellakis. By February, Roncase stopped answering calls and text messages from
Kanellakis.7 In March of 2018, with little work having been completed, the
5 N.T., 123 6 The Trial Court gave Roncase the opportunity to return the items he allegedly kept in his shed to Kanellakis and provide the receipt from the return of the bathroom vanity; the items have still not been returned and no receipt has been provided. 7 N.T., 55
3 (.,}1
C!.) property in worse shape than it was when he started, and property missing o, (·._) Kanellakis finally got the police involved. \Jl
I'-, Procedural History
On March 29, 2018 a report of Home Improvement Fraud was generated
IJl with Spring Garden Township Police. On April 3, 2018 Detective Hott had an
initial informational meeting with Maria Kanellakis. 8 On April 10, 2018, Hott met
--,..J Kanellakis at the East Market Street property and was able to see the lack of work
that had been completed by Roncase.9 Hott directed Kanellakis to send a letter to
Roncase via certified mail stating that the work had not been done and requesting a
refund; this was sent on April 25, 2018.10 Kanellakis received no response to her
letter.
On May 23, 2018, Detective Hott filed a criminal complaint against
Roncase. Initially, Roncase was charged with one count of Theft by Deception11,
and two counts of Home Improvement Fraud.12 One count of Theft by Failure to
Make Required Disposition of Funds Received13 was added at trial.14 Roncase was
arrested on July 3, 2018. A pre-trial conference was held on February 20, 2019
8 N.T. 114 9 N.T. 116 10N.T.118 11 18 Pa. C.S.A. §3922(a)(l) 12 73 P.S. §517.8(a)(2) 13 18 Pa. C.S.A. §3927(a) 14 N.T. 6
4 1.)1
c1 during which the case was set for a non-jury trial on April 1, 2019 before the
r·--' Honorable Harry M. Ness. 1,.J1
�._1 The non-jury trial was held as scheduled. At the conclusion of the
Commonwealth's case, Defense Counsel moved for judgment of acquittal.15 The \,Jt Court did not grant Defense's motionrdid dismiss count two.16 Defense Counsel
did submit a Memorandum of Law in Support of Defendant's Motion for Judgment co J », •• of Acquittal. The Trial Court scheduled a hearing for April 11, 2019, allowing ten �,.:)
days for a reserved decision.
On April 11, 2019, the trial court denied Defendant's motion and he was
found guilty of count one, Theft by Deception, count three Home Improvement
Fraud, and count four, Theft by Failure to Make Required Disposition of Funds.
On April 16, 2019, Defendant was sentenced in count one to three years'
probation, in count three to three years' probation, and in count four to three years'
probation; these probationary sentences are to run concurrently with each other.
Defendant was ordered to pay restitution in the amount of $19,392 to Maria
Kanellakis in equal monthly installments over the probationary period. As a
condition of probation, Defendant is to be employed, in a business other than the
home improvement business, and work at least 35 hours a week.17
t5 N.T. 134 16 N.T. 135 17 Sentencing Hearing Transcript, page 14
5 t_.,·;
•.n On May 14, 2019 a Notice of Appeal was filed. This Court filed a Direction
t·-) to Appellant to File a Statement of Matters Complained of Pursuant to Pa. R.A.P. \Jl
r·-.) 1925(b) on May 17, 2019. The Statement of Matters Complained of was filed on Cl �....:,.
f..C) June 7, 2019. This Opinion Pursuant to 1925(a) now follows.
Issues Raised on Appeal
1. Whether the evidence was sufficient to sustain William Roncase' s conviction for theft by failure to make required disposition of funds so �••._J received. CD 2. Whether the evidence was sufficient to sustain William Roncase's en (:) conviction for theft by deception. 3. Whether the evidence was sufficient to sustain William Roncase's conviction for home improvement fraud.
Discussion
Defense Counsel raises a number of sufficiency of evidence arguments. That
is, the Commonwealth did not present sufficient evidence to meet the elements of
the crimes for which Appellant was convicted.
The standard used to analyze a sufficiency of the evidence claim is as follows: Evidence will be deemed sufficient to support the verdict when it establishes each material element of the crime charged and the commission thereof by the accused, beyond a reasonable doubt. Where the evidence offered to support the verdict is in contradiction to the physical facts, in contravention to human experience and the laws of nature, then the evidence is insufficient as a matter of law. When reviewing a sufficiency claim the court is required to view the evidence in the light most favorable to the verdict winner giving the prosecution the benefit of all reasonable inferences to be drawn from the evidence.18
18 Commonwealth v. Widmer, 744 A.2d 745, 751 (Pa. 2000) (internal citations omitted). 6 {,/)
1.1"1
(:) In proving its case, the Commonwealth may rely solely on circumstantial
t·-.) evidence.19 The Commonwealth "need not preclude every possibility of V1
innocence.v-" If there is doubt about a Defendant's guilt, the doubt "may be resolved
by the fact-finder unless the evidence is so weak and inconclusive that as a matter of
law no probability of fact may be drawn from the combined circumstances.'?' The J:o,. jury, "while passing upon the credibility of witnesses and the weight of the evidence (.{:) ··--.J produced, is free to believe all, part or none of the evidence,"22 and the court "may ,.,);
1--, not weigh the evidence or substitute our judgment for that of the fact-finder."23
1. The evidence was sufficient to sustain William Roncase's conviction for theft by failure to make required disposition of funds received.
The offense of theft by failure to make required disposition of funds
received is comprised of four elements: 1) the obtaining of the property of another;
2) subject to an agreement or known legal obligation upon the receipt to make
specified payments or other disposition thereof; 3) intentional dealing with the
property obtained as the defendant's own; andLf) failure of the defendant to make
the required disposition of the property.24
19 Commonwealth v. Brown, 48 A.3d 426, 430 (Pa. Super. Ct. 2012)(citing Commonwealth v. Markman, 916 A.2d 586, 598 (2007)). 2 ° Id. 21 Commonwealth v. Tejada, 107 A.3d 788, 792 (Pa. Super. Ct. 2015). 22 u. 23 Commonwealth v. Pouliczek, 2015 WL 9594364, *8 (Pa. Super. Ct. 2015)(citing Com. v. Bohonyi, 900 A.2d 877, 881-82 (Pa. Super. Ct. 2006)). 24 Commonwealth v. Morrisey, 654 A.2d I 049, I 052 (Pa. 1995) (citing 18 Pa.C.S. §3927).
7 fl
":) Appellant argues that the first element has not been met. Appellant's
reasoning relies on the Superior Court's decision in Commonwealth v. Austin, 393
A.2d 36, 38 (Pa. Super. 1978). In Austin, The Superior Court held that the
D acceptance of advance money on a construction contract is the property of another.
fl They reasoned that the ownership of the money passed to the defendant and he
could not fraudulently convert his own property. In Austin, the Appellant, a
·...J contractor, was given a down-payment by the homeowners that was to be used
towards material; he was also given a subsequent payment for labor. Once he
received the money Appellant worked on the property for two months, only
discontinuing the project when he realized there was more work than he had
initially anticipated. Id. At 38.
We find the reasoning proffered by the Superior Court in Commonwealth v.
Robichow, 487 A.2d 1000 (Pa. Super. 1985), to be more persuasive. In Robichow,
Appellant entered into an agreement to do home repairs for the victim. Appellant
received an advance payment from the home-owner and then never completed the
repairs. The Superior Court rejected the reasoning in Austin, noting the significant
difference in the fact that Appellant in Austin actually completed work for two
months whereas in Robichow Appellant did not complete any work and did not
contact the homeowner to explain his failure to do the work. Id. at 1003. It was the
8 actual work that was completed in Austin that transformed the money into
.) Appellant's own property . .n
-.) The material facts in the instant case are more similar to Robichow than 7)
D Austin. In the instant case, Appellant did receive an initial down-payment from
.'1 Kanellakis as well as thirty five additional payments, ranging in amounts from
$100 upwards to $2,500. Unlike the appellant in Austin, Roncase did not use the
money to complete work for Kanellakis for two months, or any length of time. At
,).) this point it is unclear what Roncase did with the money he received from
Kanellakis but little of it was spent on the remodeling project he was hired to do.
Like in Robichow, Appellant failed to complete a substantial part of the work.
Additionally, Roncase did not contact Kanellakis to explain his failure to do the
work. It was only when confronted by Kanellakis about the lack of work being
completed that Roncase proffered excuses about why the work was not done; the
Trial Court finds the excuses to lack credibility.
Where a contractor receives a down-payment from a home-owner to
complete a construction project and no significant work is completed on the project
and the contractor makes no effort to contact the homeowner to explain his failure
to do the work, the money does not transfer ownership and is still property of
another. Because Roncase received a down payment, and subsequent payments,
from Kanellakis, failed to work on the project he was hired to do, and did not
9 )1
contact Kanellakis to explain his failure to do the work the property interest in the
......} money was not transferred to Roncase and he therefore obtained the property of
another, fulfilling the first element of the offense.
Appellant also claims that there was no agreement and therefore the second
Ul element of the offense was not met and there was no agreement. Appellant again
relies on Commonwealth v. Austin, in which the second element was met when (1.) �--,J there was a contract and the receipt for the down payment noted that it was for
materials. Id. at 37.We acknowledge that there was no written contract between
Roncase and Kanellakis, but that does not mean that there was no agreement as
required by the statute.
All that is required in the second element of the Failure to Make Required
Disposition of Funds Received statute is an agreement, or known legal obligation.
This has been broadly interpreted in case law. In Commonwealth v. Gallagher, in a
case where the agreement was one for bribery, the Cumberland County Court of
Common Pleas acknowledged that the section applies to all agreements, both legal
and illegal." The Pennsylvania Superior Court has also broadly interpreted what it
means to have an agreement even when there is no written contract. In
Commonwealth v. English, the Superior Court found that there was an agreement
when businesses paid Appellant to publish and print a directory and that agreement
25 Commonwealth v. Gallagher, 6 Pa. D. & C.3d 520, No. 780 Criminal 1977.
10 .•,
l"j
:) was breached when Appellant failed to pay a third party to actually print the n
._) directory.26 In their decision, the Superior Court relied upon the reasoning in rt
._) Commonwealth v. Crafton, in which a travel agent took funds for a chartered trip
D and the participants expected her to use the funds to make arrangements with third
/1 parties.27 When the agent failed to maintain enough to pay for the airline this was .:::.::. found to be a violation of the agreement because she took the money knowing that /) -.. ) she would have to pay for the travel arrangements.28 At the same time, the Superior
Court has not said that anything goes. In Commonwealth v. Wetmore, when
determining whether or not a promise made by the appellee was sufficient to create
an agreement the Superior Court stated that bare words are not enough. 29 This
follows the standards set forth in contract law, in which consideration must be
exchanged for a contract to be valid.
It is clear that the facts in the instant case pass the "bare words" standard
from Wetmore. Like in both English and Crafton, Roncase received money from
-di"� Kanellakis to perform a service. In the instant case, there was norcontrac; There
was, however, a written estimate, a down payment for work, receipts for payments
made by Kanellakis to Roncase for labor and materials for the renovation, and text
messages between Roncase and Kanellakis regarding the project. Additionally,
26 Commonwealth v. English, 597 A.2d 122 (Pa. Super. 1991). 27 Commonwealth v. Crafton, 367 A.2d 1092, 1095 (Pa. Super. 1976). 28 Id. 29 Commonwealth v. Wetmore, 447 A.2d 1012, 1014 (Pa. Super. 1982).
11 t)
n
Roncase did actually perform some work in exchange for the money paid to him
by Kanellakis. Fl
__, Finally, both Defense and Appellate counsel have conceded that there was
.{} an agreement. During trial, Defense Counsel made reference to the agreement
Jl several times: "the sole timeline for Your Honor to look at is my client's intention
at the time this agreement was entered'P"; "Mr. Roncase entered this agreement .0 ·--.j with the intent to complete the job"!'; "His charges revolve around the contract as
a whole."32 In their Statement of Errors Complained of, Appellant Counsel referred
to the agreement twice: "In fact, there was no evidence that Roncase intended not
to perform on his agreement when Maria Kanellakis gave him money"33; "Where
the money was given to Roncase pursuant to the construction agreement. .. "34 All
of these things combined show a meeting of the minds between Roncase and
Kanellakis and fit the statutory requirement of an agreement, fulfilling the second
element of the offense of Failure to Make Required Disposition of Funds Received.
As all elements of the offense of theft by failure to make required disposition
of funds received have been met, there was sufficient evidence to find Roncase
guilty of this offense.
30 N.T., 182 31 N.T., 184 32 N.T., 184 33 Statement of Errors Complained of on Appeal, pg. 3 34 Id.
12 2. The evidence was sufficient to sustain William Roncase's conviction for » theft by deception. •._)
J1 A person is guilty of theft by deception if they: 1) intentionally obtain or •._)
::::, withholds 2) property of another 3) by deception. A person deceives if he .D intentionally 1) creates or reinforces a false impression, including a false .J1
impression as to law, value, intention or other state of mind; but deception as to a b.
person's intention to perform a promise shall not be inferred from the fact alone .o -�..! that he did not subsequently perform the promise.35 "·,.J Appellant alleges that the first element of the offense has not been met. They
argue that there was no evidence that Roncase intended not to perform on his
agreement when Kanellakis gave him money. In supporting their position,
Appellant cites Commonwealth v. Bruce.36 We find this case to be unpersuasive. In
Bruce, a lumber broker worked with Ongley, a sawmill owner, to sell lumber to a
buyer. Bruce would take possession of the lumber from Ongley and after being
paid by the buyer, Bruce would take his cut and then give the remaining profits to
Ongley. Their arrangement worked for several months. Eventually, Bruce owed
Ongley a debt; Bruce gave Ongley a check for the debt and in return Ongley gave
Bruce more lumber. Bruce was charged with theft by deception after the check
bounced and he failed to pay for the additional lumber Ongley gave him. The
35 18 Pa. C.S.A. §3922(a)(l) 36 Commonwealth v. Bruce, 607 A.2d 294 (Pa. Super. 1992).
13 .,')
1)
)1
Superior Court reversed the trial court's finding of guilt. They reasoned that
·.. ) "Appellant's intention not to pay for the lumber at the time he received it cannot be .Fl
inferred from the fact alone that he did not pay for all the lumber."37 Additionally,
the court also considered the fact that "at no time during their relationship did
.Tl appellant conceal his whereabouts or true identity from Ongley."38 .l:;� Bruce is materially different than the instant case. Whereas Bruce and i.D '··.J Ongley had prior business dealings in which Ongley was paid for the lumber,
Kanellakis did not have prior dealings with Roncase. This is significant because it
shows that there was a business relationship between Ongley and Bruce and time
was not of the essence for Ongley in the past. In the instant case, Roncase would
go to Kanellakis for money on a weekly or sometimes even more frequent basis.
Sometimes he would say what the money is for, as evidenced by notations on the
receipts. Even when Roncase would say what the money was specifically for it is
unclear ifhe actually used the money for that purpose. For example, Roncase told
Kanellakis he needed money for permits. We now know that he never got permits
for the 1512 East Market Street property.
Unlike in Bruce, there were times when Roncase would conceal his
whereabouts from Kanellakis, There were times when Kanellakis would go to the
=t« at 297 38 ]d.
14 ))
house and Roncase would not be there when he said he would be. Additionally,
j-._J Roncase would ignore both phone calls and text messages from Kanellakis. L,Fi
t•._) The Superior Court in Bruce focused on Bruce's intent at the time he 1--' r;.() received the lumber. Appellant focuses on this and argues "this [Appellant's
l-...
IJl subpar work] does not translate into intent to deceive at the relevant time." This
argument is made as if there was only a single relevant time. However, we find that
=. ...J there was not just a single relevant time. Appellant's conduct may be scrutinized
every time he received money from Kanellakis, which was approximately 36
times. We recognize that some work was done, for example new pillars were
constructed outside, and this work would have required money for the materials.
One of the most telling instances of conduct involved the building permits.
Appellant went to Kanellakis and said he needed $150 and $142 for building
permits. When the detective investigated, there were no building permits. This is
just one example of where Appellant took advantage ofKanellakis' naivety.
We find Commonwealth v. Shapiro39 to be more persuasive. In Shapiro, the
Superior Court found the first element of theft by deception to be present when
Shapiro appropriated his clients' funds for his own use. In the instant case, we find
that Appellant also appropriated Kanellakis' funds for his own use. First, Appellant
would ask Kanellakis for money for "materials" but when Kanellakis would go to
39 Commonwealth v, Shapiro, 418 A.2d 594 (Pa. Super. 1980).
15 the property she did not see the materials Appellant said he was buying." Other
times Appellant would askKanellakis for an "advance." When Kanellakis would
t·._) ask why he needed an advance it was always for personal reasons such as the water
pump going out on his car or having to travel to Philly to see his sick brother.41 We
I.fl certainly are not saying that a contractor should not be getting paid for labor, but J:.-,. the testimony reflects that very little labor was actually being done.42
"·�I To find intent one may look at the totality of the circumstances. In the ···--,J (.:) instant case, Appellant's failure to uphold his end of the agreement, failure to
complete a substantial portion of the work requested by Kanellakis, his use of
Kanellakis' money as his own, his propensity to conceal his whereabouts by
not being at the property when he said he would be and not responding to
Kanellakis' phone calls and text messages are indicative of Appellant's intent. For
the foregoing reasons we find that the first element of theft by deception has been
met.
Appellant argues that the second element of theft by deception has also not
been met. That is, that Appellant did not take the property of another because
under the construction agreement it was his money when he received it. This
element is substantially the same as the first element of theft by failure to make
40 N. T., 32 41 N.T., 36 42 Kanellakis observed that nothing was being done and when she brought it up to Appellant he always told her that it would be "done next week." N.T. 37
16 /) ··, J.i ., .., J'I
:a required disposition of funds. We have already analyzed this in the first section and
·· .. ) would incorporate our reasoning herein. We found that the property interest in the .,.11
· .. ) money did not pass to Appellant and it remained property of another. For the
:.D foregoing reasons, we find that the second element of theft by deception has been
As all elements of the offense of theft by deception have been met, there was
''•.j sufficient evidence to find Roncase guilty of this offense.
3. There was sufficient evidence to find Appellant guilty of home improvement fraud.
A person is guilty of home improvement fraud if they: 1) receive any
advance payment for performing home improvement services or providing home
improvement materials; and 2) fail to perform or provide such services or materials
when specified in the contract; and 3) fail to return the payment received for such
services or materials that were not provided by that date; and 4) do so with intent
to defraud or injure someone.
Appellant argues that the contract in this case does not specify any
completion date for the project and therefore the second element of the offense of
Home Improvement Fraud has not been met. This argument is unpersuasive.
17 '-.Fl
I·-·. • . .;.) There is not an abundance of case law regarding the home improvement o, fraud statute. However, we find Commonwealth v. Geske43 to be persuasive in the
instant case. In Geske, the Appellant and victim had a contract for various home
improvement projects.44 Appellant was supposed to install kitchen cabinets on 1---'' 1•• .r1 September 4, 2016 and was supposed to begin masonry work on September 15,
2016.45 Appellant did do some work on the kitchen cabinets on September 4 but
"·•.J left the project incomplete and left the victim's kitchen in disarray; September 4 "'·..J was the last date Appellant did any work in the victim's home.46 Appellant argued
that the evidence was insufficient to support the conviction of home improvement
fraud because the "Proposal" did not set forth a schedule for the masonry work."?
The Superior Court wholly rejected Appellant's argument. First, the
Superior Court rebuked Appellant for not including dates in the written "proposal"
as this is a violation of the Home Improvement Consumer Protection Act.48
Second, the Superior Court accepted the victim's testimony that he and Appellant
orally agreed to a start date.49 The Superior Court found the oral agreement
43 Commonwealth v. Geske, 2018 WL 3616384, No. 1417 MDA 2017 (Pa. Super. 2018). Non-Precedential Decision used only for persuasive purpose. 44 Id. at 1 45 Id. 46 Id. 47 Id at 2 48 Id at 4 49 Id
18 /J
:,J
I1
regarding the start date was sufficient to find that there was a date specified, as
required by the Home Improvement Fraud Statute. Jl
·-.) We find the facts of the instant case to be materially similar to Geske. The
estimate provided by Appellant did not include a specific start or end date. There is [···· l..'1 a notation on the estimate, written by Appellant, "Received $1,000 to start- 9-8-
o:, ° 17."5 Kanellakis believed this was the date that Appellant would start the project.
Kanellakis also testified about the end date for the project. When she asked (:) •· .•,,J Appellant how long it would take to do the job he told her that it would take two
months, but Kanellakis told Appellant that as long as it was done by the end of
December she would be happy.51 Like in Geske, we find the oral agreement
regarding the start and end date is sufficient to find that there was an agreement for
the completion date for the project.
Appellant argues that the intent element has also not been met. The element
of intent in home improvement fraud is substantially similar to the intent element
of theft by deception. We adopt our reasoning from the above section. We also
note that Appellant's intent to defraud Kanellakis can be shown through his
constant asking of more money from Kanellakis without purchasing materials or
performing labor that would justify the need for more money.
5 51 ° Commonwealth's Exhibit 1 N.T., 24
19 .n As all of the elements of home improvement fraud have been met we find
·· ...) the evidence was sufficient to convict Roncase of this offense. II
'..) ·:::;;i Conclusion
I··--" In conclusion, the trial court respectfully requests that the Superior Court ,.. n affirm the trial court's verdict of guilt for the crimes of theft by failure to make
required disposition of funds received, theft by deception, and home improvement U) �--� (:) fraud. ··-.,J
DATED: June 25, 2019