The Chancellor :
On the 20th day of May, 1872, the complainant, and defendant, Jameson, entered into a contract in writing, by which the former agreed “to do and perform all the work of every kind mentioned and contained in the foregoing specifications, which are hereby made a part of this contract, and according and subject to the conditions above recited,,and according to the drawings prepared and referred to,” for the sum of $3,400, which the said Jameson bound himself to make in separate payments as follows :
First payment when 2d-story floor joist are placed on the walls.
Second payment when enclosed and slated.
Third payment when plastered.
Fourth payment on the 1st of November, 1872.
“ The building to be completed on or before the 1st of October, 1872.”
The specifiations were for a brick dwelling house to be erected in Edgefield, and were drawn up with great particularity by the architects. The conditions appended to these [605]*605specifications, and which were also signed by the parties, were as follows:
“The contractor shall and will, at his own cost and charges, find, provide, and deliver all and every kind of new material of the best quality and description; together with the goods and chattels, cartage, scaffolding, tools, &c., which may be necessary for the due, proper and complete execution, and accordingly erect, build, execute, perform, finish and complete in the best workmanlike manner, to the perfect satisfaction and approbation of the architect, agreeably and conformably in all and every respect to the specifications, drawings, dimensions and explanations and observations therein or herein stated, described or implied, and all things incident thereto which may become necessary according to the true intent and meaning thereof, although not specifically stated or described by, but which may be inferred from the above said drawings and specifications, the same generally to illustrate each other. The architect to be at liberty to make any deviation from, or alteration in the plans, form, construction, details and execution described by the drawings and specifications, without invalidating or rendering void the contract ,• and in, case of any difference in the expense, an addition to or abatement from the said contract amount shall be made in the ratio or proportion such work may bear to the whole contract work agreed to be performed, and the same to be determined by the architect; but no extra or addition to be admitted or allowed unless executed under written authority from the owner. The architect’s opinions, certificate, report, and decision on all matters to be binding and conclusive.”
The work was commenced shortly after the contract was executed, but the building was not completed by the time designated in the contract. By the contract, also, the contractor was to provide and deliver, at his own .proper cost and expense, every thing necessary to carry on the work. But he admits in his deposition, that he had little or no means, and the proof abundantly shows that [606]*606from tbe first he was compelled to draw upon the defendant for money with which to pay for labor or material, or to meet necessary expenses. The plan adopted was for the complainant to draw upon the defendant in favor of his woi’k-men or employees, which orders the defendant paid and subsequently delivered up to the complainant when the latter delivered to the former the certificate of the architect’s showing that he was entitled to payment under the contract. On the 8th of July, 1872, the architect gave the complainant his first certificate for $400, which seems to have been at once taken up by the defendant. On the 5th of September, 1872, he gave him a second certificate for $2,200, the full amount of which is receipted for, on the back of the certificate, under the date of September 6, 1872. There is some dispute as to whether the receipt was given on that day, or afterwards and antedated, but none that it was executed. A third certificate was given on the 9th of October, 1872, for $850, stating on its face that it is for “the third instalment ” under the contract. These three certificates more than cover the entire consideration agreed to be paid by $50. This sum being added", with Jameson’s consent, to cover any changes in the work. The final estimate or certificate, which, as the architect says in his deposition, “ constitutes the approval ” of the work, was never given.
The building was not completed until in the month of November or December, and the defendant paid for the work and material necessary for its completion. The workmen seem to have been employed, in most if not all instances, by the complainant, but the defendant was compelled to promise to pay them, before they would do the work.
After the defendant had gone into possession and occupation of the building, an effort was made between him and the complainant, in the presence of the architect, to come to a settlement, but it failed, and thereupon the complainant filed his original bill claiming a large balance as still due him on the contract and for extra work, and claiming a mechanic’s lien. The defendant answered, and filed a cross-[607]*607bill for counter relief, insisting that be bad paid orders of tbe complainant to tbe full amount due, and incurred expenses necessary to tbe completion of tbe building according to contract, and sustained damage by reason of tbe failure of tbe complainant to do and complete bis work according to contract. Tbe defendant also stated that be bad become liable for tbe complainant by staying a judgment against bim wbicb be bad been compelled to pay. Proof was taken on both sides, and an order made by consent referring it to tbe master to take a general account, and bis report is before me on exceptions.
I have bad occasion heretofore to call tbe attention of tbe bar to an erroneous practice in tbis court, tbe evils of wbicb are strikingly exemplified in tbis case. Instead, of taldng proof with a view to a determination of tbe rights of tbe parties, and tbe settlement of tbe principles upon wbicb tbe account between them should be taken as a preliminary to tbe actual taking of tbe account, tbe learned counsel have inadvertently agreed upon a general reference settling nothing. Tbe consequence is that both tbe Clerk and Master and tbe Chancellor are compelled, if they act at all, to depart from their proper functions and perform, to some extent, tbe duties of each other. Their provinces, in tbis state, are, to a great extent, separate and distinct. It is tbe duty of tbe judge to adjudicate rights and settle principles. It is the duty of tbe master to inquire into and report upon facts. His duty is inquisitorial not judicial. Evans v. Evans, 2 Cold. 152. If you make a general reference to bim, without first settling tbe rights of tbe parties and giving bim special directions, be must himself judicially determine these rights before be can take any account at all. If be determines them wrong, tbe whole labor of taldng tbe account is thrown away. Moreover, no matter what report be makes, the Chancellor must, in acting upon exceptions, not only look to tbe facts bearing upon each exception, but settle tbe law wbicb regulates tbe rights of tbe parties. If he fails to do tbis, an account is taken without any adjudication of rights at all.
[608]*608In tbis case tbe original complainant was demanding a settlement upon tbe ground of tbe fulfillment of a contract.
Free access — add to your briefcase to read the full text and ask questions with AI
The Chancellor :
On the 20th day of May, 1872, the complainant, and defendant, Jameson, entered into a contract in writing, by which the former agreed “to do and perform all the work of every kind mentioned and contained in the foregoing specifications, which are hereby made a part of this contract, and according and subject to the conditions above recited,,and according to the drawings prepared and referred to,” for the sum of $3,400, which the said Jameson bound himself to make in separate payments as follows :
First payment when 2d-story floor joist are placed on the walls.
Second payment when enclosed and slated.
Third payment when plastered.
Fourth payment on the 1st of November, 1872.
“ The building to be completed on or before the 1st of October, 1872.”
The specifiations were for a brick dwelling house to be erected in Edgefield, and were drawn up with great particularity by the architects. The conditions appended to these [605]*605specifications, and which were also signed by the parties, were as follows:
“The contractor shall and will, at his own cost and charges, find, provide, and deliver all and every kind of new material of the best quality and description; together with the goods and chattels, cartage, scaffolding, tools, &c., which may be necessary for the due, proper and complete execution, and accordingly erect, build, execute, perform, finish and complete in the best workmanlike manner, to the perfect satisfaction and approbation of the architect, agreeably and conformably in all and every respect to the specifications, drawings, dimensions and explanations and observations therein or herein stated, described or implied, and all things incident thereto which may become necessary according to the true intent and meaning thereof, although not specifically stated or described by, but which may be inferred from the above said drawings and specifications, the same generally to illustrate each other. The architect to be at liberty to make any deviation from, or alteration in the plans, form, construction, details and execution described by the drawings and specifications, without invalidating or rendering void the contract ,• and in, case of any difference in the expense, an addition to or abatement from the said contract amount shall be made in the ratio or proportion such work may bear to the whole contract work agreed to be performed, and the same to be determined by the architect; but no extra or addition to be admitted or allowed unless executed under written authority from the owner. The architect’s opinions, certificate, report, and decision on all matters to be binding and conclusive.”
The work was commenced shortly after the contract was executed, but the building was not completed by the time designated in the contract. By the contract, also, the contractor was to provide and deliver, at his own .proper cost and expense, every thing necessary to carry on the work. But he admits in his deposition, that he had little or no means, and the proof abundantly shows that [606]*606from tbe first he was compelled to draw upon the defendant for money with which to pay for labor or material, or to meet necessary expenses. The plan adopted was for the complainant to draw upon the defendant in favor of his woi’k-men or employees, which orders the defendant paid and subsequently delivered up to the complainant when the latter delivered to the former the certificate of the architect’s showing that he was entitled to payment under the contract. On the 8th of July, 1872, the architect gave the complainant his first certificate for $400, which seems to have been at once taken up by the defendant. On the 5th of September, 1872, he gave him a second certificate for $2,200, the full amount of which is receipted for, on the back of the certificate, under the date of September 6, 1872. There is some dispute as to whether the receipt was given on that day, or afterwards and antedated, but none that it was executed. A third certificate was given on the 9th of October, 1872, for $850, stating on its face that it is for “the third instalment ” under the contract. These three certificates more than cover the entire consideration agreed to be paid by $50. This sum being added", with Jameson’s consent, to cover any changes in the work. The final estimate or certificate, which, as the architect says in his deposition, “ constitutes the approval ” of the work, was never given.
The building was not completed until in the month of November or December, and the defendant paid for the work and material necessary for its completion. The workmen seem to have been employed, in most if not all instances, by the complainant, but the defendant was compelled to promise to pay them, before they would do the work.
After the defendant had gone into possession and occupation of the building, an effort was made between him and the complainant, in the presence of the architect, to come to a settlement, but it failed, and thereupon the complainant filed his original bill claiming a large balance as still due him on the contract and for extra work, and claiming a mechanic’s lien. The defendant answered, and filed a cross-[607]*607bill for counter relief, insisting that be bad paid orders of tbe complainant to tbe full amount due, and incurred expenses necessary to tbe completion of tbe building according to contract, and sustained damage by reason of tbe failure of tbe complainant to do and complete bis work according to contract. Tbe defendant also stated that be bad become liable for tbe complainant by staying a judgment against bim wbicb be bad been compelled to pay. Proof was taken on both sides, and an order made by consent referring it to tbe master to take a general account, and bis report is before me on exceptions.
I have bad occasion heretofore to call tbe attention of tbe bar to an erroneous practice in tbis court, tbe evils of wbicb are strikingly exemplified in tbis case. Instead, of taldng proof with a view to a determination of tbe rights of tbe parties, and tbe settlement of tbe principles upon wbicb tbe account between them should be taken as a preliminary to tbe actual taking of tbe account, tbe learned counsel have inadvertently agreed upon a general reference settling nothing. Tbe consequence is that both tbe Clerk and Master and tbe Chancellor are compelled, if they act at all, to depart from their proper functions and perform, to some extent, tbe duties of each other. Their provinces, in tbis state, are, to a great extent, separate and distinct. It is tbe duty of tbe judge to adjudicate rights and settle principles. It is the duty of tbe master to inquire into and report upon facts. His duty is inquisitorial not judicial. Evans v. Evans, 2 Cold. 152. If you make a general reference to bim, without first settling tbe rights of tbe parties and giving bim special directions, be must himself judicially determine these rights before be can take any account at all. If be determines them wrong, tbe whole labor of taldng tbe account is thrown away. Moreover, no matter what report be makes, the Chancellor must, in acting upon exceptions, not only look to tbe facts bearing upon each exception, but settle tbe law wbicb regulates tbe rights of tbe parties. If he fails to do tbis, an account is taken without any adjudication of rights at all.
[608]*608In tbis case tbe original complainant was demanding a settlement upon tbe ground of tbe fulfillment of a contract. Tbe defendant was insisting by cross-bill upon damages for a failure to comply with tbe contract. Of course, no account could be satisfactorily taken until it was first determined whether there bad been a fulfillment or breach of contract. Tbe parties, without any bearing or adjudication, agree to a reference ‘ ‘ to take an account of all tbe dealings and transactions between tbe complainant and defendant, and to report tbe balance.” Nothing could possibly be more general, or more unsatisfactory. Tbe Clerk and Master, in executing this reference, has chosen, and, I think» properly, to construe tbe words of tbe order literally, and to report upon nothing but “dealings and transactions ” between the parties, that is, orders made by the one and payments made by tbe other. He has entirely ignored tbe rights of tbe defendant, if be lias any, to damages for a failure to comply with the contract; nor could be notice such rights without usurping tbe province of tbe Chancellor, and deciding that the defendant bad such rights. But an account so taken is clearly one-sided. The defendant seeks to rectify the defect by filing exceptions specifying damages, and claiming damages. The court may very properly determine the question whether he is, oris not entitled to damages. If the Chancellor goes a step further, as required by the exceptions, and determines the amount of damages, he is, in turn, performing the duties of the Master. The parties are entitled to the judgment of the court upon the right to damages, and to the judgment of the Master, upon a reference, as to the extent of the damage. If I undertake now, to fix the items of damage, the parties will never have had the benefit of the Master’s scrutiny upon the questions of fact involved; for the Master, in this case, has refused to investigate these facts? The only correct mode of proceeding is to have the legal rights of the parties first adjudged, and upon such adjudication a reference to the Master, whose duty it will then be carefully to sift the facts. His conclusions, upon these facts, [609]*609may be revised by the Chancellor, upon proper exceptions, but it is obvious that the parties have had the benefit of the double investigation. By the plan adopted in this case, the parties have lost the benefit of the Master’s judgment, and have not the full benefit of the Chancellor’s judgment upon the facts alone, for he has the onerous duty, at the same time, of deciding the law.
In this case, it is very clear that there has been a breach of contract by the complainant in not completing the building in the time stipulated, and in failing to ‘ ‘ find, provide, and deliver all and every kind of material ” necessary to the erection of the building, and to “erect, build, execute, perform, finish, and complete” said building, “at his own cost and charges.” The proof leaves no doubt that the material was supplied and the work done at the cost and charges of the defendant, and that his expenditures largely exceeded the contract price. The defendant is entitled to be credited with the two sums of $400 and $2,200 shown to have been paid by him to the complainant or on his orders, and with such further sums of money as he may show that he has paid to the complainant, or for him, or upon his order, and with such sums of money as he may have been compelled to pay for work, labor and materials necessary to the completion of the building according to contract. He is also entitled to recoup the complainant’s demand by any damages he may have sustained by reason of the complainant’s failure to do any part of the work according to contract, or to complete the building by the 1st of October, 1872, as stipulated. The proof fails to show that the delay in completing was in any respect the fault of the defendant, but the burden will be upon him to show actual damage by the delay.
The complainant is entitled to the price agreed upon by his contract, less $235 which, he admits, he agreed with the defendant to deduct for plastering paid for by the latter. He will also be entitled to the $50 admitted to be due for extra work, but to no other extra work “ unless executed [610]*610under written authority’ ’ from the defendant. If, however, he can show a special contract with the defendant, even by parol for work not within the contract, he will be allowed the same under such special contract, but not under the original contract. He is also entitled to any difference in expense over contract price occasioned by any deviation from or alteration in the plans, etc., made by the architect as provided in the contract, in the ratio of such work to the whole work.
The rights of the parties will be declared by decree in accordance with this opinion. If either party desires that the matters of account shall be again referred to the Master, with directions to take and report the same in accordance with the principles adjudged, the report already, made will be set aside and the reference ordered. If the parties prefer, however, that I should finally determine their rights upon the report and exceptions already made and filed, I will act upon them.