NOT FOR PUBLICATION WITHOUT THE APPROVAL OF THE APPELLATE DIVISION This opinion shall not "constitute precedent or be binding upon any court." Although it is posted on the internet, this opinion is binding only on the parties in the case and its use in other cases is limited. R. 1:36-3.
SUPERIOR COURT OF NEW JERSEY APPELLATE DIVISION DOCKET NO. A-0362-18T1
CNJ CONSTRUCTION CORPORATION,
Plaintiff-Respondent,
v.
AUTOBUILDERS GENERAL CONTRACTING SERVICES, INC.,
Defendant-Appellant,
and
ARCH INSURANCE COMPANY,
Defendant. ___________________________________
Submitted October 31, 2019 – Decided January 31, 2020
Before Judges Nugent and DeAlmeida.
On appeal from the Superior Court of New Jersey, Law Division, Morris County, Docket No. L-1327-16.
Scott Mark Yaffe, attorney for appellant. Hoagland Longo Moran Dunst & Doukas, attorneys for respondent (Lawrence P. Powers, of counsel; Peter K. Oliver, on the brief).
PER CURIAM
Defendant Autobuilders General Contracting Services, Inc.
(Autobuilders) appeals from the August 14, 2018 final judgment of the Law
Division awarding damages to plaintiff CNJ Construction Corporation (CNJ)
and dismissing Autobuilders's counterclaim in this construction contract
dispute. We affirm.
I.
The trial court found the following facts after trial. Autobuilders was the
general contractor responsible for the construction of a Maserati dealership in
Morris County (the Project). In 2014 and 2015, Autobuilders entered into four
subcontracts with CNJ relating to the Project. Under the subcontracts, CNJ was
responsible for demolition, concrete, steel, and site work. The provisions of the
four subcontracts at issue here are identical.
According to Article 9.1 of the subcontracts,
[i]f in the opinion of Autobuilders, [CNJ] shall at any time: (1) refuse or fail to provide sufficient properly skilled workmen or materials of the proper quality; (2) fail in any respect to prosecute the work according to the current schedule; (3) cause, by any action or omission, the stoppage, or delay of or interference with
A-0362-18T1 2 the work of Autobuilders or of any other builder or subcontractor; (4) fail to comply with all provisions of this Subcontract or the Contract Documents[;] or (5) act, or fail to act, in any other way which significantly and negatively impacts the timely completion of the Project or otherwise negatively impacts the work in general, then after serving three (3) days' written notice, unless the condition(s) specified in such notice shall have been alleviated within such three (3) days, Autobuilders may, at its option: (a) . . . take such steps as are necessary to overcome the condition, in which case [CNJ] shall be liable to Autobuilders for the cost thereof . . . or (b) terminate the Subcontract for default [and] complete the work either by itself or through others . . . .
....
Notwithstanding anything herein to the contrary, in the event [CNJ] actually or effectively abandons its contract work on the Project, or is otherwise aware of its continuing non-performance or unacceptable work, Autobuilders may exercise its options herein without the requirement of any three[-]day written notice.
In the event of a termination for default under Article 9.1, if the amount paid by
Autobuilders to complete the subcontract exceeds the amount due to CNJ for the
work it performed prior to the termination CNJ is liable to Autobuilders for the
difference.
Article 24.1 of the subcontracts provides the methods for providing notice
to CNJ of alleged deficiencies under Article 9.1. Such notices must be sent to
the address or telephone number specified in the subcontract by fax, with written
A-0362-18T1 3 confirmation, nationally recognized overnight carrier, or registered mail, return
receipt requested.
Article 9.3 provides, "[i]f Autobuilders wrongfully exercises any option
under Article 9.1 . . . such exercise shall be deemed a [t]ermination for
[c]onvenience and [CNJ will be] compensated as provided for in Article 15" of
the subcontracts. Article 15.1 provides that after a termination for convenience,
CNJ "shall be paid the amount representing costs which are due . . . for its work
as provided in the" subcontracts without being responsible for the costs incurred
by Autobuilders after termination.
On September 16, 2015, an Autobuilders representative sent four letters
to CNJ, one for each subcontract, alleging deficiencies in CNJ's performance.
Although the letters listed verbatim the categories of deficiencies set forth in
Article 9.1, they did not identify with specificity any alleged deficiency in CNJ's
work. The letters stated Autobuilders
will accordingly exercise its right to supplement your company's work for any further delays, omissions, lack of materials, failure to follow the schedule, or any other act or omission that relates to any of the above stated issues. [CNJ] will be back charged for all related costs and expenses.
The letters, which were not sent by any of the methods of delivery set forth in
Article 24.1, made no mention of a three-day cure period.
A-0362-18T1 4 On the same day it received the September 16, 2015 notice, CNJ requested
in writing clarification of the nature of the deficiencies and an opportunity to
cure the deficiencies. CNJ also demanded payment for work it had completed
under the subcontracts.
On September 24, 2015, Autobuilders sent CNJ a letter specifying in
detail alleged deficiencies in CNJ's work. At the time it sent the September 24,
2015 letter, Autobuilders had already signed at least one subcontract to correct
the alleged deficiencies in CNJ's work and paid a subcontractor for that work.
Autobuilders refused to pay invoices submitted by CNJ for work it completed
on the Project prior to the September 16, 2015 letter. The parties ultimately
stipulated the amount sought by CNJ for completed work under the demolition,
concrete, and steel subcontracts totaled $110,052.15.
CNJ filed construction liens on the demolition, concrete, and steel
subcontracts for its outstanding invoices. It subsequently filed a complaint in
the Law Division alleging book account claims and claims under the
Construction Lien Law, N.J.S.A. 2A:44A-1 to -38, to recover what it alleges it
is due for work completed on the demolition, concrete, and steel subcontracts.
CNJ does not seek payment under the site work subcontract, as it concedes it
was paid for all work it performed under that agreement.
A-0362-18T1 5 Autobuilders filed a counterclaim alleging under Article 9.1 CNJ is liable
for the costs Autobuilders incurred to complete the site work subcontract.
Autobuilders alleged the amount CNJ owes on the counterclaim offsets all
amounts Autobuilders owes CNJ, and results in a liability in favor of
Autobuilders of $145,107.82.
The matter was tried without a jury over two days before Judge Frank J.
DeAngelis. During trial, Autobuilders argued it provided notice and a three-day
cure period in conformity with Articles 9.1 and 24.1 and, alternatively, that CNJ
abandoned the Project after receipt of the September 16, 2015 letter.
On August 1, 2018, Judge DeAngelis issued a comprehensive oral opinion
in which he found Autobuilders provided no evidence that it complied with the
notice provisions of Articles 9.1 and 24.1, and failed to provide CNJ with a
Free access — add to your briefcase to read the full text and ask questions with AI
NOT FOR PUBLICATION WITHOUT THE APPROVAL OF THE APPELLATE DIVISION This opinion shall not "constitute precedent or be binding upon any court." Although it is posted on the internet, this opinion is binding only on the parties in the case and its use in other cases is limited. R. 1:36-3.
SUPERIOR COURT OF NEW JERSEY APPELLATE DIVISION DOCKET NO. A-0362-18T1
CNJ CONSTRUCTION CORPORATION,
Plaintiff-Respondent,
v.
AUTOBUILDERS GENERAL CONTRACTING SERVICES, INC.,
Defendant-Appellant,
and
ARCH INSURANCE COMPANY,
Defendant. ___________________________________
Submitted October 31, 2019 – Decided January 31, 2020
Before Judges Nugent and DeAlmeida.
On appeal from the Superior Court of New Jersey, Law Division, Morris County, Docket No. L-1327-16.
Scott Mark Yaffe, attorney for appellant. Hoagland Longo Moran Dunst & Doukas, attorneys for respondent (Lawrence P. Powers, of counsel; Peter K. Oliver, on the brief).
PER CURIAM
Defendant Autobuilders General Contracting Services, Inc.
(Autobuilders) appeals from the August 14, 2018 final judgment of the Law
Division awarding damages to plaintiff CNJ Construction Corporation (CNJ)
and dismissing Autobuilders's counterclaim in this construction contract
dispute. We affirm.
I.
The trial court found the following facts after trial. Autobuilders was the
general contractor responsible for the construction of a Maserati dealership in
Morris County (the Project). In 2014 and 2015, Autobuilders entered into four
subcontracts with CNJ relating to the Project. Under the subcontracts, CNJ was
responsible for demolition, concrete, steel, and site work. The provisions of the
four subcontracts at issue here are identical.
According to Article 9.1 of the subcontracts,
[i]f in the opinion of Autobuilders, [CNJ] shall at any time: (1) refuse or fail to provide sufficient properly skilled workmen or materials of the proper quality; (2) fail in any respect to prosecute the work according to the current schedule; (3) cause, by any action or omission, the stoppage, or delay of or interference with
A-0362-18T1 2 the work of Autobuilders or of any other builder or subcontractor; (4) fail to comply with all provisions of this Subcontract or the Contract Documents[;] or (5) act, or fail to act, in any other way which significantly and negatively impacts the timely completion of the Project or otherwise negatively impacts the work in general, then after serving three (3) days' written notice, unless the condition(s) specified in such notice shall have been alleviated within such three (3) days, Autobuilders may, at its option: (a) . . . take such steps as are necessary to overcome the condition, in which case [CNJ] shall be liable to Autobuilders for the cost thereof . . . or (b) terminate the Subcontract for default [and] complete the work either by itself or through others . . . .
....
Notwithstanding anything herein to the contrary, in the event [CNJ] actually or effectively abandons its contract work on the Project, or is otherwise aware of its continuing non-performance or unacceptable work, Autobuilders may exercise its options herein without the requirement of any three[-]day written notice.
In the event of a termination for default under Article 9.1, if the amount paid by
Autobuilders to complete the subcontract exceeds the amount due to CNJ for the
work it performed prior to the termination CNJ is liable to Autobuilders for the
difference.
Article 24.1 of the subcontracts provides the methods for providing notice
to CNJ of alleged deficiencies under Article 9.1. Such notices must be sent to
the address or telephone number specified in the subcontract by fax, with written
A-0362-18T1 3 confirmation, nationally recognized overnight carrier, or registered mail, return
receipt requested.
Article 9.3 provides, "[i]f Autobuilders wrongfully exercises any option
under Article 9.1 . . . such exercise shall be deemed a [t]ermination for
[c]onvenience and [CNJ will be] compensated as provided for in Article 15" of
the subcontracts. Article 15.1 provides that after a termination for convenience,
CNJ "shall be paid the amount representing costs which are due . . . for its work
as provided in the" subcontracts without being responsible for the costs incurred
by Autobuilders after termination.
On September 16, 2015, an Autobuilders representative sent four letters
to CNJ, one for each subcontract, alleging deficiencies in CNJ's performance.
Although the letters listed verbatim the categories of deficiencies set forth in
Article 9.1, they did not identify with specificity any alleged deficiency in CNJ's
work. The letters stated Autobuilders
will accordingly exercise its right to supplement your company's work for any further delays, omissions, lack of materials, failure to follow the schedule, or any other act or omission that relates to any of the above stated issues. [CNJ] will be back charged for all related costs and expenses.
The letters, which were not sent by any of the methods of delivery set forth in
Article 24.1, made no mention of a three-day cure period.
A-0362-18T1 4 On the same day it received the September 16, 2015 notice, CNJ requested
in writing clarification of the nature of the deficiencies and an opportunity to
cure the deficiencies. CNJ also demanded payment for work it had completed
under the subcontracts.
On September 24, 2015, Autobuilders sent CNJ a letter specifying in
detail alleged deficiencies in CNJ's work. At the time it sent the September 24,
2015 letter, Autobuilders had already signed at least one subcontract to correct
the alleged deficiencies in CNJ's work and paid a subcontractor for that work.
Autobuilders refused to pay invoices submitted by CNJ for work it completed
on the Project prior to the September 16, 2015 letter. The parties ultimately
stipulated the amount sought by CNJ for completed work under the demolition,
concrete, and steel subcontracts totaled $110,052.15.
CNJ filed construction liens on the demolition, concrete, and steel
subcontracts for its outstanding invoices. It subsequently filed a complaint in
the Law Division alleging book account claims and claims under the
Construction Lien Law, N.J.S.A. 2A:44A-1 to -38, to recover what it alleges it
is due for work completed on the demolition, concrete, and steel subcontracts.
CNJ does not seek payment under the site work subcontract, as it concedes it
was paid for all work it performed under that agreement.
A-0362-18T1 5 Autobuilders filed a counterclaim alleging under Article 9.1 CNJ is liable
for the costs Autobuilders incurred to complete the site work subcontract.
Autobuilders alleged the amount CNJ owes on the counterclaim offsets all
amounts Autobuilders owes CNJ, and results in a liability in favor of
Autobuilders of $145,107.82.
The matter was tried without a jury over two days before Judge Frank J.
DeAngelis. During trial, Autobuilders argued it provided notice and a three-day
cure period in conformity with Articles 9.1 and 24.1 and, alternatively, that CNJ
abandoned the Project after receipt of the September 16, 2015 letter.
On August 1, 2018, Judge DeAngelis issued a comprehensive oral opinion
in which he found Autobuilders provided no evidence that it complied with the
notice provisions of Articles 9.1 and 24.1, and failed to provide CNJ with a
three-day period in which to cure alleged deficiencies in its work. In addition,
Judge DeAngelis found the record contained no evidence CNJ abandoned the
Project after the September 16, 2015 notice, given its written request for
clarification of the alleged deficiencies on the same day it received the notice.
Thus, the judge concluded, Autobuilders terminated the site work subcontract
for convenience and is not entitled to recover from CNJ amounts spent after
termination of the site work subcontract. Finally, Judge DeAngelis found CNJ
A-0362-18T1 6 established its claim Autobuilders owed it $110,052.15 for work performed on
the demolition, cement, and steel subcontracts. In reaching his decisions, the
judge made specific credibility determinations based on the the testimony of the
witnesses.
On August 14, 2018, the court entered judgment awarding CNJ
$110,052.15 in damages and dismissing Autobuilders's counterclaim.
This appeal followed. Autobuilders makes the following arguments for
our consideration:
POINT I
THE TRIAL COURT ERRED IN MAKING AN AWARD TO CNJ ON THE CONCRETE AND STRUCTURAL STEEL SUBCONTRACTS AS CNJ PROVIDED NO EVIDENCE OF ANY UNPAID COSTS.
POINT II
THE TRIAL COURT ERRED IN NOT MAKING AN AWARD TO AUTOBUILDERS ON ITS COUNTERCLAIM AS AN OVERPAYMENT WAS PROVEN PRIMA FACIE AND UNCONTROVERTED.
II.
Our scope of review of the judge's findings in this nonjury case is limited.
We must defer to the judge's factual determinations, so long as they are
A-0362-18T1 7 supported by substantial credible evidence in the record. Rova Farms Resort,
Inc. v. Inv'rs Ins. Co. of Am., 65 N.J. 474, 483-84 (1974). This court's
"[a]ppellate review does not consist of weighing evidence anew and making
independent factual findings; rather, [this court's] function is to determine
whether there is adequate evidence to support the judgment rendered at trial."
Cannuscio v. Claridge Hotel & Casino, 319 N.J. Super. 342, 347 (App. Div.
1999) (citing State v. Johnson, 42 N.J. 146, 161 (1964)). We only review de
novo the court’s legal conclusions. Manalapan Realty, L.P. v. Twp. Comm.,
140 N.J. 366, 378 (1995).
In addition, this court "must give deference to those findings of the trial
judge which are substantially influenced by his or her opportunity to hear and
see the witnesses and have the 'feel' of the case, which [this court does] not enjoy
upon appellate review." State ex rel. D.M., 451 N.J. Super. 415, 424 (App. Div.
2017) (quoting State ex rel. S.B., 333 N.J. Super. 236, 241 (App. Div. 2000)).
There must be "deference to the trial court's credibility determinations[,]"
N.J. Div. of Youth & Family Servs. v. M.M., 189 N.J. 261, 279 (2007), "because
it 'hears the case, sees and observes the witnesses, and hears them testify,'
affording it 'a better perspective than a reviewing court in evaluating the veracity
A-0362-18T1 8 of a witness.'" City Council v. Edwards, 455 N.J. Super. 261, 272 (App. Div.
2018) (quoting Gnall v. Gnall, 222 N.J. 414, 428 (2015)).
Having carefully reviewed Autobuilders's arguments in light of the record
and applicable legal principles, we are satisfied there is substantial credible
evidence supporting Judge DeAngelis's findings of fact. We also agree with his
legal conclusions CNJ is entitled to recovery for the work it performed under
the demolition, concrete, and steel subcontracts, the amount due under those
subcontracts was agreed to by the parties and not controverted at trial, and
Autobuilders failed to establish its counterclaim. We therefore affirm the
August 14, 2018 final judgment for the reasons stated in Judge DeAngelis's
August 1, 2018 oral opinion.
Affirmed.
A-0362-18T1 9