Camosy, Inc. v. State

Court of Claims of Illinois

Camosy, Inc. v. State

33 Ill. Ct. Cl. 94, 1979 Ill. Ct. Cl. LEXIS 23

CourtCourt of Claims of Illinois

DecidedAugust 13, 1979

DocketNo. 75-CC-1366

StatusPublished

This text of 33 Ill. Ct. Cl. 94 (Camosy, Inc. v. State) is published on Counsel Stack Legal Research, covering Court of Claims of Illinois primary law. Counsel Stack provides free access to over 12 million legal documents including statutes, case law, regulations, and constitutions.

Bluebook

Camosy, Inc. v. State, 33 Ill. Ct. Cl. 94, 1979 Ill. Ct. Cl. LEXIS 23 (Ill. Super. Ct. 1979).

Pincite

Opinion

Per Curiam.

This claim coming on to be heard on the joint stipulation of the parties hereto, and the Court being fully advised in the premises:

This Court finds that this claim is for time lost and other costs involved in the delay in installation of a sanitary sewer for the Mental Retardation Facility, Department of Mental Health, Waukegan, Illinois. An investigation of this claim by the Capital Development Board determined that the delay was caused by the Respondent’s failure to obtain a required sewer permit causing the job to be stopped, and that after a thorough examination and audit it was determined that $100,000.00 was a fair, legal and proper figure to reimburse Claimant for time lost plus $25,000.00 retained from Claimant in a progress payment.

It is hereby ordered that the sum of $125,000.00 be hereby awarded to Claimant, Camosy, Inc., in full satisfaction of any and all claims presented to the State of Illinois under the above-captioned cause.

Free access — add to your briefcase to read the full text and ask questions with AI

Per Curiam.

This claim coming on to be heard on the joint stipulation of the parties hereto, and the Court being fully advised in the premises:

This Court finds that this claim is for time lost and other costs involved in the delay in installation of a sanitary sewer for the Mental Retardation Facility, Department of Mental Health, Waukegan, Illinois. An investigation of this claim by the Capital Development Board determined that the delay was caused by the Respondent’s failure to obtain a required sewer permit causing the job to be stopped, and that after a thorough examination and audit it was determined that $100,000.00 was a fair, legal and proper figure to reimburse Claimant for time lost plus $25,000.00 retained from Claimant in a progress payment.

It is hereby ordered that the sum of $125,000.00 be hereby awarded to Claimant, Camosy, Inc., in full satisfaction of any and all claims presented to the State of Illinois under the above-captioned cause.

Cite This Page — Counsel Stack

Bluebook (online)

33 Ill. Ct. Cl. 94, 1979 Ill. Ct. Cl. LEXIS 23, Counsel Stack Legal Research, https://law.counselstack.com/opinion/camosy-inc-v-state-ilclaimsct-1979.